Contract Substantial Completion Date definition

Contract Substantial Completion Date means the date set forth on Exhibit B attached hereto for Substantial Completion of the Work, as such date may be adjusted pursuant to the terms of the Contract Documents.
Sample 1Sample 2Sample 3
Contract Substantial Completion Date shall have the meaning set forth in the Contractor’s Statement.
Sample 1Sample 2

Examples of Contract Substantial Completion Date in a sentence

  • The Commission reserves the right to request a proposal from the Contractor to accelerate or compress the schedule in lieu of granting a Time Extension request in order to maintain the Contract Substantial Completion Date or original project duration (Acceleration Proposal).

  • Design-Build Contract Substantial Completion Date was revised from the original date of 7/31/2013 to 9/9/2013.

  • The Commission reserves the right to request a proposal from the Design-Builder to accelerate or compress the schedule in lieu of granting a Time Extension request in order to maintain the Contract Substantial Completion Date or original project duration (Acceleration Proposal).

  • The parties agree that the Owner will be substantially damaged in amounts that will be difficult or impossible to determine if Substantial Completion or Final Acceptance is not achieved by the Contractor on or before the Contract Substantial Completion Date and/or Contract Final Acceptance Date set forth herein.

  • Contractor shall be entitled to a compens- able time extension for an Unavoidable Delay caused by a Change Order initiated or caused by the City, provided such Unavoidable Delay is critical, extends the most current Contract Substantial Completion Date, and is not concurrent with a Contractor-caused delay or other type of Unavoidable Delay as previous- ly defined.

  • Time extensions will be granted only if a Change Order Proposal affects the activities on the Critical Path of the Owner approved Project Schedule (i.e., when the work impacts the "Contract Substantial Completion Date").

  • If the Contract Substantial Completion Date, Contract Completion Date and the Contract Expiration Date are not defined in the Agreement, Bidder shall provide time periods as allowed on the Bid Form.

  • If Contrac- tor fails to notify Walmart Construction Department of status, ITBA will be scheduled into store during week following Contract Substantial Completion Date.

  • Construction Manager at Risk Drahota Commercial, LLC Fort Collins, COGuaranteed Maximum Price $3,693,215 Contract Substantial Completion Date May 1, 2009 (In Thousands)TotalAdminConstrDesignFF&EMiscContingencyBudget$4,945$135$3,710$468$189$90$353Expended$4,893$117$3,710$434$189$90$353Obligated$64$18$12$34000Un-obligated($12)0($12)0000 Remarks All work is complete with the exception of some modifications to the Audio Visual equipment.

  • Energy Innovation Center Construction Manager at Risk G E Johnson Construction CompanyJackson, WYGuaranteed Maximum Price $18,926,514 Contract Substantial Completion Date June 4, 2012 Extended June 7, 2013 (In Thousands)TotalAdminConstrDesignTechFF&EMiscCntngcyBudget25,40068619,3481,8551,0701,007507927Expended28,66360622,7051,8551,070993507927Obligated00000000Other Funding3,35703,35700000Un-obligated94800001400 Remarks Warranty review was done in November.

Related to Contract Substantial Completion Date

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Final Completion Date means the date on which Final Completion occurs.

  • Guaranteed Substantial Completion Date or “Guaranteed Substantial Completion Dates” has the meaning set forth in Section 5.3B.

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Substantial Completion Certificate means the certificate issued and approved by the Authority indicating the date upon which the Trade Contractor Work (or a designated portion thereof) is Substantially Complete.

  • Certificate of Substantial Completion means the certificate executed by the A/E, ODR and Contractor that documents to the best of A/E’s and ODR’s knowledge and understanding, Contractor’s sufficient completion of the work in accordance with the Contract, so as to be operational and fit for the use intended.

  • Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Substantial compliance means a level of compliance with these rules where any deficiencies pose no greater risk to resident health or safety than the potential for causing minor harm.

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Subproject means a development activity proposed by a Beneficiary under Part A.2 (d) of the Project and financed or to be financed through a Subproject Grant (as hereinafter defined) made out of the proceeds of the Development Credit;

  • Improvement completion assurance means a surety bond, letter of credit,

  • Contract Start Date means the date specified in your Contract for Signature asthe date this Contract starts;

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.