Time Impact Analysis. 24 If Developer submits a Relief Request indicating that an event, situation, or change affects a 25 Critical Path of the Project Schedule as set forth in Section 14.1.3.1 of the Agreement, 26 Developer shall prepare a Time Impact Analysis showing the cumulative effect of the change on 27 the completion or fixed milestone date with the Relief Request. Developer shall include a written 28 report, in a form satisfactory to ADOT, describing the Time Impact Analysis with the Time 29 Impact Analysis. The revision to the Project Schedule associated with the time extension must 30 not modify the early- and late-start cost curves of the Project Schedule, except with respect to 31 activities that have been affected by the event that justify the extension. Developer may 32 reschedule activities not otherwise affected by the event to take advantage of additional Float 33 available as the result of the time extension. Developer shall reflect any such rescheduling in 34 the Project Schedule. Each Time Impact Analysis must include a fragnet demonstrating the 35 following information:
Time Impact Analysis. Within the relevant time periods set forth in Article 19, Contractor shall submit to Owner’s Contracting Officer, pursuant to the Section
Time Impact Analysis. As part of a Relief Request as set forth in Section 15.1.2 of the PPA Developer shall submit to IFA a written time impact analysis illustrating the influence of each claimed Relief Event. Each time impact analysis shall include a fragmentary network demonstrating how Developer proposes to incorporate the change, delay, or Developer request into the current Project Status Schedule. The time impact analysis shall demonstrate the time impact to each and every affected schedule Activity in the most recent Project Status Schedule at the time of the occurrence. The time impact analysis submittal shall include the details of the change, including added, changed or deleted data for schedule Activities and logic. If the current Project Status Schedule is revised subsequent to submittal of a time impact analysis but prior to its approval, Developer shall promptly indicate in writing to IFA the need for any modification to its time impact analysis. Developer shall submit one printed Xxxxx chart including all schedule Activities affected by the time impact analysis, grouped and sorted by WBS and compared to the current Project Baseline Schedule. In addition, Developer shall provide one electronic backup of the Project Schedule with the time impact analysis and a comprehensive narrative for each Relief Request. Developer shall incorporate the results of the Relief Event Determination from IFA into the Project Status Schedule for the next Progress Report.
Time Impact Analysis. B.4.4.1 When changes or delays are experienced because of a Change Order, Design Builder shall submit a written time impact analysis (“Time Impact Analysis”) to the City illustrating the influence of each change or delay in the Project Schedule.
Time Impact Analysis. All Parties shall agree to address any Section Schedule issues as quickly and as contemporaneously as possible per AACE International Recommended Practice No. 45R-08 “
Time Impact Analysis. As Applied to Construction when preparing a time impact analysis. The Contractor shall submit a time impact analysis and a Proposed Schedule within fourteen (14) days following a request by JEA. This required fourteen (14) day period may be extended as necessary subject to the approval of JEA. The Proposed Schedule shall be developed using duplicate electronic files of the Current Baseline Schedule and shall include all statuses to reflect current progress using information from agreed to Schedule Progress Updates, but shall not allocate costs to any proposed activities. Multiple delays will be analyzed chronologically in the order of occurrence. Costs may be allocated to activities only when the Change Order Proposal has been approved by JEA. Under no circumstances shall a time impact analysis based on Schedule Progress Update(s) be acceptable as a basis for an adjustment to a Completion Deadline. Proposed Schedules shall be used by the Contractor to: Request revisions to logic ties and activities in the Current Baseline Schedule, Propose changes in the Current Baseline Schedule required to implement schedule recovery plans, To negotiate the schedule impact of a Change Order Proposal with JEA, or To propose changes for any other reason in the Current Baseline Schedule. Proposed Schedules shall code affected and added activities to each Change Order Proposal or schedule recovery plan. Furthermore, Proposed Schedules shall accurately reflect all revisions and/or adjustments made to activities, logic ties and restraints that are necessary to reflect the Contractor’s current approach for Work remaining. At a minimum, Proposed Schedules shall: Incorporate all proposed activities and logic ties required to implement any proposed revisions, Detail all impacts on pre-existing activities and logic ties, Include a narrative describing the causes of any delay and actions planned to recover the schedule to meet Contract Deadlines. Each Proposed Schedule shall include a subnet demonstrating how the Contractor plans to incorporate a Change Order Proposal or other change and/or revision into the Current Baseline Schedule. A subnet is defined as a sequence of new or revised activities that are proposed to be added to the Current Baseline Schedule. If the Contractor does not submit a time impact analysis for a specific change order or delay within the specified period set forth above, or extended period as agreed to between Contractor and JEA, the Contractor shall be deem...
Time Impact Analysis. 21 If Developer receives a Request for Change Proposal, submits a Change Request or submits a Relief 22 Request asserting that an event, situation, or change affects a Critical Path of the Project Schedule as 23 set forth in Section 13.1.3.1 of the Agreement, Developer shall prepare and submit with the response to 24 the Request for Change Proposal, the Change Request or Relief Request a Time Impact Analysis 25 showing the cumulative effect of the change on the completion or fixed milestone date. Developer shall 26 also submit a Time Impact Analysis where otherwise provided in the Contract Documents. With each 27 Time Impact Analysis, Developer shall include a written report, in a form satisfactory to ADOT, describing 28 the Time Impact with the Time Impact Analysis. A revision to the Project Schedule associated with a time 29 extension shall not modify the early- and late-start cost curves of the Project Schedule, except with 30 respect to activities that have been affected by the event that justify the extension. Developer may 31 reschedule activities not otherwise affected by the event to take advantage of additional Float available 32 as the result of the time extension. Developer shall reflect any such rescheduling in the Project Schedule. 33 Each Time Impact Analysis shall include a fragnet demonstrating the following information:
Time Impact Analysis. A. This analysis will be performed by the Engineer (CM’s scheduler) based on schedule updates as accepted in monthly schedule meetings.
Time Impact Analysis. The Contractor shall notify the County or Construction Observer when an impact may justify an extension of Contract Time or adjustment of milestone dates. This notice shall be made in writing as soon as possible, but no later than the end of the next estimate period after the commencement of an impact or the notice for a change is given to the Contractor. Not providing notice to the County or Construction Observer by the end of the next estimate period will indicate the Contractor's approval of the time charges as shown on that time statement. Future consideration of that statement will not be permitted and the Contractor forfeits its right to subsequently request a time extension or time suspension unless the circumstances are such that the Contractor could not reasonably have knowledge of the impact by the end of the next estimate period. When changes are initiated or impacts are experienced, the Contractor shall submit to the County or Construction Observer a written time impact analysis describing the influence of each change or impact. A time impact analysis is an evaluation of the effects of changes in the construction sequence, contract, plans, or site conditions on the Contractor's plan for constructing the Project, as represented by the Project Schedule. The purpose of the time impact analysis is to determine if the overall Project has been delayed, and if necessary, to provide the Contractor and the County a basis for making adjustments to the time allotted for Substantial Completion and Final Completion. A time impact analysis shall consist of one or all of the steps listed below.
