Partial Condemnation means any Condemnation which does not constitute a Termination Event.
Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent of the then replacement cost of the Building.
Condemnation Event means any act of taking by a public or quasi-public authority through condemnation, reverse condemnation or eminent domain.
Net Casualty Proceeds means, with respect to any Casualty Event, the amount of any insurance proceeds or condemnation awards received by the Borrower or any of its U.S. Subsidiaries in connection with such Casualty Event (net of all collection or similar expenses related thereto), but excluding any proceeds or awards required to be paid to a creditor (other than the Lenders) which holds a first priority Lien permitted by clause (d) of Section 7.2.3 on the property which is the subject of such Casualty Event.
Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.
Insurance and Condemnation Event means the receipt by any Credit Party or any of its Subsidiaries of any cash insurance proceeds or condemnation award payable by reason of theft, loss, physical destruction or damage, taking or similar event with respect to any of their respective Property.
Loss Occurrence means the sum of all individual losses directly occasioned by any one disaster, accident or loss or series of disasters, accidents or losses arising out of one event which occurs within the area of one state of the United States or province of Canada and states or provinces contiguous thereto and to one another. However, the duration and extent of any one "loss occurrence" shall be limited to all individual losses sustained by the Company occurring during any period of 168 consecutive hours arising out of and directly occasioned by the same event, except that the term "loss occurrence" shall be further defined as follows:
Major Casualty means, in relation to a Ship, any casualty to that Ship in respect of which the claim or the aggregate of the claims against all insurers, before adjustment for any relevant franchise or deductible, exceeds $500,000 or the equivalent in any other currency;
Casualty Loss means, with respect to any item of Equipment, the loss, theft, damage beyond repair or governmental condemnation or seizure of such item of Equipment.
Material Casualty has the meaning set forth in Section 14.1.1.
Landlord Default shall have the meaning given such term in Article 14.
Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.
Insured Casualty has the meaning set forth in Section 5.1(x)(iv)(B).
Untenantable means that Tenant shall be unable to occupy and shall not be occupying the Premises or the applicable portion thereof for the conduct of business ordinarily conducted in the Premises as a result of the Casualty.
Partial Taking means the taking of only a portion of the Premises which does not constitute a Total Taking; (4) "Date of Taking" means the date upon which the title to the Premises, or a portion thereof, passes to and vests in the condemnor or the effective date of any order for possession if issued prior to the date title vests in the condemnor; and (5) "Award" means the amount of any award made, consideration paid, or damages ordered as a result of a Taking.
Building, structure, facility, or installation means all of the pollutant-emitting activities which belong to the same industrial grouping, are located on one or more contiguous or adjacent properties, and are under the control of the same person (or persons under common control) except the activities of any vessel. Pollutant-emitting activities shall be considered as part of the same industrial grouping if they belong to the same major group (i.e., which have the same two-digit code) as described in the Standard Industrial Classification Manual, 1972, as amended by the 1977 Supplement (U.S. Government Printing Office stock numbers 4101-0066 and 003-005-00176-0, respectively).
Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.
Partial Loss means any Physical Damage loss which is not a Total Loss.
Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:
Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.
Casualty Amount means Five hundred thousand Dollars ($500,000) (or the equivalent in any other currency);
Substantial Completion Date means the date on which Substantial Completion occurs.
Casualty shall have the meaning set forth in Section 6.2 hereof.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Casualty Proceeds means, with respect to any Casualty Event, the amount of any insurance proceeds or condemnation awards received by the Borrower, any Parent Guarantor or any of their respective Subsidiaries in connection therewith, but excluding any proceeds or awards required to be paid to a creditor (other than the Lenders) which holds a first-priority Lien permitted by Section 7.2.3 on the property which is the subject of such Casualty Event.
Premises Total Destruction means damage or destruction to the Premises, other than Lessee Owned Alterations and Utility Installations and Trade Fixtures, which cannot reasonably be repaired in six (6) months or less from the date of the damage or destruction. Lessor shall notify Lessee in writing within thirty (30) days from the date of the damage or destruction as to whether or not the damage is Partial or Total.