Project Substantial Completion Date definition

Project Substantial Completion Date means, in respect of any Project, the Project Substantial Completion Date indicated on the Declaration of Project Substantial Completion.
Sample 1Sample 2Sample 3
Project Substantial Completion Date of the Project shall be [______], 20[__].
Sample 1Sample 2Sample 3
Project Substantial Completion Date has the meaning set forth in Section 12.8.
Sample 1Sample 2Sample 3

Examples of Project Substantial Completion Date in a sentence

  • After Seller’s compliance with Section 10.2, the Parties shall execute a Change Order to (a) adjust the Critical Path Project Schedule (other than the Guaranteed Project Substantial Completion Date), to account for material delays to the Critical Path Project Schedule resulting from the Excusable Event and/or (b) adjust the Contract Price to account for the material increase in the cost of the performance of the Work resulting from the Excusable Event.

  • Seller agrees that if Project Substantial Completion is not achieved by the Guaranteed Project Substantial Completion Date, then Seller shall pay the Daily Delay Liquidated Damages to Purchaser for each Day that Seller fails to achieve Project Substantial Completion after the Guaranteed Project Substantial Completion Date until Project Substantial Completion is achieved (the “Delay Liquidated Damages”).

  • Except as set forth in Section 6.2, Section 9.2 or Section 3.4 of this Agreement or unless otherwise expressly provided by the terms of this Agreement, there shall be no increase in the Contract Price or extension in the Guaranteed Project Substantial Completion Date except as agreed in writing by the Parties or otherwise expressly provided by this Agreement.

  • If, as a result of any inspection, examination, or testing in accordance with this Agreement, Purchaser identifies any defective Work not in compliance with the requirements of this Agreement, and regardless of whether payment has been made therefor, then Purchaser may reject such portion of the Work prior to the Project Substantial Completion Date by prompt Notice to Seller.

  • The proposed recovery schedule will, at a minimum, demonstrate the means by which Seller intends to recapture lost time, meet Critical Milestones and achieve Project Substantial Completion by the Guaranteed Project Substantial Completion Date.

  • After achieving Project Substantial Completion, Seller may, at its option and sole cost and expense, continue to attempt to achieve the Minimum Guaranteed Plant Reliability until the date that is ninety (90) Days after the Guaranteed Project Substantial Completion Date (such period, the “Reliability Test Cure Period”).

  • The warranty set forth in Section 13.1 above shall commence on the Project Substantial Completion Date and apply for a period equal to [two (2) years] after the Project Substantial Completion Date, as such period may be extended as provided below, (the “Warranty Period”).

  • Prior to the Project Substantial Completion Date, Purchaser shall, at its own cost and expense, establish a NAR account in Purchaser’s name and take all such other actions that are necessary to receive and transfer the Environmental Attributes from the Project.

  • After achieving Project Substantial Completion, Seller may, at its option and sole cost and expense, continue to attempt to achieve the Minimum Guaranteed Plant Capacity until the date that is ninety (90) Days after the Guaranteed Project Substantial Completion Date (such period, the “Capacity Test Cure Period”).

  • Without altering, revising or otherwise changing the Guaranteed Project Substantial Completion Date, Seller shall, on a monthly basis submit an updated Critical Path Project Schedule to Purchaser and the Independent Engineer.


More Definitions of Project Substantial Completion Date

Project Substantial Completion Date means the date on which the Project achieves Project Substantial Completion, per Section 6.3.2.
Sample 1Sample 2Sample 3
Project Substantial Completion Date means the date on which Substantial Completion (as defined in the BOT Agreement) is achieved under the BOT Agreement.
Sample 1Sample 2Sample 3
Project Substantial Completion Date means the date established by the GMP Amendment as the date upon which the Construction Manager shall achieve Project Substantial Completion.
Sample 1Sample 2
Project Substantial Completion Date has the meaning given such term in the TEPC.
Sample 1Sample 2
Project Substantial Completion Date means the date that all WTGs have been Commissioned and all such WTGs are in commercial operation, as such date is notified to Contractor by Owner.
Sample 1
Project Substantial Completion Date shall have the meaning ascribed to such term in Section 7.5.2 of the Supply Agreement. [***] Confidential portions of this document have been redacted and filed separately with the Commission. "Proprietary Data" shall have the meaning ascribed to such term in Section 19.1(b) of the Supply Agreement and Section 10.15(b) of the Service Agreement, as applicable.
Sample 1

Related to Project Substantial Completion Date

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion Date means the date on which Final Completion occurs.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Subproject means a specific project to be carried out by an existing BE utilizing the proceeds of a Sub-loan or Investment, as hereinafter defined, fulfilling the conditions set forth in Part A of Schedule 4 to this Agreement;

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.