Scheme Completion Date definition

Scheme Completion Date means the date set out in the Firm Scheme Delivery Timetable by which:
Sample 1Sample 2Sample 3
Scheme Completion Date means the date set out in the Firm Scheme Delivery Timetable by which the Site acquisition and Practical Completion of the Works (as applicable) must have been achieved; Firm Scheme Delivery Timetable means the timetable for the acquisition, development, repair, Rehabilitation and delivery of a Firm Scheme as agreed by Homes England through IMS;
Sample 1Sample 2Sample 3
Scheme Completion Date means the date on which the Scheme Supervisors confirm the completion of the Scheme in accordance with Clause 9.1 (Scheme Completion).
Sample 1Sample 2Sample 3

Examples of Scheme Completion Date in a sentence

  • In this connection, the SIC has also confirmed that the Scheme Completion Date Condition may be amended such that the Scheme Exemption Ruling will be conditional on the Trust Scheme being completed within 8 months of the Joint Announcement Date.

  • Firm Scheme having reached Practical Completion (or in respect of a Single Claim Scheme, having reached Completion) by the Capital Firm Scheme Completion Date, the Grant Recipient may apply to Homes England for the Practical Completion Tranche Grant (or in respect of a Single Claim Scheme the Total Grant Tranche) payable in respect of that Capital Firm Scheme to be paid to it (the PC Claim).

  • The Scheme Supervisors will notify LFSL of the Scheme Completion Date promptly.

  • To do that I will make my case on two fronts: first through a comparison of the internal features of the three mathematical cultures, and second through an analysis of the social conditions under which the those cultures came into being and died out.Let’s take the internal characteristics first, again based on the three examples I have already used.

  • It is important to me that I am held in high esteem by people I know 5.

  • From the Effective Time until the Scheme Completion Date, LFSL and the Scheme Supervisors shall provide Scheme Creditors with such assistance as is reasonably practicable in connection with the Scheme and LFSL will use its reasonable efforts to answer reasonable questions from Scheme Creditors relating to the Scheme process and that Scheme Creditor's Scheme Claims.

  • LFSL shall not be required to make any Additional LFSL Contributions if the Scheme Completion Date has occurred.

  • Any remaining amounts of the Purchase Price (including the residual completion payment (as described in the 2019 Announcement) of up to a maximum of A$100 million) will be paid by AIA Australia on the Scheme Completion Date or such other date as the parties may agree, in accordance with the Transfer Deed.

  • As part of the arrangement hereunder, subsequent to the Scheme Completion Date, but prior to the issuance / allotment of SMTM Shares to WSPL and the shareholders of WSPL in accordance with Article 9.1 above, SMTM’s issued and paid-up share capital will stand reduced by way of cancellation of SMTM Shares in the ratio of 125 SMTM Shares cancelled for every 225 SMTM Shares held by each shareholder of SMTM.

  • Based on the report and recommendation of the President (RRP), 4 the expected impact of the project was to improve the health status and quality of life of the population in line with the MDGs related to safe water supply and sanitation.


More Definitions of Scheme Completion Date

Scheme Completion Date means the date logged onto the Asset Management Performance System on which all Operations within each individual Scheme have been completed.
Sample 1Sample 2Sample 3
Scheme Completion Date means the date of completion of the Delivery Phase Activities;
Sample 1

Related to Scheme Completion Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Final Completion Date means the date on which Final Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Completion Deadline means the date by which the Arrangement is to be completed, which date shall be April 30, 2014 or such later date as may be agreed to in writing by the Parties;

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Construction Start Date means the later to occur of the date on which Seller delivers to Buyer (a) a copy of the Notice to Proceed that Seller has delivered to the EPC Contractor for the Project, and (b) a written Certification substantially in the form attached hereto as Appendix IV-1.