Early Occupancy Date definition

Early Occupancy Date. (if any) is defined in Item 7(c) of the Basic Lease Information.
Sample 1Sample 2
Early Occupancy Date means that date that is the later to occur of October 1, 2005, and five (5) days after the date that the TI Work is substantially completed pursuant to the Work Letter.
Sample 1
Early Occupancy Date means (and shall occur on) the date Landlord notifies Tenant in writing that Landlord has advanced the Commencement Date Conditions sufficiently to allow Tenant to engage in the installation and testing of Equipment and other Tenant’s Personal Property in the Datacenter Space and makes the Datacenter Space available to Tenant for such purposes.
Sample 1

Examples of Early Occupancy Date in a sentence

  • Evidence of that insurance must be delivered to Landlord prior to the Early Occupancy Date.

  • Estimated Early Occupancy Date: Sixteen (16) weeks from and after the date of this Lease.

  • From and after the Early Occupancy Date, Tenant shall pay to Landlord, as additional rent, Tenant's Share of all Operating Expenses, as defined in Section 4.2(f), incurred by Landlord in the operation of the Building and the Project.

  • Kermit Terlinden requested approval to authorize Emergency Management to distribute sand bags and sand to the public Wright/Nies motion carried unanimously to direct Emergency Management Director to order 10,000 sand bags for the county to have on hand and develop a policy on sand bag distribution.

  • Tenant shall be permitted, subject to the terms and conditions of this Section 3.2 herein provided, to occupy the Premises for its business operations for that period (the "Early Occupancy Period") equal to ninety (90) days following the date (the "Early Occupancy Date") that the tenant improvements constructed by Landlord pursuant to the attached Work Letter (the "Tenant Improvements") are substantially completed but for minor punch list matters, and the Premises, as so improved, are tendered to Tenant.

  • The Premises shall be expanded to include the Must-Take Space on the date (the “Must-Take Space Commencement Date”) that is the earlier of (A) the date upon which Tenant first commences to conduct business in the Must-Take Space, and (B) the date that is ninety (90) days after the Must-Take Space Early Occupancy Date (as defined below).

  • Tenant will be granted three (3) months of Basic Rent Free Early Occupancy beginning the earlier of April 1,2004 or upon substantial completion of the Expansion Space Improvements ("Early Occupancy Date").

  • Check if this owner has EVER had any of the following adverse legal actions imposed by the State of New Jersey or by any other state or federal agency or program.

  • Lessor shall permit Lessee to occupy the Premises on the Early Occupancy Date at Lessee's risk in order to perform Lessee's Work (defined in the Work Letter) attached hereto as Exhibit B and incorporated by reference herein) and, to the extent permitted under applicable laws, to deliver inventory to the Premises.

  • The court granted M.B.’s application and entered an order on April 16, 2018, certifying the March 16, 2018 order as permissibly appealable.8 M.B. filed an emergency application to stay the March 16, 2018 order pending appeal on April 23, 2018.


More Definitions of Early Occupancy Date

Early Occupancy Date will mean the date 30 days prior to the date of Substantial Completion as such date of Substantial Completion is projected by Landlord in good faith. On the Early Occupancy Date, the construction of the Building and the Leasehold Improvements relating to the Additional Premises will be completed to a degree which will allow the installation of Tenant's Lines (as defined in Section 4.5 hereof) without any undue delay or material adverse cost to Tenant; provided, however, that the Work in the Building and the Additional Premises may continue as of such date and such completion will not be deemed Substantial Completion (as defined in Section 1.33 hereof). Prior to the installation of Tenant's Lines, Landlord, Tenant and their respective representatives, will walk through the Building and the Additional Premises to determine the condition of space within the Building and the Additional Premises as of such date. Tenant will be responsible for all costs of repair of damage to the Building and the Additional Premises caused by Tenant, its employees, agents or contractors during the period between the Early Occupancy Date and the Term Commencement Date or the Effective Date (as defined in Section 1.1 of the Lease), as the case may be.
Sample 1
Early Occupancy Date means the date on which Landlord delivers early access of the Premises to Tenant. 1.12 "Expiration Date" shall have the meaning set forth in Section 4. 1.13 "HV AC" shall have the meaning set forth in Section 9.2. 1.14 "BY AC Maintenance Contract" shall have the meaning set forth in Section 92. 1.15 ''HV AC System" shall have the meaning set forth in Section 9.2. 1.16 "Insurance Costs" shall mean the cost of fire, extended coverage, boiler, sprinkler, apparatus, general comprehensive liability, property damage, rent, earthquake and other insurance as Landlord carries with respect to the Property, including the amounts of any deductible payment for such insurance incurred by Landlord in connection with any claim thereunder 1.17 "Landlord's Address": c/o Seagis Property Group LP 100 Xxxxx Xxxxxx, Xxxxx 000 Xxxx Xxxxxxxxxxxx, Xxxxxxxxxxxx 00000 Attn: Cxxxxxx X. Xxx 1.18 "Landlord Repair Work" shall have the meaning set forth in Section 9.4. 1.19 "Landlord's Work" shall mean those improvements described on Exhibit G and to be performed by Landlord at Landlord's sole cost and expense and not included in Operating Expenses. 1.20 "Lease Interest Rate" shall mean 300 basis points in excess of the Prime Rate in effect from time to time. 1.21 "Operating Expenses" shall have the meaning set forth in Section 6.1. 1.22 "Permitted Use" shall mean only use for warehousing, distribution, ancillary office and administrative uses, and any lawful use ancillary thereto, but subject in all events to Section 7. 1.23 "Premises" shall mean the approximately 24,110 square foot area contained in the Building as depicted on the Site Plan. -2-
Sample 1
Early Occupancy Date means the date upon which the Tenant Improvements in the Office Premises are Substantially Complete in accordance with the Work Letter Agreement. The period between the Early Occupancy Date and the Commencement Date shall be referred to herein as the “Early Occupancy Period.” During the Early Occupancy Period, Tenant shall have no obligation to pay Basic Rent, Operating Expenses or Real Property Taxes, but Tenant shall be obligated to pay for all utilities provided to the Office Premises during the Early Occupancy Period in accordance with Article 19 above. All other terms and provisions of this Lease shall apply to the Office Premises both during the Early Occupancy Period and thereafter.
Sample 1
Early Occupancy Date will mean the date indicated on the Construction Schedule, as updated from time to time with notice to, and the consent of Tenant, on which construction of the Facility will be completed to a degree which will allow the installation of Tenant's FF&E (as defined in Section 4.5 hereof) conveniently to Tenant's role in Operation Qualification, Operation/Performance Completion and Performance Qualificationand without any undue delay or material adverse cost to Tenant; provided, however, that the Work may continue as of such date and such completion will not be deemed Substantial Completion. Prior to the installation of Tenant's FF&E, Landlord, Tenant and their respective representatives, will walk through the Facility to determine the condition of space within the Facility as of such date.
Sample 1
Early Occupancy Date has the meaning given in Section 28.D.;
Sample 1
Early Occupancy Date means the date that is the later of (i) the date Landlord achieves substantial completion of Landlord’s Work in accordance with the terms and provisions of Exhibit “D” or (ii) the date which is ninety (90) days after the date of Tender of the Premises. The Commencement Date (the “Commencement Date”) means the date that is six months after the Early Occupancy Date. Tenant agrees to accept Tender of the Premises (as defined in Exhibit “D”) when Landlord tenders possession thereof to Tenant in accordance therewith. By acceptance of the Tender of the Premises, Tenant shall be deemed to have accepted the Premises in their condition as of the date of Tender of the Premises subject only to any remaining Landlord’s Work. At anytime after the completion of Tenant’s Work, Tenant agrees to execute and deliver to Landlord, within ten days after Landlord has requested same, a letter confirming (1) the Commencement Date, (2) that Tenant has accepted the Premises, and (3) that Landlord has performed all of the Landlord’s Work with respect to the Premises (except for punch-list items specified in such letter). Temporary Space: At anytime between the Effective Date and the date which is ninety (90) days after the date of Tender of the Premises, upon thirty (30) days prior written request by Tenant to Landlord, Landlord will provide Tenant with approximately 3,407 rentable square feet of temporary space in Building I of the Project (the “Temporary Space”); provided, however, that if Tenant gives Landlord notice of the need for the Temporary Space after July 1, 2006 then Landlord is only required to provide 2,445 rentable square feet of Temporary Space unless Landlord has additional unoccupied and uncommitted space available as of the date of such notice. The location of the Temporary Space in Building I will be designated by Landlord in Landlord’s sole discretion. Tenant will accept the Temporary Space in its “AS IS” and “WITH ALL FAULTS” condition and WITHOUT ANY REPRESENTATION OR WARRANTY, WHETHER EXPRESSED OR IMPLIED except as expressly stated in this Lease. Tenant’s occupancy of the Temporary Space will be on all of the terms and conditions of this Lease except that (i) the term of Tenant’s occupancy of the Temporary Space will expire on first to occur of the date of occupancy of the Premises by Tenant, the Commencement Date or the date Tenant notifies Landlord in writing of the date Tenant no longer requires the Temporary Space and vacates the Temporary Space on or bef...
Sample 1

Related to Early Occupancy Date

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.

  • Prior Occupancy means Owner’s use of all or parts of the Project before Substantial Completion, as more fully set forth in Section 6.08 A.

  • Single Room Occupancy or “SRO” means housing consisting of single room dwelling units that is the primary residence of its occupant or occupants. An SRO does not include facilities for students.

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Commencement Date means the date fourteen (14) days after the date the Contract comes into effect or any other date named in the Contract Data.

  • Owner-occupied means property that is the principal

  • Lease Commencement Date has the meaning specified in Section 3.2 of the Master Lease.

  • On-premises sign means a sign advertising activities conducted or maintained on the property on which it is located. The boundary of the property shall be as determined by tax rolls, deed registrations, and apparent land use delineations. If a sign consists principally of brand name or trade name advertising and the product or service advertised is only incidental to the principal activity conducted or maintained on the property, or if the sign brings rental income to the property owner or sign owner, it shall be considered the business of outdoor advertising and not an on-premises sign. On-premises sign does not include a sign on a narrow strip of land contiguous to the advertised activity, or a sign on an easement on adjacent property, when the purpose is clearly to circumvent the intent of this act.

  • bicycle parking space – occupant means an area that is equipped with a bicycle rack or locker for the purpose of parking and securing bicycles, and:

  • Transient occupancy means occupancy in transient lodging that has all of the following

  • Child-occupied facility means a building or portion of a building constructed prior to 1978, visited regularly by the same child, age six years or younger on at least two different days within any week (Sunday through Saturday period), provided that each day’s visit lasts at least three hours and the combined weekly visit lasts at least six hours, and the combined annual visits last at least 60 hours. Child-occupied facilities may include, but are not limited to, day-care centers, preschools and kindergarten classrooms.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Storage Space means a space where goods of non-hazardous nature are stored and includes cold storage and banking safe vaults;

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Premises Building Total Destruction means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is fifty percent (50%) or more of the then Replacement Cost of the Building.

  • Rent Commencement Date means [Insert date or description] or any later date calculated in accordance with paragraph 3.3 of Part 5 of the Schedule;

  • Occupancy Rate means, for any Property, the percentage of the net rentable area (determined on a square feet basis) of such Property leased by bona fide tenants of such Property (excluding tenants that have vacated the Property on a permanent basis and have not sublet same to a bona fide subtenant) pursuant to bona fide tenant leases (or subleases), in each case, which tenants (or subtenants) are not more than sixty days past due in the payment of all rent payments due under such leases (or subleases).

  • Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Lease Term means the term of this Lease which shall commence on the Commencement Date and continue for the period specified in Section J of the Summary.

  • Commercial Premises Means a place of trade or premises operated for financial gain, including but not limited to, a retirement village or a block of flats that has a common facility; a place of trade where the manufacture and production of products or produce takes place; a site where renovation, restoration and refurbishment work as described in Appendix B takes place.

  • Loan Commencement Date means, with respect to each Loan, the first Business Day of the calendar month following the Funding Date of such Loan.

  • Base Term Commencing (i) with respect to the Original Premises on the Commencement Date, and (ii) with respect to the Expansion Premises on the Expansion Premises Commencement Date, and ending with respect to the entire Premises on September 15, 2016 (“Expiration Date”).”

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.