Contractor Claim definition

Contractor Claim means any amount validly claimed in accordance with the Construction Contracts for goods or services provided under or pursuant to the Construction Contracts.
View Source
Contractor Claim. A separate demand by a Contractor sent by registered mail or certified mail, with return receipt requested, for one or more of the following: (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District; (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Construction Contract and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled; (C) payment of an amount that is disputed by the District. A Contractor Claim does not include, and the procedures for processing of Contractor Claims do not apply to the following: (i) Penalties or forfeitures prescribed by statute or regulation imposed by a governmental agency other than penalties for delay assessed by the District pursuant to Section 1.1.18(B); (ii) ▇▇▇▇ claims for personal injury or death; (iii) False claims liability under California Government Code Section 12650, et seq.; (iv) Defects in the Work first discovered by District after final payment by District to Contractor; (v) Stop notices; (vi) The right of District to specific performance or injunctive relief to compel performance of any provision of the Contract Documents or for other District claims against the Contractor.
View Source
Contractor Claim. A separate demand by a Contractor sent by registered mail or certified mail, with return receipt requested, for one or more of the following: (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District; (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Construction Contract and payment for which is not otherwise expressly provided or to which the claimant is not otherwise entitled;
View Source

Examples of Contractor Claim in a sentence

  • Contractor shall submit a written Contractor Claim in accordance with Section 4.2 of the General Conditions.

  • The Contractor’s written statement prepared in accordance with Section 14.3 (Submission of Contractor Claim) of the Construction Contract required as a condition of its initiating the Contract Dispute Resolution Process.

  • On the Effective Date, in full satisfaction of each Allowed Mineral Contractor Claim, to the extent not already satisfied pursuant to a prior order of the Bankruptcy Court, each holder of an Allowed Mineral Contractor Claim shall receive Cash in an amount equal to such Claim on the later of: (a) the Effective Date; or (b) the date due in the ordinary course of business in accordance with the terms and conditions of the particular transaction giving rise to such Allowed Mineral Contractor Claim.

  • Exit Facility As defined in the Term Sheet General Unsecured Claims Any Claim other than an Administrative Claim, a Professional Claim, a Secured Tax Claim, an Other Secured Claim, a Priority Tax Claim, an Other Priority Claim, a Mineral Contractor Claim, a Lender Claim, or a DIP Facility Claim.

  • The A/E shall review each Contractor Claim, prepare a written analysis of its content, and submit the written analysis to the Project Manager no more than 30 days after receiving the Contractor’s substantiated and certified Claim.

  • However, if the Contractor is the party initiating the Contractor Claim, the Contractor shall be responsible for contributing up to an amount equal to the filing fee that would be paid to initiate the claim in the court of general jurisdiction in the state in which the Contractor provides Services, unless a lower fee amount would be owed by the Contractor pursuant to the AAA Rules, applicable law, or Subsection 11(e)(1) above.

  • As soon as reasonably possible after receipt by a Contractor Indemnitee of any Contractor Claim or notice of the commencement of any action, administrative or legal proceeding, or investigation in connection with an actual or potential Contractor Claim as to which any indemnity provided for in Section 13.2.1 may apply, the Contractor Indemnitee will notify Owner in writing of such fact.

  • A Contractor Claim Dispute is the Contractor‘s dispute of a payment, denial or recoupment of the payment of a claim, or imposition of a sanction, by ADHS.

  • Upon receipt of notice of any Contractor Claim covered by this provision, the Defendant shall promptly notify the applicable Class Member in writing.

  • No settlement of any such Contractor Claim shall be made without the prior written consent of both the Defendant and the applicable Class Member, which consent shall not be unreasonably withheld, conditioned, or delayed.


More Definitions of Contractor Claim

Contractor Claim means an Administrative Contractor Claim, Priority Contractor Claim, Secured Contractor Claim, or Unsecured Contractor Claim.
View Source