Reasonable Circumstances definition

Reasonable Circumstances shall have the same meaning ascribed to it in Clause 7.1;
Sample 1Sample 2Sample 3
Reasonable Circumstances shall have the same meaning ascribed to it in Clause 7.1; “Residential Block Common Areas” shall mean the areas, facilities and amenities specified in Schedule 12 which are to be used and enjoyed in common with all the Apartment Acquirers and includes Block-B-Tower Residential Common Portions;
Sample 1
Reasonable Circumstances shall have the same meaning ascribed to it in Clause 6.1; “Complex Common Areas” shall mean the areas, facilities and amenities specified in Schedule 12 which are to be used and enjoyed in common with all the PurchaserPurchasers;
Sample 1

Examples of Reasonable Circumstances in a sentence

  • The Allottee/Transferee agrees and confirms that, in the event it becomes impossible for the Promoter/Transferor to implement the project due to Force Majeure conditions and/or Reasonable Circumstances, then this allotment shall stand terminated and the Promoter/Transferor shall refund without interest to the Allottee/Transferee the entire amount received by the Promoter/Transferor from the allotment within 45 (forty five) days from that date.

  • If, however, the completion of the Project is delayed due to the Force Majeure conditions and/or due to Reasonable Circumstances then the Allottee/Transferee agrees that the Promoter/Transferor shall be entitled to the extension of time for delivery of possession of the Bungalow, provided that such Force Majeure conditions and/or the Reasonable Circumstances are not of a nature which make it impossible for the contract to be implemented.

  • If, however, the completion of the Project is delayed due to the Force Majeure conditions and/or due to Reasonable Circumstances then the Allottee/Transferee agrees that the Promoter/Transferor shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions and/or the Reasonable Circumstances are not of a nature which make it impossible for the contract to be implemented.

  • This rule is not intended to be absolute; a financially interested individual may rebut the presumption by demonstrating facts that, in the opinion of the COIC Committee, constitute Compelling and/or Reasonable Circumstances.

  • This rule is not intended to be absolute; the presumption may be rebutted by demonstrating facts that, in the opinion of the COIC Committee, constitute Compelling and/or Reasonable Circumstances.

  • The COIC Committee may determine the specific Reasonable Circumstances.

  • In these instances the rebuttable presumption continues to apply; however, the COIC Committee need only apply a Reasonable Circumstances standard in determining whether the activity may ensue.

  • The Allottee agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions and/or Reasonable Circumstances, then this allotment shall stand terminated and the Promoter shall refund without interest to the Allottee the entire amount received by the Promoter from the allotment within 45 (forty five) days from that date.

  • If, however, the completion of the Project is delayed due to the Force Majeure conditions and/or due to Reasonable Circumstances then the Allottee agrees that the Promoter shall be entitled to the extension of time for delivery of possession of the Apartment, provided that such Force Majeure conditions and/or the Reasonable Circumstances are not of a nature which make it impossible for the contract to be implemented.

  • The Purchaser agrees and confirms that, in the event it becomes impossible for the Promoter to implement the project due to Force Majeure conditions and/or Reasonable Circumstances, then this allotment shall stand terminated and the Promoter shall refund without interest to the Purchaser the entire amount received by the Promoter from the allotment within 45 (forty five) days from that date.

Related to Reasonable Circumstances

  • Reasonable in the circumstances means using no more force than is needed.

  • Exigent Circumstances means circumstances where collection or disclosure is urgently necessary, such that procedures that would otherwise be required cannot be followed.

  • Unforeseen Circumstances means changes in circumstances affecting a Covered Species or the Covered Lands that could not reasonably have been anticipated by the Parties at the time of the HCP’s negotiation and development, and that result in a substantial and adverse change in the status of the Covered Species.

  • Aggravated circumstances means circumstances in which a parent:

  • Special Circumstances means either or both of the following:

  • Exigent Circumstance means a Covered Person either has a Condition that may seriously jeopardize his or her life, health, or ability to regain maximum function or is undergoing a current course of treatment using a non-Formulary medication. The request for an expedited review should include the following support:

  • Exceptional Circumstances means disclosure:

  • reasonable possibility means that there is a cause and effect relationship between the investigational product, study device and/or study procedure and the AE.

  • Extraordinary Circumstances means floods, snow, ice storms, tornadoes, earthquakes, or other

  • Extenuating Circumstances means the inability to perform at an optimum level arising from one or more of the reasons set out in clause 6.1.

  • Reasonable grounds means that a reasonable person in your position would also suspect the information indicates misconduct or a breach of the law.

  • Special Circumstance means an event where, in the opinion of the Bank acting reasonably and in good faith, an amendment or a change is made to a taxation act or regulation, to taxation practices, policies or administration, to the interpretation of a taxation act or regulation or taxation practice, policy or administration; or an event occurs, now or in future, caused by circumstances beyond the control of the Bank making it illegal or disadvantageous, from a legislative or regulatory point-of-view, or disadvantageous, from a financial point- of-view, for the Bank to allow the Deposits of such series to remain outstanding. As provided hereunder, certain other extraordinary events affecting the underlying interest may be deemed to constitute a Special Circumstance and entitle the Bank to proceed with a Reimbursement Under Special Circumstances.

  • Uncontrollable Circumstance means any event which:

  • Reasonable suspicion means a basis for forming a belief based on specific facts and rational inferences drawn from those facts.

  • Reasonable pupil means a pupil, including, but not limited to, an exceptional needs pupil, who exercises average care, skill, and judgment in conduct for a person of his or her age, or for a person of his or her age with his or her exceptional needs.

  • Reasonable Steps means those steps the Receiving Party takes to protect its own similar proprietary and confidential information, which must not be less than a reasonable standard of care.

  • Reasonable access for the purposes of this section means:

  • Circumstance means an incident, fact, occurrence, matter, act or omission that may give rise to a Claim in the context of civil liability;

  • Reimbursement Under Special Circumstances means a special reimbursement of the Deposits, prior to the Maturity Date, in the circumstances and the manner described under “Extraordinary Events and Special Circumstances – Reimbursement Under Special Circumstances and Payment”.

  • Reasonable Commercial Efforts means, with respect to the applicable obligation of the Company, reasonable commercial efforts for similarly situated, publicly-traded companies.

  • Change in Circumstance means any significant change to you, including but not limited to:

  • reasonable measures means appropriate measures which are commensurate with the money laundering or terrorism financing risks;

  • Reasonable Costs means the reasonable actual costs and expenses incurred by us in carrying out any further Audit under this Contract, including, but not limited to, reasonable travel and subsistence costs;

  • Reasonable person means a reasonable person under similar circumstances and with similar identities to the victim.

  • Reasonable and Customary means, in relation to a charge for Medical Service, such level which does not exceed the general range of charges being charged by the relevant service providers in the locality where the charge is incurred for similar treatment, services or supplies to individuals with similar conditions, e.g. of the same sex and similar Age, for a similar Disability, as reasonably determined by the Company in utmost good faith. The Reasonable and Customary charges shall not in any event exceed the actual charges incurred.

  • Reasonable Care means the use of reasonable custodial practices under the applicable circumstances as measured by the custodial practices then prevailing in Russia of International Financial Institutions acting as custodians for their institutional investor clients in Russia.