Sheriff-Coroner definition

Sheriff-Coroner means the Sheriff-Coroner, County of Orange, or designee, or upon written notice to Lessor, such other person or entity as shall be designated by the County Executive Officer or the Board of Supervisors.
View Source

Examples of Sheriff-Coroner in a sentence

  • Orange County Sheriff-Coroner Department may, in writing, require the Contractor to remove from the Work any employee County Project Manager deems incompetent, careless, or otherwise objectionable.

  • If the Contractor fails or refuses to comply promptly, Orange County Sheriff-Coroner Department may issue an order stopping all or part of the Work until satisfactory corrective action has been taken.

  • Failure of receipt of such notice from Orange County Sheriff-Coroner Department shall not relieve the Contractor of responsibility.

  • Visitors for other purposes shall be referred to Orange County Sheriff-Coroner Department.

  • The Contractor shall, without charge, replace any material or correct any workmanship found by Orange County Sheriff-Coroner Department not to conform to the Contract requirements, unless in the public interest Orange County Sheriff-Coroner Department consents to accept such material or workmanship with an appropriate adjustment in Contract price.

  • The Contractor shall report to Orange County Sheriff-Coroner Department, promptly and in reasonable detail, each notice or claim of patent infringement based on the performance of this Contract of which the Contractor has knowledge.

  • Orange County Sheriff-Coroner Department (OCSD) is the authorized representative of the Board of Supervisors and, under the Board of Supervisors, has complete charge of the Contract, and shall exercise full control of the Contract, so far as it affects the interest of the County.

  • Orange County Sheriff-Coroner Department shall ascertain the facts and the extent of the delay and extend the time for completing the Project when, in its judgment, the delay is justified.

  • Orange County Sheriff-Coroner Department may notify the Contractor of any noncompliance with the foregoing provisions and the action to be taken.

  • COUNTY, through its Sheriff-Coroner and deputies, officers and employees, 24 hereinafter referred to as “SHERIFF”, shall render to CITY law enforcement 25 services as hereinafter provided.