CIDS/ODS definition

CIDS/ODS means the corridor intruder detection system and object detection system to be installed by the CIDS/ODS Contractor "Claim" includes any claim, demand, action, proceeding or suit of any kind whatsoever for an increase in the Contract Sum, for payment of money (including damages), for an extension of time to a Date for Construction Completion or a Date for Milestone Achievement or for any other form of relief:
View Source

Examples of CIDS/ODS in a sentence

  • If the Principal takes any such action it will be entitled to recover its reasonable costs and expenses from the CIDS/ODS Contractor as a debt due from the CIDS/ODS Contractor to the Principal.

  • Following completion of a request for tenders process, the Principal selected the CIDS/ODS Contractor as the successful tenderer for the delivery of the Works.

  • Without prejudice to the CIDS/ODS Contractor's obligations to execute a Collateral Warranty Deed Poll as a condition precedent to Construction Completion of the first Portion to achieve Construction Completion, the CIDS/ODS Contractor must, within 5 Business Days of receipt of a request from the Principal, give the Principal's Representative an executed Collateral Warranty Deed Poll.

  • Within 10 Business Days after a request by the CIDS/ODS Contractor for approval, the Principal's Representative will advise the CIDS/ODS Contractor whether the request is approved (and, if approved, any relevant conditions) or not and, where it is not approved, the reasons why approval is not given.

  • UGL Engineering Pty Limited (ABN 96 096 365 972), located at Level ▇, ▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇, North Sydney NSW 2060 (CIDS/ODS Contractor).

  • The CIDS/ODS Contractor's entitlement under this clause 3.4(b) will be its only right to payment arising out of or in any way in connection with an Authority order or direction, court or tribunal order or direction by the Principal or Principal's Representative in accordance with clause 3.4(a)(v), 3.4(a)(vi) or 3.4(a)(vii) (as applicable).