Subsequent updates Sample Clauses

Subsequent updates. An updated TIA shall be submitted in December 2015 or when the total built square footage with the Carolina North Project reaches 800,000 square feet of total building floor space, whichever occurs first. Thereafter, additional TIA updates shall be submitted upon a schedule mutually agreed upon by the Town and University, provided that an update shall be submitted no less frequently than every five years. If there has not been substantial development on the Carolina North Project in the period since the previously completed TIA, the University may request that the Manager approve a revised schedule or a modification in the scope of the TIA.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Subsequent updates. If any subsequent updated version(s) of the Title Commitment and/or Survey should contain exceptions that were not set forth on the original versions of the Title Commitment and Survey reviewed by Purchaser (and were not created by Purchaser or with Purchaser’s express, written consent), the foregoing provisions of this Section 6 shall apply, as to such additional exceptions only, as to the updated version(s) of the Title Commitment and/or Survey with respect to the review, objection and cure of such additional exceptions; provided, however, all deadlines in this Section 6 shall be reduced so that Purchaser’s Title Review Period would be four (4) days, Seller’s Response Period would be two (2) days, and Purchaser’s termination right would last for two (2) days.
Sample 1
Subsequent updates. The Updates referred to in this Contract mean that any improvements made to the subject matter of this contract by either party or both parties during the term of this Contract. Both Parties agree that the subsequent improvements to the subject matters of this Contract shall be made by Party A and shall be owned by Party A.
Sample 1
Subsequent updates. All subsequent updates shall be made only as set forth in Supply Terms Section 4.5. The costs of all such subsequent updates shall be as set forth in such Supply Terms Section.
Sample 1
Subsequent updates. An updated TIA shall be submitted in December 2012 or when the total square built square footage with the Carolina North projectProject reaches 800,000 square feet of total building floor space, whichever occurs first. later. Thereafter, additional TIA updates shall be submitted upon a schedule mutually agreed upon by the Town and University, provided that an update shall be submitted no less frequently than every five years or for each increment of development on the Carolina North Tract that includes 800,000 square feet of total building floor space, whichever occurs later. These updates shall continue until construction of the buildings included in the Carolina North projectProject subject to this Agreement is substantially complete, a new development agreement supersedes this requirement, or this Agreement is modified. New traffic and transportation data shall be collected in September/October of the applicable year for each TIA update. If there has not been substantial development on the Carolina North project in the period since the previously completed TIA, the University may request that the Manager approve a delay in a TIA update or a modification in the scope of the TIA.
Sample 1

Related to Subsequent updates

  • Automatic Updates If you choose to allow automatic app updates, your device will periodically check with Apple for updates and upgrades to the Apple Software and, if an update or upgrade is available, the update or upgrade will automatically download and install onto your device and, if applicable, your peripheral devices. You can turn off the automatic app updates altogether at any time by changing the automatic app updates settings found within Settings.

  • Schedule Updates the Contractor agrees to maintain the Work duration schedule updates on an ongoing basis and, when the County requests it, include the updates in its payment request. The Contractor may be required to submit a narrative report with each monthly update which shall include a description of current and anticipated problem areas, delaying factors and their impact, and an explanation of corrective action taken or proposed. Failure to do so may be considered a material breach of the Contract. Any additional or unanticipated costs or expense required to maintain the schedules shall be solely the Contractor’s obligation and Contractor agrees not to charge the County.

  • Disclosure Updates Promptly and in no event later than 5 Business Days after obtaining knowledge thereof, notify Agent if any written information, exhibit, or report furnished to the Lender Group contained, at the time it was furnished, any untrue statement of a material fact or omitted to state any material fact necessary to make the statements contained therein not misleading in light of the circumstances in which made. The foregoing to the contrary notwithstanding, any notification pursuant to the foregoing provision will not cure or remedy the effect of the prior untrue statement of a material fact or omission of any material fact nor shall any such notification have the effect of amending or modifying this Agreement or any of the Schedules hereto.

  • Software Updates XXXXX agrees to keep current with software licensed from Skyward and will install new versions on a timeline approved by XXXXX governance. This timeline will be communicated by NWRDC to the Districts. School District Workstations Configuration requirements for devices and their software that school district personnel use to access WSIPC’s software modules can be found on our website: xxxxx://xxx.xxxxx.xxx/technology‐team/. State Reports XXXXX will provide, at no additional fee, all data reports required by the state that impact 50% or more of the school districts in the state. WSIPC and NWRDC will work with state agencies to gather requirements on the required data. WSIPC will inform NWRDC staff of any mandated changes to state reports and NWRDC will communicate the information to the District. Appendix B NWRDC FTE Fees Fiscal Only NWRDC Software Support Services XXXXX Software Licensing Total FTE Fee $13.63 $20.34 $33.97 $15.56 $13.08 $28.64 $24.52 $20.34 $44.86 Student Only Full Service

  • Alternative Work Schedule An alternate forty (40) hour work schedule (other than five (5) uniform and consecutive eight (8) hour days in a seven (7) day period), or for hospital personnel an eighty (80) hour workweek in a fourteen (14) day period and other mutually agreed upon schedules that comply with applicable federal and state law. Employee work schedules normally include two (2) consecutive days off.

  • RDDS update time Refers to the time measured from the reception of an EPP confirmation to a transform command on a domain name, host or contact, up until the servers of the RDDS services reflect the changes made.

  • DNS update time Refers to the time measured from the reception of an EPP confirmation to a transform command on a domain name, until the name servers of the parent domain name answer “DNS queries” with data consistent with the change made. This only applies for changes to DNS information.

  • Alternative Work Schedules Employees may request alternative work schedules such as a nine (9) day - 80 hour two week schedule or a four (4) day - 40 hour week schedule. Management will respond to an employee's request within 15 calendar days. Any changes from existing work schedules will be based on the needs of the service as determined by Management. Employees covered by the Fair Labor Standards Act will not be placed on alternate work schedules that mandate the payment of overtime under the Act.

  • Updates “Updates” are changes that do not require a change to the established Centralized Contract terms and conditions. Updates may include: Centralized Contract changes and updates made in accordance with the previously approved pricing formula (e.g. discount from list price); adding new products or services within the established, previously approved pricing structure; lowering pricing of products or services already on Contract, deleting products or services available through the Centralized Contract, adding product or service that do not fall under the previously established price structure or discounts under the Contract, re-bundled products, and other updates not listed above that are deemed to be in the best interest of the State and do not result in a change to the established Centralized Contract terms and conditions. Updates must be submitted to OGS for review, and must be accompanied by a justification of reasonableness of price if the change results in a change in pricing methodology. OGS will notify Contractor in writing if approved.

  • How Do I Get More Information? This Settlement Notice does not fully describe all of the claims, defenses, or contentions of the parties. If you have questions about this Notice or the Action, please do not contact the Court. If you have questions regarding the Settlement, you can call Class Counsel at 0-000-000-0000, email Class Counsel at xxxxxxx@xxxxxxxxxxxxxxxxx.xxx, call the Settlement Administrator at 0-000-000-0000, write to the Settlement Administrator at JPM Stable Value Fund Litigation c/o JND Class Action Administration, P.O. Box 91304, Seattle, WA 98111, or go to the following website: xxx.xxxxxxxxxxxxxxxxx.xxx where you will find the Court’s order certifying the Class, the Plaintiffs’ Consolidated and Amended Complaint, the Defendants’ Answer to the Consolidated and Amended Complaint, the Settlement Agreement, and information regarding the day, time, and location of the Fairness Hearing once it has been scheduled by the Court. Other filings with the Court and information regarding the Settlement are also available online. Dated: , 2017 BY THE ORDER OF THE UNITED STATES DISTRICT COURT FOR THE SOUTHERN DISTRICT OF NEW YORK ATTACHMENT 1 PLAN SPONSOR 1 1888 XXXXX, LLC 2 X.X. XXXXXXXX CO., INC. 3 ABILENE CHAMBER OF COMMERCE 4 ABITIBI CONSOLIDATED SALES CORPORATION 5 ACCE BENEFIT TRUST 6 ACCE BENEFITS TRUST 7 ACCE BENEFITS TRUST 401(K) PLAN 8 ADVANCED MEDICAL OPTICS, INC. 9 AGGREKO, LLC 10 AJAX PAVING INDUSTRIES OF FLORIDA, INC. 11 AJAX PAVING INDUSTRIES, INC. 12 ALASKA TANKER COMPANY ATC 13 ALCON LABS 14 ALLERGAN INC 15 ALM MEDIA INC. 16 ANCHOR ACQUISITION, LLC 17 AMARILLO CHAMBER OF COMMERCE 18 AMERICAN CHAMBER OF COMMERCE EXECUTIVES 19 AMERICAN CIVIL CONSTRUCTORS, INC. 20 AMERICAN LIGHTING ASSOCIATION 21 AMERICAN ROYAL ASSOCIATION 22 AMERICAN TECHNOLOGIES, INC. 23 ALLIANT ENERGY CORPORATE SERVICES, INC. 24 AMERICAN ELECTRIC POWER SERVICE CORP. (AEP) 25 XXXXXXXX CORP. 26 XXXXXX CORP. 27 ANGELO'S AGGREGATE MATERIALS, LTD. 28 XXXX TRUCKING L.L.C. 29 APAC PAPER & PACKAGING CORP. 30 ARBOR MANAGEMENT, INC. 31 ARCH CHEMICAL INC. 32 AREA ENERGY & ELECTRIC, INC. 33 ARGO GROUP US 34 ARIZONA CHEMICAL COMPANY PLAN SPONSOR 35 ARLINGTON METALS CORPORATION 36 ASPHALT PAVING, INC. 37 ASSOCIATED WHOLESALE GROCERS, INC. 38 ASTEC INDUSTRIES, INC. 39 ASTELLAS US LLC 40 ATLANTIC SOUTHEAST AIRLINES, INC 41 AUDIO AUTHORITY CORPORATION 42 AUGUSTA NEWSPRINT COMPANY 43 AVON PRODUCTS, INC. 44 X.X. XXXXXXXX / XXXXXXXX / UNITED TECHNOLOGIES CORPORATION (UTC) 45 BADGERLAND SUPPLY. INC. 46 BAESMAN PRINTING CORPORATION 47 BANK OF COMMERCE & TRUST COMPANY 48 BATON ROUGE AREA CHAMBER PROFIT SHARING PLAN 49 XXXXXXX XXXXXX COMPANY LLC 50 XXXX TOYOTA CORP. 51 BEECHMONT PRESS, LLC 52 XXXX INC. 53 BELL CORP. 54 XXXXX COMPANY, INC. 55 BENESYS, INC. 56 XXXXXXX, XXXXXXX, XXXXXXX AND DAVIS APLC 57 BEST BUY 58 BIGSTON CORPORATION 59 BIOMEDICAL RESEARCH FOUNDATION 60 BISON GEAR ENG. CORP 61 BOC XXXXXXX, INC. 62 BOISE CONVENTION & VISITORS BUREAU PROFIT 63 BOISE METRO CHAMBER OF COMMERCE 64 BOSE CORP. 65 XXXXXX AND XXXXXX P.A. 66 XXXXXX & XXXXXXXX CORPORATION 67 XXXXX XXXXX COMPANY 68 BROOK FURNITURE RENTAL INC. 69 XXXXXXXXXX HOLDINGS, INC. 70 BROWN AND XXXXXXXX PLAN SPONSOR 71 BUCKEYE PIPE LINE SERVICES COMPANY 72 XXXX-O-MATIC CORPORATION 73 X.X. ENTERPRISES 74 CANBERRA OAK RIDGE, LLC 75 CARATRON INDUSTRIES, INC. 76 XXXXXXX INC. 77 CARL ZEISS VISION INC. 78 XXXX INDUSTRIES, INC. 79 XXXXXX MACHINERY CO. 80 CATERPILLAR INC. 81 CDM FEDERAL SERVICES, INC. 82 CELANESE (HOECHST CELANESE) 83 CENTRALIZED LABORATORY SERVICES INC 84 CERNER CORP. 85 CHATTANOOGA AREA CHAMBER OF COMMERCE 86 CHRISTIAN REFORMED CHURCH IN NORTH AMERICA 87 CINCINNATI TOOL STEEL COMPANY 88 XX XXXXXX CONSTRUCTION COMPANY 89 CLARIAN HEALTH / INDIANA UNIV. HEALTH INC. 90 XXXXXX QUALITY COATINGS, INC. 91 CLEAR LAKE AREA CHAMBER OF COMMERCE 92 XXXX HARDWOOD INC. 93 XXXXXXX & XXXXXX PRODUCTS CO. 94 COLONIAL PIPELINE CO. 95 COMMODORE ADVANCE SCIENCES, INC. 96 COMSYS IT PARTNERS INC. 97 CONNING & COMPANY 98 COOK COMPOSITES & POLYMERS COMPANY 99 COOPERATIVE REGIONS OF ORGANIC PRODUCER POOLS COOPERATIVE, INC. 100 CROWN EQUIPMENT CORP. 101 CSK AUTO, INC. 102 CUMMINS INC. 103 XXXXXXX & XXXXXXXXX, INC. 104 DACO INCORPORATED 105 DAKOTA CLINIC / INNOVIS HEALTH 106 DALLAS REGIONAL CHAMBER PLAN SPONSOR 107 DASCO PRO INC. 108 DETROIT LEGAL NEWS COMPANY 109 XXXX XXXXXX INC. 110 DIRECT GENERAL CORPORATION 111 XXX X. XXXXXXX, INC. 112 XXXXXXX COMPANIES INC. 113 DOTT INDUSTRIES, INC. 114 DOWCO INC. 115 DURATEK FEDERAL SERVICES, INC. 116 X.X. XXXXXXX COMPANY 117 EAGLE-PICHER CORPORATION 118 XXXX XXXXX CO. INC. 119 EDISON ELECTRIC INSTITUTE INC. 120 EET CORPORATION 121 XXX XXXXX 122 ELKAY MANUFACTURING COMPANY 123 ELMER'S PRODUCTS INC. 124 EMPIRE LEVEL MANUFACTURING CORP. 125 ENERCON ENGINEERING, INC. 126 ENERGY EAST CORP. 127 ENERGY NORTHWEST 128 XX XXXX GROUP, L.P. 129 ERICSSON INC. 130 XXXXX XXXXX GLOBAL INC. 131 E-S PLASTIC PRODUCTS INC. 132 FATHER XXXXXXXX'X BOYS' HOME 133 XXXXXXX COMPANIES, INC. 134 FERRO CORP. 135 XXXXXX & COMPANY, INCORPORATED 136 FITCH, INC. 137 FIVE STAR DISTRIBUTING, INC. 138 XXXXXXXXX & XXXX 139 FOREMOST FARMS USA 140 FOREST LABORATORIES, INC. 141 FLORIDA CHAMBER OF COMMERCE 142 FLORIDA GAS TRANSMISSION COMPANY 143 FLO-TORK, INC. PLAN SPONSOR 144 FOX CITIES CHAMBER OF COMMERCE & INDUSTRY 145 XXXXX X. XXXX COMPANY 146 FREEPORT MCMORAN / XXXXXX DODGE CORP. 147 XXXXXXX DENVER, INC. 148 GERLIN, INC. DBA CORE PIPE PRODUCTS, INC. 149 GENERAC 150 GENERAL XXXXX 151 XXX CONSULTANTS, LLC 152 GHP OPERATING COMPANY LLC (GLOBAL HOME PRODUCTS) 153 XXXXXXXX / PROCTER & XXXXXX 154 GLENMARK INDUSTRIES INC. 155 GPD, INC. 156 GREAT PLAINS ENERGY INCORPORATED 157 GREATER BINGHAMTON CHAMBER OF COMMERCE 000 XXXXXXX XXXXXXXXXX XXXXXXX OF COMMERCE 159 GREATER XXXXXXX CHAMBER PARTNERSHIP 160 GREATER LOUISVILLE INC. 161 GREATER NEW HAVEN CHAMBER OF COMMERCE 162 GREATER PROVIDENCE CHAMBER OF COMMERCE 163 GREATER RALEIGH CHAMBER OF COMMERCE 164 GREATER READING CHAMBER OF COMMERCE/INDUSTRY 165 GREATER SCRANTON CHAMBER OF COMMERCE 166 GREATER TAMPA CHAMBER OF COMMERCE 167 GREATER TOPEKA CHAMBER OF COMMERCE 168 GREATER WACO CHAMBER OF COMMERCE 169 GREATER WASHINGTON BOARD OF TRADE 170 GREEN DIAMOND RESOURCE COMPANY 171 GREEN THUMB LAWNSCAPING, INC. 172 GRINDMASTER CORPORATION 173 XXXXXXXXX LUMBER & SPPLY, INC. 174 GZA GEOENVIRONMENTAL, INC. 175 H&S TOOLS INC. 176 XXXXX & XXXXXXX INC 177 HAPAQ-XXXXX 178 XXXXXXX ROADS CHAMBER OF COMMERCE 179 XXXXXX PUBLICATIONS, INC.

Time is Money Join Law Insider Premium to draft better contracts faster.