Epidemic Failure In the event that CONTRACTUAL PRODUCTS under warranty have the same or similar functional defect during a time period of three (3) months and the number of defected CONTRACTUAL PRODUCTS exceed [***] of the quantity delivered within this time period, this [***] = CERTAIN INFORMATION ON THIS PAGE HAS BEEN OMITTED AND FILED SEPARATELY WITH THE COMMISSION. CONFIDENTIAL TREATMENT HAS BEEN REQUESTED WITH RESPECT TO THE OMITTED PORTIONS. shall be an “Epidemic Failure” as mentioned in the following. The term “Epidemic Failure” shall exclusively apply to delivered CONTRACTUAL PRODUCTS with a number of pieces of more than ten thousand (>10.000) during three (3) months. If either CONTRACTUAL PARTY learns of the existence or likely existence of an Epidemic Failure, then such CONTRACTUAL PARTY will inform the other CONTRACTUAL PARTY as soon as possible. The CONTRACTUAL PARTIES shall then work together to jointly devise a containment action plan. As soon thereafter as reasonably possible, the CONTRACTUAL PARTIES will develop a corrective action plan to remedy the Epidemic Failure. Phoenix Contact shall use its best efforts to implement such remedy as quickly as possible at Phoenix Contact’s own expense, which efforts shall include receiving all shipments of affected Product back (freight collect), repairing or replacing all such affected Products in accordance with the agreed remedy devised by the Parties, shipping the repaired or replaced Products back to ENPHASE at Phoenix Contact’s expense, and implementing the agreed remedy in all newly manufactured Products. Phoenix Contact shall be responsible for the reasonable following costs and expenses actually incurred and substantiated as a result of all aspects of implementing the agreed remedy on the affected Products: reasonable costs of the retrieval, packing, shipping and transportation of such Products, and the re-deployment of repaired or replacement Products (including all labor, consulting, contractor and the like charges, incurred by ENPHASE, only if Phoenix Contact has agreed in writing that ENPHASE is allowed to do the aforementioned activities). For the avoidance of doubt all damages defined in Article 11.4 shall be direct damages and shall be subject to Article 14.2.
Equipment Failures In the event of equipment failures beyond the Administrator's control, the Administrator shall take reasonable and prompt steps to minimize service interruptions but shall have no liability with respect thereto. The Administrator shall develop and maintain a plan for recovery from equipment failures which may include contractual arrangements with appropriate parties making reasonable provision for emergency use of electronic data processing equipment to the extent appropriate equipment is available.
Temperature The Committed Gas shall not have a temperature of less than forty degrees Fahrenheit (40°F) nor more than one hundred twenty degrees Fahrenheit (120°F).
Borrower’s Failure to Notify If the Borrower fails to give notice pursuant to Section 1.6(a) above of the continuation or conversion of any outstanding principal amount of a Borrowing of Eurodollar Loans before the last day of its then current Interest Period within the period required by Section 1.6(a) and such Borrowing is not prepaid in accordance with Section 1.8(a), the Borrower shall be deemed to have given the notice three (3) Business Days prior to the end of the then current Interest Period and such Borrowing shall automatically be continued as a Borrowing of a Eurodollar Loan with a one (1) month Interest Period; provided that all Lenders are able to accommodate such one (1) month Interest Period and such Eurodollar Loan shall be subject to the funding indemnity set forth in Section 1.11 hereof in the event it is prepaid prior to the end of the Interest Period. In the event the Borrower fails to give notice pursuant to Section 1.6(a) above of a Borrowing equal to the amount of a Reimbursement Obligation and has not notified the Administrative Agent by 12:00 noon (Chicago time) on the day such Reimbursement Obligation becomes due that it intends to repay such Reimbursement Obligation through funds not borrowed under this Agreement, the Borrower shall be deemed to have requested a Borrowing of Base Rate Loans under the Revolving Credit (or at the option of the Swing Line Lender under the Swing Line) on such day in the amount of the Reimbursement Obligation then due, which Borrowing shall be applied to pay the Reimbursement Obligation then due.
Payment Failure Any Credit Party (i) fails to pay any principal when due under this Agreement or (ii) fails to pay, within three Business Days of when due, any other amount due under this Agreement or any other Credit Document, including payments of interest, fees, reimbursements, and indemnifications;
Business Failure Any act by, against or relating to any Loan Party, or its property or assets, which act constitutes the determination by any Loan Party to initiate or acquiesce to: a program of partial or total self-liquidation; an application for, consent to, or sufferance of the appointment of a receiver, trustee, or other person, pursuant to court action or otherwise, with respect to all or any part of any Loan Party’s property; the granting of any trust mortgage or execution of an assignment for the benefit of the creditors of any Loan Party; any other voluntary or involuntary liquidation or extension of debt agreement for any Loan Party; the offering by, or entering into by, any Loan Party of any composition, extension, or any other arrangement seeking relief from or extension of the debts of any Loan Party; or the initiation of any judicial or non-judicial proceeding or agreement by, against, or including any Loan Party which seeks or intends to accomplish a reorganization or arrangement with creditors; and/or the initiation by or on behalf of any Loan Party of the liquidation or winding up of all or any part of any Loan Party’s business or operations.
Tenant Delay If the Substantial Completion of the Tenant Improvement Work is delayed (a “Tenant Delay”) as a result of (a) any failure of Tenant to approve the Construction Pricing Proposal pursuant to Section 2.6 above on or before Tenant’s Approval Deadline; (b) Tenant’s failure to timely approve any matter requiring Tenant’s approval; (c) any breach by Tenant of this Work Letter or the Lease; (d) any request by Tenant for a revision to the Approved Construction Drawings (except to the extent such delay results from any failure of Landlord to perform its obligations under Section 2.7 above); (e) Tenant’s requirement for materials, components, finishes or improvements that are not available in a commercially reasonable time given the anticipated date of Substantial Completion of the Tenant Improvement Work as set forth in this Agreement; (f) any change to the base, shell or core of the Premises or Building required by the Approved Construction Drawings; or (g) any other act or omission of Tenant or any of its agents, employees or representatives, then, notwithstanding any contrary provision of this Agreement, and regardless of when the Tenant Improvement Work is actually Substantially Completed, the Tenant Improvement Work shall be deemed to be Substantially Completed on the date on which the Tenant Improvement Work would have been Substantially Completed if no such Tenant Delay had occurred.
Floor Load Tenant shall not place a load upon any floor of the Premises that exceeds 50 pounds per square foot “live load”. Landlord reserves the right to reasonably designate the position of all Equipment which Tenant wishes to place within the Premises, and to place limitations on the weight thereof.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Landlord Delay Landlord’s (a) failure to comply with any time requirements expressly set forth in Paragraph 2.d. above with respect to Landlord’s obligation to provide notice of approval or disapproval of the Space Plan, Working Drawings or Change Orders, or (b) Landlord’s unreasonable interference with the completion of Tenant Improvements, including any failure or refusal of Landlord or Landlord’s agents or contractors to permit Tenant, its agents or contractors, access to and use of the Building or any Building facilities or services (including hoists, elevators, and loading docks) which access or use is reasonably required for the orderly and continuous performance of the work necessary to complete Tenant Improvements, are referred to collectively herein as “Landlord Delay” (provided that no Landlord Delay as described in clause (b) above will be deemed to have occurred unless and until Tenant has notified Landlord of the event which Tenant claims constitutes a Landlord Delay and Landlord has failed to cure such event within five (5) Business Days thereafter). Tenant will use commercially reasonable efforts to mitigate its damages and/or construction delays in the event of an alleged Landlord Delay. Notwithstanding anything to the contrary in this Paragraph 2, if and to the extent Tenant reasonably incurs a net increased cost (taking into account any cost saving Landlord might have facilitated by its actions, including any Landlord Delay) of design or construction of the Tenant Improvements as a direct result of any Landlord Delay (as reasonably evidenced by Tenant, with supporting documentation), Landlord will be responsible for such reasonable increased costs and Landlord’s Allowance will be increased by the amount of such reasonable increased cost. Further, when determining whether a particular Landlord Delay delayed Substantial Completion of the Tenant Improvements, the subject Landlord Delay shall be offset by any action or response by Landlord that achieved a reduction in Tenant’s construction schedule (each day saved in Tenant’s construction schedule being a “Schedule Saving Day”) and any aggregate Landlord Delay as described in this Paragraph 2.f. shall first be offset against, and reduced on a day-for-day basis by, the aggregate number of Schedule Saving Days. In the event of a disagreement between Landlord and Tenant as to whether a Landlord Delay has occurred and/or as to the application of this grammatical paragraph, either party may submit the issue to the dispute resolution procedure set forth in Paragraph 2.j. below. This Paragraph 2.f. is inapplicable to delays in Delivery, whether caused by Landlord, Landlord’s Contractor or otherwise (such delays being expressly covered by Paragraph 2.a. above) and this Paragraph 2.f. only applies to delays in the commencement or Substantial Completion of the Tenant Improvements following Delivery.
