Governmental Delay definition

Governmental Delay has the meaning assigned to such term in Section 5.14(b).
Sample 1Sample 2Sample 3
Governmental Delay means any delay suffered by a Party in the performance of its obligations under this Agreement caused by the relevant agencies of the Government failing to grant timely approval of the environmental impact assessment or any other permits or approvals required in order for such Party to perform its obligations under this Agreement. Hydrocarbons has the same meaning set forth in Article 1.28 of the License.
Sample 1Sample 2
Governmental Delay means any delay that is caused by the failure to obtain (i) a grading permit for the Land Sitework by September 4, 2009, or (ii) a building permit for the Shell Building by September 18, 2009, in each case from the applicable governmental entity; provided, however, that in order for any such delay to be considered a Governmental Delay, (a) Landlord shall be required to give written notice to Tenant not later than September 18, 2009 (in the case of delay in obtaining the grading permit), or October 2, 2009 (in the case of delay in obtaining the building permit), and (b) Landlord must be pursuing the applicable permit with reasonable diligence, and using commercially reasonable efforts to cause such Governmental Delay to cease.
Sample 1

Examples of Governmental Delay in a sentence

  • Further, Contractor has included in the analysis of the time required for this Project, items set forth in General Conditions Article 8.3.2.1, Submittal Schedules, Rain Day Float, and Governmental Delay Float.

  • Specifically, major categories of Work under the DSA 152 (Project Inspection Card) should be allocated Governmental Delay Float at the Contractor’s discretion.

  • If the Contract Time is 182 days, then the Contract Time shall require six (6) days of Governmental Float) This Governmental Delay float must be incorporated into the schedule and should be incorporated in each critical activity as Contractor deems fit.

  • It is the Contractor’s responsibility to timely schedule and pay (if applicable) for Special Inspections as to not delay the Project, and any failure or resulting delay is not considered Governmental Delay Float under Article 9.2.1.

  • Governmental Delay Float on the Project may exceed 12 days per one (1) year period, but Contractor is required to include not be less than 12 days of Governmental Delay Float during each one (1) year period.

  • Any unutilized Governmental Delay may be reallocated back to Project Float as deemed appropriate solely by the District, without any additional compensation to the Contractor.

  • Days shall be set aside in the approved construction schedule as Governmental Delay to be utilized on critical path delays as further described in the Supplemental Conditions.

  • However, the use of Float does not extend to Governmental Delay, which shall only be used as indicated above.

  • Governmental Delay may include, in the District’s sole and absolute discretion, delays associated with other governmental agencies that have jurisdiction over the Project, District or campus “black-out” days, testing days, or other non-contractor related delays as deemed necessary by the District.

  • Failure to plan and pay (if applicable) for quicker delivery of Special Inspections may be counted as Float, but is not considered Governmental Delay under Article 9.2.1.


More Definitions of Governmental Delay

Governmental Delay means the failure of any Governmental Authority to timely perform a function that it is required to perform or customarily performs on a routine basis due to no fault or failure of the party claiming the Governmental Delay. The determination of whether a Governmental Authority has failed to timely perform a routinely-performed function as aforesaid, shall be determined by the Landlord in its sole but reasonable discretion, based on a comparison of the amount of time taken by the applicable Governmental Authority to actually perform the function at issue, with the average amount of time then being taken by such Governmental Authority to perform such routinely-performed function under substantially identical circumstances and conditions.
Sample 1
Governmental Delay means any delay suffered by Syntroleum in the performance of its obligations under this Agreement caused by the relevant agencies of the Government failing to grant timely approval of the environmental impact assessment or any permits required in order for Syntroleum to perform its obligations under this Agreement.
Sample 1
Governmental Delay means any delay that is caused by the failure to obtain (i) approval of revisions to the existing grading permit necessary for the Land Sitework by December 22, 2009, or (ii) a building permit for the building described in the December Plans by January 8, 2010, in each case from the applicable governmental entity; provided, however, that in order for any such delay to be considered a Governmental Delay, (a) Landlord shall be required to give written notice to Tenant not later than January 4, 2010 (in the case of delay in obtaining the grading permit), or January 22, 2010 (in the case of delay in obtaining the building permit), and (b) Landlord must be pursuing the applicable permit with reasonable diligence, and using commercially reasonable efforts to cause such Governmental Delay to cease.
Sample 1
Governmental Delay means a delay in performance by the Developer directly caused 365 by either: (i) with respect to any matter that requires the approval of the City specifically under 366 this Agreement, where the Developer has provided the City sufficient information to respond to 367 such request for approval, the City fails to specify in reasonable detail the reason for the City’s 368 disapproval or rejection of such matter and the changes that would be required for approval, (ii) 369 with respect to any matter that requires the review or consent of any Governmental Authority, 370 where the Developer has provided such Governmental Authority sufficient information to 371 respond to such request for approval, delays caused by such Governmental Authority not 372 completing its review within the customary response period for the matter in question, imposing 373 conditions that are not customary for the matter in question or that would constitute a change to 374 the Construction Work Plans or the Construction Schedule, or acting outside of such 375 Government Authority’s powers contained in Applicable Law; provided that the Developer must 376 provide notice to the City of such Governmental Delay event within seven (7) days of discovery 377 of such Governmental Delay event, which notice shall include the Developer’s estimate of the 378 length of the delay that will be caused by such event and the actions the Developer is taking to 379 minimize such delay. 380 381 “Gross Revenues” means, for any calendar year or part thereof, the sum of: (a) the 382 aggregate gross revenues in respect of such calendar year or part thereof deriving from Parking 383 Fees and any other revenues related to the Project, (b) any insurance proceeds received by the 384 Developer to the extent that such proceeds are in respect of lost gross revenues, and (c) any all 385 other amounts deposited during such calendar year or part thereof in the Gross Revenues 386 Account, which amounts are not otherwise included in the calculation of aggregate gross 387 revenues under clause (a) above, such as interest earnings, income, and Fees in respect of the 388 Project; provided, however, that Gross Revenues specifically excludes any taxes collected by the 389 Developer from Persons parking within the Parking System that are required to be remitted to a 390 Governmental Authority under Applicable Law.
Sample 1
Governmental Delay means a delay in performance by the Developer directly caused 487 by either: (i) with respect to any matter that requires the approval of the Smithsonian specifically 488 under this Agreement, where the Developer has provided the Smithsonian sufficient information 489 to respond to such request for approval, the Smithsonian fails to specify in reasonable detail the 490 reason for the Smithsonian’s disapproval or rejection of such matter and the changes that would 491 be required for approval and (ii) with respect to any matter that requires the review or consent of 492 any Governmental Authority, where the Developer has provided such Governmental Authority 493 sufficient information to respond to such request for approval, delays caused by such 494 Governmental Authority not completing its review within the customary response period for the 495 matter in question, imposing conditions that are not customary for the matter in question or that 496 would constitute a material change to the Construction Works Plans or the Construction Schedule, 497 or acting outside of such Government Authority’s powers contained in Applicable Law; provided 498 that the Developer must provide notice to the Smithsonian of such Governmental Delay event 499 within seven (7) days of discovery of such Governmental Delay event, which notice shall include 500 the Developer’s estimate of the length of the delay that will be caused by such event and the actions 501 the Developer is taking to minimize such delay. 502
Sample 1
Governmental Delay means a delay in performance by Developer directly caused by one or more of the following:
Sample 1

Related to Governmental Delay

  • Governmental subdivision means any city, county, or combination thereof.

  • Governmental Actions means any and all consents, approvals, permits, orders, authorizations, waivers, exceptions, variances, exemptions or licenses of, or registrations, declarations or filings with, any Governmental Authority required under any Governmental Rules.

  • Governmental Action means all authorizations, consents, approvals, waivers, exceptions, variances, orders, licenses, exemptions, publications, filings, notices to and declarations of or with any Governmental Authority (other than requirements the failure to comply with which will not affect the validity or enforceability of any Loan Document or have a material adverse effect on the transactions contemplated by any Loan Document or any material rights, power or remedy of any Person thereunder or any other action in respect of any Governmental Authority).

  • Governmental Charges has the meaning set forth in Section 9.2.

  • Governmental Bar Date means the date established pursuant to the Bar Date Order by which Proofs of Claim of Governmental Units must be Filed.

  • Governmental Requirement means any law, statute, code, ordinance, order, determination, rule, regulation, judgment, decree, injunction, franchise, permit, certificate, license, rules of common law, authorization or other directive or requirement, whether now or hereinafter in effect, of any Governmental Authority.

  • Governmental Authority(ies) means any federal, state or local government, and political subdivision(s) thereof, and any entity(ies) exercising executive, legislative, judicial, regulatory or administrative functions having or pertaining to government.

  • Governmental Consents has the meaning set forth in Section 3.5.

  • Governmental Acts means any act or omission, whether rightful or wrongful, of any present or future de jure or de facto government or Governmental Authority.

  • Governmental means any federal, state or local court or governmental or regulatory agency or authority or any arbitration board, tribunal or mediator having jurisdiction over the Company or its assets or Members.

  • Governmental Body means any: (a) nation, state, commonwealth, province, territory, county, municipality, district or other jurisdiction of any nature; (b) federal, state, local, municipal, foreign or other government; or (c) governmental or quasi-governmental authority of any nature (including any governmental division, department, agency, commission, instrumentality, official, organization, unit, body or Entity and any court or other tribunal).

  • Governmental Authority means the government of the United States or any other nation, or of any political subdivision thereof, whether state or local, and any agency, authority, instrumentality, regulatory body, court, central bank or other entity exercising executive, legislative, judicial, taxing, regulatory or administrative powers or functions of or pertaining to government (including any supra-national bodies such as the European Union or the European Central Bank).

  • Governmental unit means a governmental unit as defined in section 101(27) of the Bankruptcy Code.

  • Governmental Filings means all filings, including franchise and similar tax filings, and the payment of all fees, assessments, interests and penalties associated with such filings with all Governmental Authorities.

  • Governmental Requirements means all judgments, orders, writs, injunctions, decrees, awards, laws, ordinances, statutes, regulations, rules, franchises, permits, certificates, licenses, authorizations and the like and any other requirements of any government or any commission, board, court, agency, instrumentality or political subdivision thereof.

  • Governmental Consent means any notice to, registration, declaration or filing with, exemption or review by, or authorization, order, consent or approval of, any Governmental Entity, or the expiration or termination of any statutory waiting periods;

  • Governmental Rules means any and all laws, statutes, codes, rules, regulations, ordinances, orders, writs, decrees and injunctions, of any Governmental Authority and any and all legally binding conditions, standards, prohibitions, requirements and judgments of any Governmental Authority.

  • Governmental Approvals means all authorizations, consents, approvals, licenses and exemptions of, registrations and filings with, and reports to, all Governmental Authorities.

  • Applicable Governmental Authority means the FERC within the United States and the appropriate governmental authority with subject matter jurisdiction over reliability in Canada and Mexico.

  • Relevant Governmental Body means the Board of Governors of the Federal Reserve System or the Federal Reserve Bank of New York, or a committee officially endorsed or convened by the Board of Governors of the Federal Reserve System or the Federal Reserve Bank of New York, or any successor thereto.

  • Governmental Entity means any nation or government, any state, province or other political subdivision thereof, any entity exercising executive, legislative, judicial, regulatory or administrative functions of or pertaining to government, including any court, arbitrator (public or private) or other body or administrative, regulatory or quasi-judicial authority, agency, department, board, commission or instrumentality of any federal, state, local or foreign jurisdiction.

  • Governmental contract means a contract awarded by a govern- mental entity for general construction, an improvement, a service, or a public works project or for a purchase of supplies, materials, or equipment. The term includes a contract to obtain professional ser- vices subject to Government Code 2254. Gov’t Code 2252.151(3)

  • Government costs, as used in this clause, means those agency costs that result directly from developing and implementing the VECP, such as any net increases in the cost of testing, operations, maintenance, and logistics support. The term does not include the normal administrative costs of processing the VECP or any increase in this contract's cost or price resulting from negative instant contract savings.

  • Governmental Authorization means any authorization, approval, consent, franchise, license, covenant, order, ruling, permit, certification, exemption, notice, declaration or similar right, undertaking or other action of, to or by, or any filing, qualification or registration with, any Governmental Authority.

  • Required Governmental Approvals With respect to each Facility, all licenses, permits, accreditations, authorizations and certifications from any Governmental Authority which are material to or required for (i) the operation of such Facility and any Capital Addition thereto for its Primary Intended Use in accordance with all applicable, material Legal Requirements, including, without limitation, material state facility licenses, certificates of need, permits, provider agreements and accreditations or certifications from Medicare and/or Medicaid, and (ii) for any other use conducted on the Leased Property of such Facility and any Capital Additions thereto as may be permitted from time to time hereunder in accordance with all applicable, material Legal Requirements.

  • Governmental Rule means any law, rule, regulation, ordinance, order, code interpretation, treaty, judgment, decree, directive, guidelines, policy or similar form of decision of any Governmental Authority.