Common use of Weather Condition Clause in Contracts

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable enough by the judgement of the BUILDER. In the event of unfavourable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSEL.

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable enough by the judgement of the BUILDER. In the event of unfavourable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSELXXXXXX.

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable favorable enough by the judgement judgment of the BUILDERBUILDER and/or the SELLERS. In the event of unfavourable unfavorable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable unfavorable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable favorable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable unfavorable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as a permissible delay in the delivery of the VESSEL.VESSEL．

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable enough by the reasonable judgement of the BUILDER. In the event of unfavourable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as a permissible delay in the delivery of the VESSEL.

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable favorable enough by the judgement of both the OWNER and the BUILDER. In the event of unfavourable unfavorable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable unfavorable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable favorable day next following, unless the BUYER OWNER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable unfavorable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSEL.

Weather Condition. The trial run shall be carried out under the weather condition condition, which is deemed favourable favorable enough by the judgement judgment of the BUILDERBUILDER in accordance with the Specifications. In the event of unfavourable unfavorable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable unfavorable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable favorable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable unfavorable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSEL.

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable enough by the judgement of the BUILDER. In the event of unfavourable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSEL, the weather should suddenly become so unfavourable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSEL.XXXXXX. 00

Weather Condition. The trial run shall be carried out under the weather condition which is deemed favourable favorable enough by the judgement of both the BUYER and the BUILDER. In the event of unfavourable unfavorable weather on the date specified for the trial run, the same shall take place on the first available day thereafter that the weather condition permits. It is agreed that, if during the trial run of the VESSELDRILLSHIP, the weather should suddenly become so unfavourable unfavorable that orderly conduct of the trial run can no longer be continued, the trial run shall be discontinued and postponed until the first favourable favorable day next following, unless the BUYER shall assent in writing to acceptance of the VESSEL DRILLSHIP on the basis of the trial run already made before such discontinuance has occurred. Any delay of trial run caused by such unfavourable unfavorable weather condition shall operate to postpone the Delivery Date by the period of the delay involved and such delay shall be deemed as permissible delay in the delivery of the VESSELDRILLSHIP.