Construction Plans and Specifications definition

Construction Plans and Specifications mean the detailed architectural drawings and specifications that are prepared for all aspects of the Project in accordance with the approved Design Development Plans and that are used to obtain Permits, detailed cost estimates, to solicit and receive construction bids, and to direct the actual construction of the Improvements.
Sample 1Sample 2Sample 3
Construction Plans and Specifications means the detailed plans submitted to the Agency in order to obtain all necessary permits for the Project, including but not limited to:
Sample 1
Construction Plans and Specifications mean the Concept Plans, the Schematic Drawings, the Design Development Plans and the Construction Drawings, individually or collectively, as the context shall appear, which shall be delivered by Developer to District, and approved by District, to the extent required by, and in accordance with the standards set forth in, Article IV of this Agreement. As used in this Agreement, the term “Construction Plans and Specifications” shall include any changes to such Construction Plans and Specifications that are made in accordance with the terms of this Agreement.
Sample 1

Examples of Construction Plans and Specifications in a sentence

  • Contractor agrees to do the work in a first class, substantial and workmanlike manner to the satisfaction of County in strict accordance with the provisions of the Contract Documents, including the Construction Plans and Specifications.

  • The Project Administrator is, in the first instance, the judge of the performance of the Contract as it relates to compliance with the Construction Plans and Specifications, quality of workmanship and material.

  • Drafting, Review, and Approval of Construction Plans and Specifications.

  • The design of Architectural, Structural, Mechanical, Electrical, Civil or other engineering features of the work shall be accomplished or reviewed and approved by Registered Professional Architects or Engineers licensed to practice in the State of Florida, and the appropriate seal and signature shall be properly displayed on the Construction Plans and Specifications.

  • Payment shall constitute full compensation for all material, labor, equipment and Work incidental thereto, necessary to complete this item in accordance with the Construction Plans and Specifications.

  • The Project Administrator is, in the first instance, the judge of the performance of the Contract as it relates to compliance with the Construction Plans and Specifications and quality of workmanship and material.

  • The Director of Covenants will make the final determination that the Construction Plans and Specifications are consistent with the DRC’s Preliminary Concept and Design Proposal approvals.

  • A separate document or report entitled "Engineering Design Summary" may be required as directed by the City Engineer, and included with the submittal of the Construction Plans and Specifications.

  • Final Construction Plans and Specifications Review (REQUIRED)The Final Construction Plans and Specifications review shall be a true extension of the plans and proposals presented and approved in Step 2 and Step 3.

  • Village staff shall review the resubmitted Construction Plans and Specifications for conformity to the requirements of applicable Village regulations, consistency with the Comprehensive Plan, suitability for development, generally accepted good engineering design practice, and other applicable requirements.


More Definitions of Construction Plans and Specifications

Construction Plans and Specifications means the detailed plans submitted to the Agency in order to obtain all necessary permits for the Project, including but not limited to: • Site plans showing all structures upon the Property together with all connections to existing or proposed utilities, roads, sidewalks and alleys; • Landscaping plan; • Elevations of the buildings depicting the site lines and the specific configuration and relationship of design elements of the building exteriors, which describe the aesthetic and technical aspects, including materials, of the building exteriors; • Detailed engineering and architectural plans for the Project showing the utility, access and structural support components, with all proposed connections to existing and proposed utilities and services and the landscape plan based on current code requirements; • A calculation of gross building areas, the number of residential units by unit type, the amount of commercial space, the floor-to-area ratio of the Project, and the number of parking spaces; • An exterior finish schedule; • Location and dimensions for exterior signage and graphics; • Exterior lighting plan; and • Location and treatment of servicing requirements, trash collection, loading docks and related functional areas.
Sample 1
Construction Plans and Specifications means, with respect to a Component or Physical Element, all plans and specifications required to complete the Component or Physical Element, as the case may be, pursuant to the terms of this Agreement as approved by PDC, to the extent required by this Agreement, and the appropriate governmental agencies.
Sample 1
Construction Plans and Specifications mean the detailed architectural drawings and specifications that are prepared for all aspects of the Project in accordance with the approved “Declaration” is that certain Declaration of Covenants in the form attached hereto as
Sample 1
Construction Plans and Specifications means the detailed plans submitted to the Agency in order to obtain all necessary permits for the Project, including but not limited to:• Site plans showing all structures upon the Property together with all connections to existing or proposed utilities, roads, sidewalks and alleys;• Landscaping plan;• Elevations of the buildings depicting the site lines and the specific configuration and relationship of design elements of the building exteriors, which describe the aesthetic and technical aspects, including materials, of the building exteriors;• Detailed engineering and architectural plans for the Project showing the utility, access and structural support components, with all proposed connections to existing and proposed utilities and services and the landscape plan based on current code requirements;• A calculation of gross building areas, the number of residential units by unit type, the amount of commercial space, the floor-to-area ratio of the Project, and the number of parking spaces;• An exterior finish schedule;• Location and dimensions for exterior signage and graphics;• Exterior lighting plan; and• Location and treatment of servicing requirements, trash collection, loading docks and related functional areas.
Sample 1
Construction Plans and Specifications means any and all construction plans, drawings, designs, specifications, manuals and diagrams depicting or describing all or any part of the Owned Real Property, the Improvements, and the machinery and equipment located therein and thereon.
Sample 1
Construction Plans and Specifications means the final plans and specifications for the Base Building Core & Shell.
Sample 1

Related to Construction Plans and Specifications

  • Plans and Specifications means the plans, drawings and specifications reasonably necessary to properly assess and review proposed Work prior to issuance of any approval that may be required under this Agreement;

  • Construction Plans means plans, drawings, specifications and related documents, and construction schedules for the construction of the Project, together with all supplements, amendments or corrections, submitted by the Developer and approved by the City in accordance with this Agreement.

  • Construction Plant means appliances, machinery with necessary supply to up keep and maintenance of the works or temporary works but dose not include materials or other things intended to form part of the permanent work.

  • Construction project means the same as that term is defined in Section 38-1a-102.

  • Construction Work means any work in connection with⎯

  • Construction Works means all works and things necessary to complete the Project in accordance with this Agreement;

  • Construction Budget means the cost of acquisition, installation, testing, constructing and developing any Property as determined by the Construction Agent in its reasonable, good faith judgment.

  • Construction Schedule means a construction schedule indicating the planned start and completion dates of the major activities of the Work as set out in Appendix [ ], a future Appendix;

  • Construction Contracts means the contracts between Lessee and Contractors for the furnishing of labor, services or materials to the Leased Premises in connection with the construction of the Improvements.

  • Project Improvements means site improvements and facilities that are:

  • Constructional Plant means all appliances or things whatever nature required in or about the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work or temporary housing, hutting, office, stores, etc.,

  • construction work permit means a document issued in terms of regulation 3; "contractor" means an employer who performs construction work;

  • construction site means a workplace where construction work is being performed;

  • Tenant Improvements Defined in Exhibit B, if any.

  • Standard Specifications means all applicable legal requirements pertaining to the development of the Property including, but not limited to, Master Subdivision Plan, applicable permits, and construction drawings required for all Infrastructure, including, without limitation, the Town's Unified Development Ordinance, Knightdale's Water Allocation Policy (Ordinance # 13-06- 19-001 and Ordinance # 00-00-00-000) and Standard Specifications and Construction Details Manual. The failure of this Agreement to describe any other permit, condition, or term of restriction applicable to the Property does not relieve Developer of the necessity of complying with the same.

  • Construction waste means solid waste which is produced or generated during construction, remodeling, or repair of pavements, houses, commercial buildings, and other structures. Construction wastes include, but are not limited to lumber, wire, sheetrock, broken brick, shingles, glass, pipes, concrete, paving materials, and metal and plastics if the metal or plastics are a part of the materials of construction or empty containers for such materials. Paints, coatings, solvents, asbestos, any liquid, compressed gases or semi-liquids and garbage are not construction wastes.

  • Construction Zone shall have the meaning set forth in Clause 8.3 (i);

  • Construction Completion Certificate means the certificate issued under ARTICLE 14.

  • Construction Contractor means a person who undertakes to or offers to undertake to, or purports to have the capacity to undertake to, or submits a bid to, or does himself or by or through others, construct, alter, repair, add to, subtract from, improve, move, wreck, or demolish any building, highway, road, railroad, excavation, or other structure, project, development, or improvement to real property, or to do any part thereof. "Construction contractor" includes subcontractors, specialty contractors, prime contractors, and any person receiving consideration for the general supervision and/or coordination of such a construction project except for remediation contracting. This definition shall govern without regard to whether or not the construction contractor is acting in fulfillment of a contract.

  • Constructional Plan means all appliances or things of whatsoever nature required for the execution, completion or maintenance of the works or temporary works (as hereinafter defined) but does not include materials or other things intended to form or forming part of the permanent work.

  • Construction sign means a sign which identifies the architect, engineers, contractors and other individuals or firms involved with the construction of a building, or announces the character of the building or enterprise, which is erected during the building construction period.

  • Construction Contract or “contract” means a written agreement between a contractor and a public agency for the construction, alteration, demolition, or repair of a facility, other than a contract having a dollar value of less than $30,000.00 or a contract that provides for 3 or fewer payments.

  • Erection, construction, remodeling, repairing means all types of work done on a particular building or work at the site thereof in the construction or development of the project, including without limitation, erecting, construction, remodeling, repairing, altering, painting, and decorating, the transporting of materials and supplies to or from the building or work done by the employees of the Contractor, Subcontractor, or Agent thereof, and the manufacturing or furnishing of

  • Construction Completion Date means date of the completion of the Construction Period, which shall be at the expiry of a period of 24 (Twenty Four) months from the Compliance Date or such other date (with the consent of the Authority) by which the overall development of the Project is completed in accordance with the provisions of this Concession Agreement and when the Construction Completion Certificate is issued by Authority as per Article 14.1.

  • Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.

  • Project Architect means the architect retained by Lessee to design and supervise construction of the Improvements.