Punch List Completion Date definition

Punch List Completion Date means the date upon which all previously incomplete or unsatisfactory items, as identified by CM, Project Architect and/or Owner are completed in a competent and workmanlike manner, consistent with standards for renovation of this type and with good building practices in the State of Florida.
Sample 1Sample 2Sample 3
Punch List Completion Date means, with respect to a Property, the date of Final Completion.
Sample 1

Examples of Punch List Completion Date in a sentence

  • The CM shall prepare a punch list of items to be completed and a schedule for their completion including completion dates for review and approval by the Owner and AE ("Punch List Completion Date").

  • In the event that the Project Substantial Completion Date occurs prior to expiration of the construction phase period as set forth in the Project Schedule, the entire remaining balance due under the terms of this Subparagraph (2) shall be due and payable on the Punch List Completion Date.

Related to Punch List Completion Date

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;