Stadium Alternative Sample Clauses

Open Split View

Download

Share

Cite

Stadium Alternative 

Sample 1Sample 2Sample 3

Save

Copy

Related to Stadium Alternative

• Capital Improvements The Department has identified the following possible opportunities for Capital Improvements:

• Emergency Generator Although Landlord is the owner of emergency generator and related automatic transfer switches serving the Building and the 901 Building (collectively, the “Emergency Generator”), prior to the date of this First Amendment, Tenant, as the sole tenant of the Building and the 901 Building, has been operating and maintaining the Emergency Generator. Tenant shall, on the date that is 1 day after the mutual execution and delivery of this First Amendment by the parties (“EG Transfer Date”), (x) deliver the Emergency Generator to Landlord in good working order with a full tank of diesel (y) assign to, transfer and deliver to Landlord all governmental permits and licenses (to the extent such permits and licenses are assignable), if any, warranties (to the extent assignable), operating and maintenance manuals, records and other documents concerning the Emergency Generator, and (y) terminate any service, maintenance or other contracts maintained by Tenant with respect to the Emergency Generator. Tenant has not been obligated to maintain a wastewater permit in connection with the Emergency Generator. With respect to any permit required for the Emergency Generator, Landlord acknowledges and agrees that Tenant has been in the process of obtaining a generator permit in connection with a Tenant permitting process underway with the Bay Area Air Quality Management District (“BAAQMD”) for the 901 Building, that Tenant will remove the generator from its permit application with BAAQMD, and that Landlord will need to obtain a generator permit from BAAQMD in its own name. To the best of Tenant’s knowledge, Tenant does not have any other permits in connection with the Emergency Generator. To the extent Tenant has current contracts with any vendors for the Emergency Generator, Tenant and Landlord shall reasonably cooperate to assign or terminate such contracts in the manner set forth in Section 14 above regarding utilities. To the extent it is not possible for Tenant to remove the request for a generator permit from its BAAQMD application or to assign or terminate any service maintenance or other contracts within 1 day after the mutual execution and delivery of this First Amendment, Tenant shall not be in default hereunder if Tenant promptly commences efforts to do so and diligently performs until such actions have been completed within a reasonable period after such date. Landlord shall, within 5 days of the EG Transfer Date, as part of Expenses, conduct such testing of the Emergency Generator required, in Landlord’s sole and absolute discretion, to determine whether the Emergency Generator is, in fact, in good working order. If such testing discloses that the Emergency Generator is not in good working order, Landlord shall have the right, at Tenant’s sole cost and expense, to perform any maintenance and/or repairs required to put the Emergency Generator in good working order. Following the EG Transfer Date, Landlord’s sole obligation for either providing emergency generators or providing emergency back-up power to Tenant shall be: (i) to provide emergency generators with not less than the current capacity of the Emergency Generator and Tenant shall be entitled to Tenant’s share of the capacity thereof available for use by all tenants of the Building and the 901 Building, collectively, in accordance with the rentable area of the Premises and the 901 Building and the collective rentable areas of the Building and the 901 Building occupied by such other tenants, (ii) to contract with a third party to maintain the emergency generators (“Emergency Generator Servicer”) as per the manufacturer’s standard maintenance guidelines, and (iii) to obtain and maintain licenses for the emergency generators as required by applicable law. Landlord shall have no obligation to provide Tenant with operational emergency generators or back-up power or to supervise, oversee or confirm that the Emergency Generator Servicer or any other third party maintaining the emergency generators is maintaining the generators as per the manufacturer’s standard guidelines or otherwise. Landlord shall provide to Tenant copies of any reports received by Landlord from the Emergency Generator Servicer regarding its maintenance and repairs of the emergency generators; provided, however, that in no event shall Landlord’s failure to deliver such reports constitute a default by Landlord under the Lease. During any period of replacement, repair or maintenance of the emergency generators when the emergency generators are not operational, including any delays thereto due to the inability to obtain parts or replacement equipment, Landlord shall have no obligation to provide Tenant with an alternative back-up generator or generators or alternative sources of back-up power. Tenant expressly acknowledges and agrees that Landlord does not guaranty that such emergency generators will be operational at all times or that emergency power will be available to the Premises when needed. Landlord shall provide Tenant with not less than five (5) business days’ notice of the scheduled disruption in the operation of the emergency generators. In the case of an emergency, Landlord shall provide Tenant with notice of any emergency disruption as soon as reasonably possible after Landlord becomes aware of the need for such emergency disruption.

• Permitted Alterations Tenant shall not make or permit ATIONS any Alterations in, on or about the Premises without the prior written consent of Landlord (which shall not be unreasonably withheld or delayed) and according to plans and specifications approved in writing by Landlord, which consent shall not be unreasonably withheld or delayed. For purposes of this Lease, "Alterations" shall mean any alterations, additions or improvements made in, on or about the Premises after the Commencement Date, including, but not limited to, lighting, heating, ventilating, air conditioning, electrical, partitioning, fixtures, drapery and carpentry installations; provided, however, that Tenant, at Tenant's sole cost and expense, may install its necessary trade fixtures, equipment and furniture in the Premises without Landlord's consent, provided that such items are installed and are removable without damage to the Project or to any of its electrical, mechanical or plumbing systems, and such alterations do not cost more than $10,000.00 each. Notwithstanding the foregoing, Landlord may withhold Landlord's consent in its sole discretion (including, without limitation, on wholly aesthetic grounds) to any: (i) alterations to the exterior or structural component of the Building, including, without limitation, exterior walls and roof of the Building; and (ii) alterations visible from outside the Building, including Outside Areas. All alterations shall be installed at: Tenant's sole expense, in compliance with all applicable laws and the CC&R's by Landlord's contractor, shall be done in a good and workmanlike manner conforming in quality and design with the Premises existing as of the Commencement Date, and shall not diminish the value of the Premises. Landlord shall have the right to require that all Alterations shall be of first class quality consistent with the quality of the Project. All alterations made by Tenant, or by Landlord at Tenant's expense, shall at the termination or expiration of the Lease become the property of Landlord and shall remain upon and be surrendered with the Premises; provided, however, that Landlord may, at its option, require that Tenant, at Tenant's expense, remove any or all nonstructural Alterations installed by Tenant, or by Landlord at Tenant's expense, and return the Premises to their condition as of the Commencement Date of this Lease, normal wear and tear excepted and subject to the provisions of Paragraph 13. If requested by Tenant, Landlord shall inform Tenant at the time Landlord consents to the Alteration as to whether or not the Alteration in question must be removed from the Premises upon the expiration or earlier termination of the Lease. Notwithstanding any other provision of this Lease, Tenant shall be solely responsible for the maintenance and repair of any and all Alterations to the Premises made by Tenant, or by Landlord at Tenant's expense.

• Tenant Improvements Subject to the terms and conditions hereof, Landlord agrees, at its cost and expense to complete a “turnkey” interior build-out (“Tenant Improvements”) of the Leased Premises in accordance with the conditions stated in the Work Letter attached hereto as Exhibit C and incorporated hereby pursuant to the Approved Final Plans to be finalized and approved in accordance with the Work Letter and upon approval attached thereto. Any changes or modifications to the Approved Final Plans thereafter must be done in writing and signed by both Tenant and Landlord in accordance with the Work Letter. So long as in accordance with Article 19 of this Lease, Tenant agrees that Landlord shall be entitled to select, in its reasonable discretion and acting in good faith, all architects, engineers, contractors and material suppliers necessary to furnish the labor and materials for the construction of the Tenant Improvements. Landlord shall be the sole contracting party with respect to the employment of contractors which perform the work necessary to construct the Tenant Improvements. Tenant shall not be entitled to access to the Leased Premises prior to the Date of Substantial Completion and Tenant shall not interfere with or impair in any material way the construction of the Tenant Improvements, and any such interference or impairment shall be included within a Tenant Delay as defined in the Work Letter and shall entitle Landlord to all remedies provided herein for breach of this Lease. Prior to the Possession Date, Tenant shall not enter into any contract for construction of any improvements within the Leased Premises with any person other than Landlord without Landlord's prior written consent. Tenant, at Tenant's expense, shall obtain and maintain any and all necessary permits and licenses to enable Tenant to conduct Tenant’s Permitted Use, and the failure of Tenant to obtain or maintain same shall not in any manner affect the Tenant’s obligations hereunder. Landlord shall be solely responsible, at its cost and expense, for obtaining all permits and approvals related to the Tenant Improvements.

• Communications Equipment Members of the board of directors or any committee thereof may participate in and act at any meeting of such board or committee through the use of a conference telephone or other communications equipment by means of which all persons participating in the meeting can hear each other, and participation in the meeting pursuant to this section shall constitute presence in person at the meeting.

• SATELLITE DISH Subject to compliance with all applicable Legal Requirements, Tenant shall have the exclusive right to place, from time to time, satellite dishes, antennae and other communication or transmission devices (such devices being referred to as the “Satellite Dishes”) on the roof of each of the Buildings. Additionally, Tenant shall have the right to install such wire, conduits, cables and other materials as necessary to connect the Satellite Dishes to Tenant’s allied machinery and equipment in the Premises (the Satellite Dishes and any such connecting material being collectively referred to as the “Satellite Dish Facilities”). However, prior to the installation of any Satellite Dish Facilities, Tenant, at its expense, shall be required to provide Landlord with a certification by a registered professional structural engineer that the structural system of the roof is adequate to support the superimposed loads produced by any Satellite Dishes at the location on the roof of such Satellite Dishes and Tenant, at its expense, shall be required to provide Landlord with satisfactory assurance that the existing construction materials of the roof (such as the roof membrane) shall be protected from the Satellite Dishes. At the expiration or earlier termination of the Lease, Tenant, at its expense, may remove the Satellite Dish Facilities belonging to Tenant, but Tenant shall remove any Satellite Dish Facilities belonging to an unaffiliated third party. Any work required to restore the roof of any other part of the Buildings from any damage occasioned by the installation, maintenance or removal of the Satellite Dish Facilities shall be borne by Tenant, and Tenant shall indemnify and hold harmless Landlord from any costs, expenses, liabilities and the like, including reasonable attorneys’ fees, occasioned by any damage to property and injury or death to persons caused by such installation, maintenance or removal, except to the extent caused by the negligence, willful misconduct or breach of this Lease of Landlord. Tenant shall be responsible for the installation of all Satellite Dish Facilities (including the attachment thereto to the roof) and for all costs and expenses arising from and relating to the Satellite Dish Facilities and the installation, operation, maintenance and repair thereof, and, if Tenant elects to remove the Satellite Dish Facilities, or for those Satellite Dish Facilities for which removal is required, for the removal thereof. The installation, maintenance and removal of the Satellite Dish Facilities shall be performed by contractors and workers first approved by Landlord, which approval will not be unreasonably withheld or delayed. However, Landlord reserves the right to require Tenant, at Tenant’s expense, to use Landlord’s roofing contractor in connection therewith if, in Landlord’s reasonable judgment, the Landlord’s roof warranty may be affected by any such work. Landlord agrees that Tenant and engineering and maintenance personnel reasonably approved by Landlord shall have access to the Satellite Dish Facilities in order to install, operate, maintain, inspect and remove, as required, the Satellite Dish Facilities. Landlord shall not unreasonably interfere with or impair the use, operation, maintenance or repair of the Satellite Dish Facilities. Tenant may sublease to unaffiliated third parties rooftop rights for the installation of Satellite Dish Facilities, without Landlord’s consent, but Tenant shall give Landlord written notice of the existence of any such subleases from time to time upon Landlord’s request. All revenues derived from such third party subleases shall belong to Tenant. The Satellite Dish Facilities shall not be considered a part of the Premises for the purpose of determining Tenant’s rental obligations under the Lease and no Rent therefor shall be charged during the Term (including any renewal period specifically provided under this Lease). However, Tenant’s use of the Satellite Dish Facilities is otherwise subject to all of the terms and conditions of this Lease with respect to Tenant’s use and occupancy of the Premises, including, without limitation, Sections 9, 22 and 31.

• Tenant Improvement Plans Any work proposed by Tenant (the “Tenant Improvements”) shall be subject to Landlord’s reasonable prior approval and shall be subject to the other terms and conditions of this Exhibit C; provided that it will be reasonable for Landlord to withhold its approval or consent (as and when applicable under this Exhibit C) if Landlord’s Mortgagee has not consented to the matter that is the subject of such approval or consent. All architectural, engineering and other design fees shall be paid by Tenant. Tenant shall use its architect, engineers and other design professionals, all of whom shall comply with any applicable licensing or governmental requirements of the City of Seattle and the State of Washington; Tenant’s architect shall be approved by Landlord (“Tenant’s Architect”), which approval shall not be unreasonably withheld, conditioned or delayed. Landlord shall also be entitled to receive a copy of the agreement between Tenant and Tenant’s Architect (the “Architect Agreement”). Tenant shall cause Tenant’s Architect to prepare a draft space plan (the “Space Plan”) for the Tenant Improvements and shall submit the proposed Space Plan to Landlord for the latter’s approval (not to be unreasonably withheld) in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Space Plan within ten (10) business days of receipt; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Space Plan to be revised to address such written comments and shall resubmit said Space Plan to Landlord for approval. Such process shall continue until Landlord has approved the Space Plan. Tenant’s Architect shall then prepare working drawings and specifications for the Tenant Improvements, including architectural, structural, plumbing, mechanical, electrical, and fire protection drawings as required, suitable for permit application (the “Working Drawings”) and shall submit the proposed Working Drawings to Landlord for the latter’s approval in a time period to allow Tenant to timely complete its Tenant Improvements under this Lease. The Space Plan and Working Drawings shall be subject to Landlord’s approval, which Landlord agrees shall not be unreasonably withheld, conditioned, or delayed. Landlord shall not be deemed to have acted unreasonably if it withholds its approval thereof because, in Landlord’s reasonable opinion, the work, as described in any such item: (i) is likely to adversely affect Building Systems, the structure of the Building or the safety of the Building and/or their occupants; (ii) might impair Landlord’s ability to furnish services to Tenant or other tenants in the Building; (iii) would materially increase the cost of operating the Building; (iv) would violate any governmental laws, rules or ordinances (or interpretations thereof); (v) contains or uses hazardous or toxic materials or substances; (vi) would negatively affect the appearance of the Building; (vii) is reasonably likely to adversely affect another tenant’s premises; or (viii) is prohibited by any ground lease affecting the Building or any mortgage, trust deed or other instrument encumbering the Building. Landlord shall deliver to Tenant any written objections, questions or comments of Landlord with regard to the Working Drawings, within ten (10) business days of Landlord’s receipt of the Working Drawings; Landlord’s consent thereto shall be deemed given if not denied in writing within said ten (10) business day period. If Landlord denies its approval, it shall specify the reasons for doing so in detail. Tenant shall cause the Working Drawings to be revised to address such written comments and shall resubmit said Working Drawings to Landlord for approval. Landlord may, when approving the Tenant Improvement Plans, elect to require Tenant to remove any Non-Standard Improvements which are made to the Premises. If Landlord so elects, Tenant shall, at its own cost, restore the Premises to the condition designated by Landlord in its election, before the last day of the Term. Such process shall continue until both parties have approved the Working Drawings. Landlord’s approval of the Space Plan and/or the Working Drawings shall not be deemed any representation or warranty that the same comply with applicable codes.

• Initial Improvements It is currently contemplated that Tenant will construct prior to September 1, 2003, at Tenant's sole cost and expense, one or more Buildings, and all on and off site work, including landscaping (collectively referred to as "Initial Improvements"). The Initial Improvements, if constructed, shall in all events comply with the requirements of the PCP Permit ultimately issued by the City of Mountain View ("PCP"). Landlord hereby approves, subject to the terms and conditions of this Lease, Tenant's construction of the Initial Improvements so long as the exterior components thereof are generally in conformity with the PCP as such PCP is ultimately issued by the City of Mountain View. If Tenant desires to make any material changes to the exterior design of the Initial Improvements, then prior to submitting any application for amendment of the PCP to the City of Mountain View, Tenant shall deliver such proposed amendment to Landlord for Landlord's review and approval, which approval will not be unreasonably withheld or delayed. Any such disapproval must be in writing stating with particularity the reasons for such disapproval and the actions Tenant may take to modify such proposal in a manner that Landlord would approve. Landlord's failure to deliver such written disapproval within five (5) business days after Tenant has delivered such request for approval to Landlord shall be deemed Landlord's approval of such proposed amendment to the PCP. Landlord shall cooperate with Tenant as reasonably requested by Tenant with respect to any required governmental approvals, including, without limitation, any application for amendment of the PCP, in connection with the Initial Improvements, including the signing of any reasonable applications or requests which are required to be signed by the owner of the Project in order to obtain required approvals, provided that Landlord shall not be required to incur any costs or expenses or liability in connection therewith. Without limiting Landlord's discretion concerning its approval rights as to any amendments to the PCP that Tenant may reasonably request, the parties agree that (i) Tenant shall not, without Landlord's prior written consent, design or seek governmental approvals to construct more than 120,000 square feet of floor area (calculated as square footage is calculated by the City of Mountain View pursuant to the City of Mountain View Shoreline West Precise Plan) within the Initial Improvements, and (ii) the general design of the Initial Improvements shall be reasonably compatible, as reasonably determined by Landlord, with the design of the buildings to be constructed on the 13.48 acre parcel of property located on the opposite side of Amphitheater Parkway from the Project. Promptly following completion of the Initial Improvements, Tenant shall deliver to Landlord as built drawings thereof on original sepia drawn to 1/8" scale, prepared at Tenant's sole cost. Notwithstanding the foregoing, if Tenant fails to substantially complete construction of the Initial Improvements on or before September 1, 2003, then Landlord may, by written notice to Tenant delivered at any time after such date and prior to substantial completion of the Initial Improvements, elect to terminate this Lease, which termination shall be effective ninety (90) days following the date of delivery of such written notice to Tenant. Notwithstanding the foregoing, (i) if Tenant substantially completes the construction of the Initial Improvements prior to the expiration of such ninety-day period, then such termination notice shall be deemed rescinded, and (ii) if Tenant delivers to Landlord an Exercise Notice of the Purchase Option to purchase the Premises as contemplated in Paragraph 34 of this Lease, prior to the expiration of such 90-day period, then such termination notice shall be deemed suspended until the date upon which the closing pursuant to the Purchase Option is scheduled to occur under the terms of this Lease. If Tenant thereafter fails to perform its obligations under the Purchase Option after Tenant's delivery of the Exercise Notice for any reason other than Landlord's failure to perform its obligations with respect to the Purchase Option, then the termination notice earlier delivered to Tenant by Landlord shall be deemed reinstated, effective as of the business day following the scheduled date for such closing which did not occur.

• Rooftop Equipment Provided that Tenant complies with the terms of ----------------- this Section, Tenant may, at its risk and expense, install a satellite dish and related communications equipment and wiring (collectively, the "Rooftop ------- Equipment") on the roof of the Building at a location approved by Landlord, --------- which equipment may be used solely by Tenant and its Permitted Transferees or Permitted Sublessees. Before installing the Rooftop Equipment, Tenant shall submit to Landlord for its approval (which approval shall be in Landlord's sole discretion) plans and specifications which (a) specify in detail the design, location, size, and, in the case of a satellite dish, frequency of the Rooftop Equipment and (b) are sufficiently detailed to allow for the installation of the Rooftop Equipment in a good and workmanlike manner and in accordance with all Laws (the "Legal Requirements"). If Landlord approves of such plans, Tenant ------------------ shall install (in a good and workmanlike manner), maintain and use the Rooftop Equipment in accordance with all Legal Requirements and shall obtain all consents and permits required for the installation and operation thereof; copies of all such permits and evidence of such consents must be submitted to Landlord before Tenant begins to install the Rooftop Equipment. Tenant shall thereafter maintain all permits necessary for the maintenance and operation of the Rooftop Equipment while it is on the Building and operate and maintain the Rooftop Equipment in such a manner so as not to unreasonably interfere with any other satellite, antennae, or other transmission facility on the Building's roof or in the Building. Landlord may require that Tenant screen the Rooftop Equipment with a parapet or other screening device acceptable to Landlord. Tenant shall maintain the Rooftop Equipment and screening device in good repair and condition. Tenant shall, at its risk and expense, remove the Rooftop Equipment (including all wiring related thereto), within five days after the occurrence of any of the following events: (1) the termination of Tenant's right to possess the Premises; (2) the termination of the Lease; (3) the expiration of the Term; or (4)

• Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.