SECTION 107 definition

SECTION 107. LEGAL REGULATIONS AND RESPONSIBILITY TO THE PUBLIC "The Contractor shall inspect all easements and rights-of-way to insure that the County has obtained all land and rights-of-way necessary for completion of the Work to be performed pursuant to the Contract Documents. The Contractor shall comply with all stipulations contained in easements acquired by the County." "The Contractor is responsible for the location of above and below ground utilities and structures which may be affected by the Work." SECTION 108 PROSECUTION AND PROGRESS The Engineer has the authority to suspend the Work wholly or in part, for as long as he may deem necessary, because of unsuitable weather, or other conditions considered unfavorable for continuing the Work, or for as long as he may deem necessary by reason of failure of the Contractor to carry out orders given, or to comply with any provisions of the Contract. If the performance of all or any portion of the Work is suspended or delayed by the Engineer, in writing, for an unreasonable period of time (not originally anticipated, customary, or inherent to the construction industry) and the Contractor believes that additional compensation and/or contract time is due as a result of such suspension or delay, the Contractor shall submit to the Engineer, in writing, a request for adjustment within 7 calendar days of receipt of the notice to resume work. The request shall set forth the reasons and support for such adjustment. Upon receipt, the Engineer will evaluate the Contractor's request. If the Engineer agrees that the cost and/or time required for the performance of the Contract has increased as a result of such suspension and the suspension was caused by conditions beyond the control of, and not the fault of, the Contractor, its suppliers, or subcontractors at any approved tier, and not caused by weather, the Engineer will make an adjustment (excluding profit) and modify the Contract in writing accordingly. The Engineer will notify the Contractor of his/her determination whether or not an adjustment of the Contract is warranted. No contract adjustment will be allowed unless the Contractor has submitted the request for adjustment within the time prescribed. No contract adjustment will be allowed under this clause to the extent that performance would have been suspended or delayed by any other cause, or for which an adjustment is provided for or excluded under any other term or condition of this Contract.
View Source

Examples of SECTION 107 in a sentence

  • NOTHING IN THIS SECTION 10.7 SHALL AFFECT THE RIGHT OF THE PARTIES HERETO TO SERVE LEGAL PROCESS IN ANY OTHER MANNER PERMITTED BY LAW.

  • EACH OF THE PARTIES REPRESENTS TO EACH OTHER PARTY HERETO THAT IT HAS DISCUSSED THIS AGREEMENT AND, SPECIFICALLY, THE PROVISIONS OF SECTION 10.7 AND THIS SECTION 10.13, WITH ITS COUNSEL.

  • By /s/ ▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ --------------------------------- Title SVP / CFO / Secretary Guarantor Signature: ▇▇▇▇▇▇▇, Inc.

  • MISCELLANEOUS 31 SECTION 10.1. Supplements and Amendments 31 SECTION 10.2. No Legal Title to Owner Trust Estate in Certificateholder 32 SECTION 10.3. Limitations on Rights of Others 32 SECTION 10.4. Notices 32 SECTION 10.5. Severability 33 SECTION 10.6. Counterparts and Consent to Do Business Electronically 33 SECTION 10.7. Assignments 33 SECTION 10.8. No Recourse 33 SECTION 10.9. Headings 33 SECTION 10.10.

  • MISCELLANEOUS 31 SECTION 10.1. Supplements and Amendments 31 SECTION 10.2. No Legal Title to Owner Trust Estate in Certificateholder 32 SECTION 10.3. Limitations on Rights of Others 33 SECTION 10.4. Notices 33 SECTION 10.5. Severability 33 SECTION 10.6. Counterparts and Consent to Do Business Electronically 33 SECTION 10.7. Assignments 34 SECTION 10.8. No Recourse 34 SECTION 10.9. Headings 34 SECTION 10.10.

  • NOTHING IN THIS SECTION 10.7 SHALL AFFECT THE COMPANY’S RIGHT TO SERVE LEGAL PROCESS IN ANY OTHER MANNER PERMITTED BY LAW OR TO BRING ANY ACTION OR PROCEEDING AGAINST ANY ORIGINATOR OR ITS PROPERTY IN THE COURTS OF ANY OTHER JURISDICTIONS.

  • When Contractor-furnished borrow or plant sites are outside the project limits, obtain all required permits and clearances required for compliance, SECTION 107.

  • EACH PARTY CERTIFIES AND ACKNOWLEDGES THAT (I) NO REPRESENTATIVE, AGENT OR ATTORNEY OR ANY OTHER PARTY HAS REPRESENTED, EXPRESSLY OR OTHERWISE, THAT SUCH OTHER PARTY WOULD NOT, IN THE EVENT OF LITIGATION, SEEK TO ENFORCE THE FOREGOING WAIVER, (II) IT UNDERSTANDS AND HAS CONSIDERED THE IMPLICATIONS OF SUCH WAIVER, (III) IT MAKES SUCH WAIVER VOLUNTARILY AND (IV) IT HAS BEEN INDUCED TO ENTER INTO THIS AGREEMENT BY, AMONG OTHER THINGS, THE MUTUAL WAIVERS AND CERTIFICATIONS IN THIS SECTION 10.7.

  • NOTHING IN THIS SECTION 10.7 SHALL AFFECT THE COMPANY'S RIGHT TO SERVE LEGAL PROCESS IN ANY OTHER MANNER PERMITTED BY LAW OR TO BRING ANY ACTION OR PROCEEDING AGAINST ANY ORIGINATOR OR ITS PROPERTY IN THE COURTS OF ANY OTHER JURISDICTIONS.

  • EACH OF THE PARTIES REPRESENT TO EACH OTHER PARTY HERETO THAT IT HAS DISCUSSED THIS AGREEMENT AND, SPECIFICALLY, THE PROVISIONS OF SECTION 10.7 AND THIS SECTION 10.13, WITH ITS COUNSEL.

Related to SECTION 107

  • Section 102 means Section 102 of the Ordinance and any regulations, rules, orders or procedures promulgated thereunder as now in effect or as hereafter amended.

  • Section 1110 means Section 1110 of the Bankruptcy Code.

  • Subsection means subsection of the section in which the term is used;

  • Article 55 BRRD means Article 55 of Directive 2014/59/EU establishing a framework for the recovery and resolution of credit institutions and investment firms.

  • Section 504 means Section 504 of the Rehabilitation Act of 1973.