ECR Number Environmental Commitment Record Requirements Description of ADOT Responsibilities TMP-3 The following measures will be implemented for the Selected Alternative: • All equipment exhaust systems will be in good working order. Properly designed engine enclosures and intake silencers will be used. • Equipment will be maintained on a regular basis. New equipment will be subject to new product emission standards. • Stationary equipment will be located as far away from sensitive receivers as possible. • Construction-related noise generators will be shielded from noise receivers (e.g., use temporary enclosures to shield generators or crushers, take advantage of site conditions to provide topographic separation). • Construction alerts will be distributed to keep the public informed of construction activities, and a toll-free number for construction-related complaints will be provided. • During the design phase, hours of operation will be evaluated to minimize disruptions during construction. ADOT to oversee for compliance TMP-4 Congestion from construction-related traffic will create temporary impacts in the project vicinity. The magnitude of these impacts will vary depending on the location of the sources of the fill material and of the disposition sites for surplus material, the land uses along the routes, the duration of hauling operations, staging locations, and the construction phasing. To identify acceptable routes and times of operation, ADOT, or its representative, will prepare an agreement with local agencies regarding hauling of construction materials on public streets. ADOT to oversee for compliance TP Attachment 000-0 Xxxxx Xxxxxxxx Xxxxxxx Project Record of Decision (ROD) Developer’s Environmental Commitment Requirements The following table includes the Project-specific environmental commitments as written in the ROD, with minor modifications for clarification purposes. As it relates to these Technical Provisions, references to freeway, project, South Mountain Freeway, proposed action, proposed freeway, and Selected Alternative mean the Project, and references to contractor mean Developer. Developer shall comply with and perform all of the contractor and ADOT requirements, including the ADOT obligations, commitments, and responsibilities, identified in the following table, except to the extent of those requirements that are specifically identified in the third column, entitled “Description of ADOT Responsibilities,” which are not delegated to Developer.
Non-Availability of Funds Every payment obligation of the State under this Charter is conditioned upon the availability of funds continuing to be appropriated or allocated for the payment of such obligations. If funds are not allocated and available for the continuance of this Charter, the Commission may terminate this Charter at the end of the period for which funds are available. No liability shall accrue to the Commission, nor the State, or any of its subdivisions, departments or divisions, in the event this provision is exercised, and neither the Commission nor the State shall be obligated or liable for any future payments or for any damages as a result of termination under this paragraph.
Limitations on Re-Disclosure The Provider shall not re-disclose Student Data to any other party or affiliate without the express written permission of the LEA or pursuant to court order, unless such disclosure is otherwise permitted under SOPPA, ISSRA, FERPA, and MHDDCA. Provider will not sell or rent Student Data. In the event another party, including law enforcement or a government entity, contacts the Provider with a request or subpoena for Student Data in the possession of the Provider, the Provider shall redirect the other party to seek the data directly from the LEA. In the event the Provider is compelled to produce Student Data to another party in compliance with a court order, Provider shall notify the LEA at least five (5) school days in advance of the court ordered disclosure and, upon request, provide the LEA with a copy of the court order requiring such disclosure.
Availability of PHI for Amendment Modernizing Medicine shall provide PHI in EMA to Medical Practice for amendment, and incorporate any such amendments in the PHI (for so long as Modernizing Medicine maintains such information in the Designated Record Set), in accordance with this Addendum and as required by 45 C.F.R. § 164.526. If Modernizing Medicine receives a request for amendment to PHI directly from an Individual, Modernizing Medicine shall forward such request to Medical Practice within ten (10) business days. Medical Practice shall have the sole responsibility for determining whether to approve an amendment to PHI and to make such amendment.
AVAILABILITY OF AGREEMENT The employer must ensure that copies of this Agreement and the NES are available to all employees to whom they apply, such as on a notice board which is conveniently located at or near the workplace or through electronic means, whichever makes them more accessible. PART 2 - ENGAGEMENT
Certain Agreements Related to Deposits Subject to Section 2.2, the Assuming Institution agrees to honor the terms and conditions of any written escrow or mortgage servicing agreement or other similar agreement relating to a Deposit liability assumed by the Assuming Institution pursuant to this Agreement.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion - Lower Tier Covered Transactions (a) The prospective lower tier participant certifies, by submission of this proposal, that neither it nor its principals is presently debarred, suspended, proposed for debarment, declared ineligible, or voluntarily excluded from participation in this transaction by any federal department or agency.
Termination or Suspension for Convenience of City City may suspend or terminate this Agreement, or any portion of the Required Services, at any time and for any reason, with or without cause, by giving specific written notice to Consultant of such termination or suspension at least fifteen (15) days prior to the effective date thereof. Upon receipt of such notice, Consultant shall immediately cease all work under the Agreement and promptly deliver all “Work Product” (defined in Section 7 below) to City. Such Work Product shall be City's sole and exclusive property as provided in Section 7 hereof. Consultant shall be entitled to receive just and equitable compensation for this Work Product in an amount equal to the amount due and payable under this Agreement for work satisfactorily performed as of the date of the termination/suspension notice plus any additional remaining Required Services requested or approved by City in advance that would maximize City’s value under the Agreement.
Certification Regarding Debarment, Suspension, Ineligibility and Voluntary Exclusion First Tier Participants:
CONDITIONS APPLICABLE PENDING TRANSFER As has already been referred to in this agreement, the common property will be owned and controlled by a body corporate for and on behalf of all owners including the purchaser. As the body corporate will only be established once the first transfer of a unit in the development has occurred, the Seller shall from the completion date and until the date of the establishment of the body corporate bear the rights and obligations of the body corporate. In this regard, during the period from the completion date until date of transfer, the following conditions shall apply:
