Weather Condition. The sea trial shall be carried out under such weather condition as the Builder in his reasonable judgment has deemed favourable. In the event of unfavourable weather on the date specified for the sea trial, the same shall take place on the first available day thereafter that the weather permits. It is agreed that if during the sea trial of the Vessel the weather should suddenly become unfavourable to continue the sea trial, the sea trial shall be discontinued and postponed until the first favourable day next following, unless the Buyer shall assent in writing to its acceptance of the Vessel on the basis of the sea trial made before such discontinuance has occurred. Any delay of the sea trial caused by such unfavourable weather condition shall operate to postpone the Expected Delivery Date by the period of delay involved and such delay shall be deemed to be a permissible delay in delivery of the Vessel.
Appears in 2 contracts
Sources: Ship Sales Contract (Safe Bulkers, Inc.), Ship Sales Contract (Safe Bulkers, Inc.)