Milestone Completion Certificate definition

Milestone Completion Certificate means the applicable certificate in the form attached hereto as Schedule 9.
Sample 1Sample 2Sample 3
Milestone Completion Certificate means as set-forth in Clause 12.2
Sample 1
Milestone Completion Certificate means a certificate, substantially in the form of Exhibit NMilestone Completion Certificates, as applicable setting forth the Milestone to which the Milestone Completion Certificate relates, and setting forth in reasonable detail the basis on which Seller believes that such Milestone has been achieved, and including any supporting materials, documents and calculations, and the results of all testing, in each case to the extent reasonably necessary to support that such Milestone has been achieved and which shall include a punch list for such Milestone (and in the case of Substantial Completion, the Punch List).
Sample 1Sample 2

Examples of Milestone Completion Certificate in a sentence

  • Dxxxxx Xxxxxxxx Construction and Operations Project Manager [REDACTED: Email address] SCHEDULE 9 SCHEDULE OF MILESTONES (AND MILESTONE COMPLETION CERTIFICATE) [REDACTED: Confidential and commercially sensitive information] MILESTONE COMPLETION CERTIFICATE This Milestone Completion Certificate (the “Certificate”) is provided in accordance with the Contract by and between ___________________ (“Owner”) and SolarBank Corporation (“Contractor”) dated ___________________, 2023 (the “Agreement”).


More Definitions of Milestone Completion Certificate

Milestone Completion Certificate means a certificate setting forth the Milestone to which the Milestone Completion Certificate relates, and setting forth in reasonable detail the basis on which Seller believes that Milestone Completion for such Milestone has been achieved, and including any supporting materials, documents and calculations, and the results of all testing, in each case to the extent reasonably necessary to support that Milestone Completion for such Milestone has been achieved, notwithstanding that any Defects or Deficiencies may later be discovered and shall be corrected as permitted by this Agreement.
Sample 1
Milestone Completion Certificate means a certificate, substantially in the form of Error! Reference source not found., as applicable setting forth the Milestone to which the Milestone Completion Certificate relates, and setting forth in reasonable detail the basis on which Seller believes that such Milestone has been achieved, and including any supporting materials, documents and calculations, and the results of all testing, in each case to the extent reasonably necessary to support that such Milestone has been achieved and which shall include a punch list for such Milestone (and in the case of Substantial Completion, the Punch List).
Sample 1
Milestone Completion Certificate means a Construction Milestone Completion Certificate, a Critical Milestone Completion Certificate, Mobilisation Milestone Completion Certificate and/or Tram Milestone Completion Certificate;
Sample 1

Related to Milestone Completion Certificate

  • Final Completion Certificate has the meaning set forth in Section 11.6.

  • Completion Certificate means the certificate to be issued by the Engineer-In- Charge when the work/s has been completed to his satisfaction as per terms of the contract.

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Project Milestone means the project milestone set forth in Schedule-J;

  • Milestone 2 means achievement of annual Net Sales of at least $35,000,000 during any Calendar Year ending on or before December 31, 2024.

  • Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Project Milestones means the project milestones set forth in Schedule-G;

  • Milestone Date means the date set against the relevant Milestone in the Implementation Plan;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • Completion Notice means a notice issued by the Developer in accordance with clause 6.1.

  • Development Milestone Event has the meaning set forth in Section 7.2.1.

  • Milestone 1 means achievement of annual Net Sales of at least $20,000,000 during the Calendar Year ending on December 31, 2021.

  • Final Completion Date means the date on which Final Completion occurs.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity