RFSU definition

RFSU means that, with respect to each Subproject, all of the following have occurred: (i) Contractor has completed all applicable Work in accordance with the requirements contained in this Agreement to ensure that the applicable Subproject is ready for use to receive Natural Gas; and (ii) Contractor has delivered to Owner a RFSU Completion Certificate for such Subproject in the form of Attachment L as required under Section 11.1A.
Sample 1Sample 2Sample 3
RFSU means that Contractor has completed all applicable Work in accordance with the requirements contained in this Agreement to ensure that Subproject 3 is ready to receive Commissioning Feed Gas in those quantities requested by Contractor pursuant to Section 11.1B to begin commissioning of the gas treatment portions of LNG Units 12 and 13.
Sample 1Sample 2Sample 3
RFSU means that all of the following have occurred: (i) Contractor has completed all applicable Work in accordance with the requirements contained in this Agreement to ensure that the Project 5 is ready for use to receive Feed Gas for liquefaction; and (ii) Contractor has delivered to Owner a RFSU Completion Certificate in the form of Attachment 12 as required under Section 11.2A.
Sample 1

Examples of RFSU in a sentence

  • Owner shall notify Contractor whether it accepts or rejects the RFSU Completion Certificate within seventy-two (72) hours following Owner’s receipt thereof.

  • Acceptance of RFSU (which such acceptance shall not be unreasonably withheld) shall be evidenced by Owner’s signature on such RFSU Completion Certificate.

  • Contractor has caused this RFSU Completion Certificate to be duly executed and delivered as of the date first written above.

  • Pursuant to Section 4.4 of the Agreement, Contractor shall prepare and provide to Owner a detailed Project Commissioning Plan one hundred eighty (180) Days prior to RFSU.

  • If Owner does not agree that RFSU has occurred, then Owner shall state the basis for its rejection in reasonable detail in such notice.

  • For operations and maintenance personnel, training must be completed six (6) months prior to RFSU of a New Plant System.

  • Trainees must have completed classroom and vendor training, and be ready for field assignment six (6) months prior to RFSU of a New Plant System.

  • Owner’s acceptance of RFSU shall not relieve Contractor of any of its obligations to perform the Work in accordance with the requirements of this Agreement.

  • Description of how personnel will respond to an oil spill Prior to RFSU This is not a permit, but rather an operating plan that must be updated prior to operating the Liquefaction Facility.

  • Abortion Services Availability and Readiness Assessment (Analytical Report), HERA XXI, RFSU, Institute of Social Studies and Analysis, 2015, p.


More Definitions of RFSU

RFSU means, with respect to each Train, that all of the following have occurred: (i) Contractor has achieved and maintained Ready for Feed Gas Introduction for such Train; (ii) systems are commissioned and ready to start producing LNG all as set forth in greater detail in Attachment A and Attachment M; (iii) Contractor has provided required documents for FERC approval; and (iv) Contractor has delivered to Owner an RFSU Certificate for such Train in the form of Schedule L-2 and Owner has accepted such certificate by signing such certificate.
Sample 1
RFSU means the point in the performance of the Work when: (a) all of the Work and conditions set forth in Exhibit A have been satisfied and remain satisfied, except for the RFSU Punch-List, and Contractor has executed and provided to Company’s Representative a certificate in the form of Annexure 4-4 certifying RFSU has occurred; (b) Contractor has (i) obtained all Permits that it is required under this Agreement to obtain before RFSU and provided such Permits to the Company’s Representative; (ii) given to the Company’s Representative all documents or other information in respect of the design, construction, testing, commissioning, completion, occupation, use and maintenance of the Facility which are required by this Agreement to be given to the Company’s Representative before RFSU; (iii) removed all of Contractor’s Equipment from the Site, other than any of Contractor’s Equipment (A) necessary to perform the Work to be performed by Contractor between RFSU and Substantial Completion and the Punch-List Items or (B) retained on the Site with the approval of Company’s Representative, as applicable; (c) the Facility is compliant with, and capable of performing all functions that it must perform between RFSU and Substantial Completion (including pre-commissioning, commissioning, start-up and Guarantee Tests) safely and in accordance with the requirements of this Agreement; (d) power block first fire has been achieved; (e) all Work, components and equipment are ready for safe operation; (f) Contractor has successfully completed all RFSU Tests; (g) final procedures for the Guarantee Test have been submitted by Contractor in accordance with the terms of the Agreement; (h) Contractor and Company have identified and agreed upon the RFSU Punch-List and the value attributable to each such Punch-List Item; and (i) Contractor has furnished to Company the following lien waivers: (i) Final Conditional Lien Waivers from all first tier Subcontractors as well as from all Major Subcontractors of any sub-tier performing Work directly or indirectly for an on-Site first tier Major Subcontractor who have completed all work contemplated by the applicable Subcontracts (other than warranty work), but who have not yet received final payment thereunder; (ii) Final Unconditional Lien Waivers from all first tier Subcontractors as well as from all Major Subcontractors of any sub-tier performing Work directly or indirectly for an on-Site first tier Major Subcontractor who have completed all wor...
Sample 1

Related to RFSU

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Final Acceptance means final written acceptance of all the Work by the Commissioner, a copy of which shall be sent to the Contractor.

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Conditional Acceptance means a conditional acceptance by the Liquidity Provider of an extension of the Scheduled Termination Date.

  • XXXX Acceptance Form means the “Acceptance Form for End User License Agreement (for SAP On Premise indirect sales)” which will be provided by SAP on a deal by deal basis.

  • Final Acceptance Date means the date on which Final Acceptance occurs.

  • Operational Acceptance means the acceptance by the Procuring Entity of the Facilities (or any part of the Facilities where the Contract provides for acceptance of the Facilities in parts), which certifies the Contractor's fulfillment of the Contract in respect of Functional Guarantees of the Facilities (or the relevant part thereof) in accordance with the provisions of GCC Clause 28 (Functional Guarantees) hereof and shall include deemed acceptance in accordance with GCC Clause 25 (Commissioning and Operational Acceptance) hereof.

  • Operational Acceptance Tests means the tests specified in the Technical Requirements and Agreed Project Plan to be carried out to ascertain whether the System, or a specified Sub system, is able to attain the functional and performance requirements specified in the Technical Requirements and Agreed Project Plan, in accordance with the provisions of GCC Clause 27.2 (Operational Acceptance Test).

  • Acceptance Test is a test of the Features executed by the Customer to prepare the acceptance.

  • Milestone means an event or task described in the Implementation Plan which, if applicable, must be completed by the relevant Milestone Date;

  • Final completion and acceptance means the stage in the progress of the work as determined by the Contracting Officer and confirmed in writing to the Contractor, at which all work required under the contract has been completed in a satisfactory manner, subject to the discovery of defects after final completion, and except for items specifically excluded in the notice of final acceptance.

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • Performance Milestone means an act or event specified in section 5.1 and described in section 9 of the EPLA.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Design Criteria Package means concise, performance-oriented drawings or specifications for a public construction project. The purpose of the Design Criteria Package is to furnish sufficient information to permit Design-Build Firms to prepare a bid or a response to the District’s Request for Proposals, or to permit the District to enter into a negotiated Design- Build Contract. The Design Criteria Package must specify performance- based criteria for the public construction project, including the legal description of the site, survey information concerning the site, interior space requirements, material quality standards, schematic layouts and conceptual design criteria of the project, cost or budget estimates, design and construction schedules, site development requirements, provisions for utilities, stormwater retention and disposal, and parking requirements applicable to the project. Design Criteria Packages shall require firms to submit information regarding the qualifications, availability, and past work of the firms, including the partners and members thereof.

  • Development Milestone Event has the meaning set forth in Section 7.1.

  • Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.

  • proof of B-BBEE status level of contributor means:B-BBEE Status level certificate issued by an authorized body or person;A sworn affidavit as prescribed by the B-BBEE Codes of Good Practice;Any other requirement prescribed in terms of the B-BBEE Act;

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Milestone Schedule means Seller’s milestone schedule, the form of which is attached to this Agreement as Exhibit Q.

  • Final Completion Date means the date on which Final Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • DOA means the department of administration.

  • Work ethic camp means an alternative incarceration program