Special penalties Sample Clauses

Special penalties. Because of the significance of the works, are burdened, without the need for notice and by the breach only, with a daily penalty of EUR 250 for every calendar day of non-performance: Non-delivery of administrative and technical documents such as reports: because not having delivered the documents listed by the time set during construction site meetings or by administrative order. Absence from construction site meetings or coordination meetings: For every absence a penalty will be imposed to the building contractor who has not attended or has not been validly represented at meetings which he was supposed to attend. Delay in executing observations or administrative orders of the contracting authority via the managing official: Where the lists of observations result from construction site visits, in particular for painting orders, or upon acceptance, have not been fulfilled by the time set by the managing official, the contractor will be penalised per calendar day of delay until performance is effectively carried out. Change of one of the key staff members without prior agreement of the contracting authority: A lump sum penalty is applied per day of default, ending when, either the managing official obtains the approval of the contracting authority for the new member’s being put in place, or the replaced member is re-established in its duties, or both parties agree about a new person as a replacement that is jointly accepted. When the penalties are applied, these may in no case be recuperated retrospectively, even where agreement is found. If a shortcoming to one of the stipulations mentioned above is found in accordance with Article 44 §2 of the Royal Decree of 14 January 2013, the contracting authority may allow a period to the building contractor to repair the shortcoming and to inform it about this reparation by registered mail. In this case, the contractor is notified of the deadline along with the failure of performance report mentioned in Art. 44 §2 of the Royal Decree of 14 January 2013. If no term is indicated in the registered letter the contractor is to repair the shortcomings without any further delay.
Sample 1
AutoNDA by SimpleDocs
Special penalties. TYPE OF PENALTY AMOUNT I COP 560,000 II COP 1,120,000
Sample 1Sample 2
Special penalties. The following special penalty provisions shall apply to violations of these Sanitary Sewer chapters:
Sample 1

Related to Special penalties

  • - FINANCIAL PENALTIES By virtue of the Financial Regulation applicable to the general budget of the European Communities, any beneficiary declared to be in grave breach of his obligations shall be liable to financial penalties of between 2% and 10% of the value of the grant in question, with due regard for the principle of proportionality. This rate may be increased to between 4% and 20% in the event of a repeated breach in the five years following the first. The beneficiary shall be notified in writing of any decision by the Commission to apply such financial penalties.

  • Statutory Penalties The defendant understands that upon his plea of guilty to Count One of the indictment charging him with conspiracy, the maximum penalty the Court may impose is not more than five years of imprisonment, a $250,000.00 fine, three years of supervised release, an order of restitution, and a $100.00 mandatory special assessment which must be paid in full at the time of sentencing. The defendant further understands that this offense is a Class D felony.

  • Prepayment Penalties 4. Any provisions in your consumer credit contract, loan, security, or account agreements that are determined to be inconsistent with or contradictory to these disclosures or the MLA (as they may be changed or amended from time to time) are inapplicable with regard to this loan. However, all other terms and conditions of the consumer credit contract shall remain in full force and effect.

  • CONTRACTUAL PENALTIES 1. Should the Accommodated Person fail to pay the price for the accommodation in the agreed amount, by the due date and under the correct variable symbol, he/she is obliged to pay interest on late payments under Section 10(2) of Act No. 176/2004 Coll., on the Disposal of the Property of Public Institutions and the Amendment to Act No. 259/1993 of the National Council of the Slovak Republic, on the Slovak Forestry Chamber, as amended by Act No. 464/2002 Coll., as amended. In addition, he/she is obliged to pay a contractual penalty (even if the contractual obligations are breached not through a fault of the Accommodated Person, e.g., by error of the financial institution) in the amount of 0.3 % of the amount due for each day of delay. The agreement regarding the contractual penalty shall not affect the Landlord’s entitlement to demand compensation for damages. Both entitlements can be exercised by the Landlord concurrently. Both the contractual penalty and the interest on late payments are to be paid via a separate bank transfer to the Landlord’s account stated in Article I in the “Landlord” section hereof (separately from the price for the accommodation).

  • Interest; Penalties In the event the Company or any Sponsor Affiliate should fail to make any of the payments to the County required under this Fee Agreement, then the item or installment so in default shall continue as an obligation of the Company or such Sponsor Affiliate until the Company or such Sponsor Affiliate shall have fully paid the amount, and the Company and any Sponsor Affiliates agree, as applicable, to pay the same with interest thereon at a rate, unless expressly provided otherwise herein and in the case of FILOT payments, of 5% per annum, compounded monthly, to accrue from the date on which the payment was due and, in the case of FILOT payments, at the rate for non-payment of ad valorem taxes under State law and subject to the penalties the law provides until payment.

  • Payment of Non-compliance Penalties j) Subject to Clause (i) above, the Service Provider shall pay the Non-compliance Penalty indicated in the Non-compliance Penalty Certificate within 10 (ten) Business Days of Transnet issuing a valid Tax Invoice to the Service Provider for the amount set out in that certificate. If Transnet does not issue a valid Tax Invoice to the Service Provider for Non-compliance Penalties accrued during any relevant period, those Non-compliance Penalties shall be carried forward to the next period.

  • Judgments; Penalties One or more fines, penalties or final judgments, orders or decrees for the payment of money in an amount, individually or in the aggregate, of at least Two Hundred Fifty Thousand Dollars ($250,000.00) (not covered by independent third-party insurance as to which liability has been accepted by such insurance carrier) shall be rendered against Borrower by any Governmental Authority, and the same are not, within ten (10) days after the entry, assessment or issuance thereof, discharged, satisfied, or paid, or after execution thereof, stayed or bonded pending appeal, or such judgments are not discharged prior to the expiration of any such stay (provided that no Credit Extensions will be made prior to the satisfaction, payment, discharge, stay, or bonding of such fine, penalty, judgment, order or decree);

  • Fines and Penalties Qwest shall be liable to pay to CLEC fines and penalties for resold services in accordance with the Commission's retail service requirements that apply to Qwest retail services, if any. Such credits shall be limited in accordance with the following:

  • Submitting False Claims; Monetary Penalties The AOC shall be entitled to remedy any false claims, as defined in California Government Code section 12650 et seq., made to the AOC by the Contractor or any Subcontractor under the standards set forth in Government Code section 12650 et seq. Any Contractor or Subcontractor who submits a false claim shall be liable to the AOC for three times the amount of damages that the AOC sustains because of the false claim. A Contractor or Subcontractor who submits a false claim shall also be liable to the AOC for (a) the costs, including attorney fees, of a civil action brought to recover any of those penalties or damages, and (b) a civil penalty of up to $10,000 for each false claim.

  • Premium Taxes If premium taxes are incurred, they will be deducted from the contract accumulation, to the extent permitted by law.

Time is Money Join Law Insider Premium to draft better contracts faster.