Submittal Review. 7.10.1 The A/E shall review Submittals such as Shop Drawings, Product Data, and Samples for conformity with design intent and conformity with the Contract Documents within 14 days of receiving Submittals or in accordance with the approved submittal schedule, or other period as mutually agreed by the A/E and Contractor.
Submittal Review. The Professional shall review all contractor submittals for compliance with the design concepts to include the following:
Submittal Review. The Architect shall review the Contractor’s Submittals for conformance with requirements of, and the design concept expressed in, the Contract Documents and approve or take other appropriate action upon them.
Submittal Review. 2.6.13.1 The A/E shall review and approve or take other appropriate action upon GC's submittals such as Shop Drawings, Product Data and Samples, for the purpose of (1) assuring compliance with applicable laws, statutes, ordinances, codes, orders, rules and regulations; and (2) assuring that the Work affected by and represented by such submittals is in compliance with the requirements of the Construction Contract Documents. A/E shall be responsible for determining what aspect of the Work shall be the subject of Shop Drawings and submittals, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Construction Contract Documents. The A/E's action shall be taken with such reasonable promptness as to cause no delay in the Work.
Submittal Review. The Architect-Engineer will review and approve, or take other appropriate action upon, the Construction Manager’s submittals such as Shop Drawings, Product Data and Samples, but only for the limited purpose of checking for conformance with information given and the design concept expressed in the Contract Documents. The Architect-Engineer’s action will be taken in accordance with the submittal schedule approved by the Owner and Architect-Engineer or, in the absence of an approved submittal schedule, with reasonable promptness while allowing sufficient time in the Architect- Engineer’s professional judgment to permit adequate review. Review of such submittals is not conducted for the purpose of determining the accuracy and completeness of other details such as dimensions and quantities, or for substantiating instructions for installation or performance of equipment or systems, all of which remain the responsibility of the Construction Manager as required by the Contract Documents. The Architect-Engineer’s review of the Construction Manager’s submittals shall not relieve the Construction Manager of the obligations under Article 4 of this Exhibit A. The Architect-Engineer’s review shall not constitute approval of safety precautions or, unless otherwise specifically stated by the Architect-Engineer, of any construction means, methods, techniques, sequences or procedures. The Architect-Engineer’s approval of a specific item shall not indicate approval of an assembly of which the item is a component.
Submittal Review. The Architect shall review, and take appropriate action upon Submittals for the limited purpose of checking for conformance with the information given and the design concept expressed in the Construction Documents. The Architect’s actions hereunder shall be taken with such reasonable promptness as to cause no delay, interruption or hindrance to the activities of the Contractor or others performing construction activities at the Site affected by such Submittal while allowing sufficient time in the Architect’s professional judgment to permit adequate review. If a Submittal Schedule or time for completion of the Architect’s review and evaluation of Submittals is set forth in the Construction Contract, and such schedule has been approved by the Architect, the Architect’s actions hereunder shall conform with such Submittal Schedule or time; Architect shall be responsible for all results or consequences of its failure or refusal to complete its review and evaluation of Submittals in accordance therewith. When professional certification of performance characteristics of materials, systems or equipment is required by the terms of the Construction Contract, the Architect shall be entitled to rely upon such certification to establish that the materials, systems or equipment will meet the performance criteria required by the Construction Contract.
Submittal Review. The CMA shall generally track the submittal submission and review process for timely processing in accord with contract requirements. The CMA shall review the GC’s submittal schedule for completeness and accuracy.
Submittal Review. The CM shall receive, review for completeness and responsiveness the Contractors’ submittals such as Shop Drawings, Product Data and Samples and shall deliver them to the A/E for review as provided in the General Conditions.
Submittal Review. Consultant will develop submittal log and coordinate review process for submittals, shop drawings, traffic control plans, test reports, and other submittals from the Contractor for compliance with the Contract Documents. The City’s EADOC program will be used to log, track, and transmit submittals and submittal responses. Consultant will review and respond to submittals in accordance with agreed communications plan.
Submittal Review. Review contractor submittals and shop drawings for conformance to the design requirements of the project. Consult with and advise City as to the acceptability of substitute and “or-equal” items proposed for use by contractor.
