Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.
Insignificant Changes No adjustment in the Purchase Price shall be required unless such adjustment would require an increase or decrease of at least 1% in the Purchase Price. Any adjustments which by reason of this Section 11.5 are not required to be made shall be carried forward and taken into account in any subsequent adjustment. All calculations under this Section 11 shall be made to the nearest cent or to the nearest one-hundred thousandth of a Preferred Share or the nearest one-hundredth of a Common Share or other share or security, as the case may be.
Permitted Delays The Company shall be entitled to postpone the filing of any Registration Statement under Section 2.3 if (i) at any time prior to the filing of such Registration Statement the Board of Directors of the Company determines, in its good faith business judgment, that such registration and offering would materially and adversely affect any financing, acquisition, corporate reorganization or other material transaction involving the Company, and (ii) the Company delivers the Holders requesting such registration written notice thereof within 10 business days of the date of receipt of such request; provided, that all such periods of postponement may not exceed 45 days during any 365-day period.
Significant Non-Compliance a) A Competent Authority shall notify the Competent Authority of the other Party when the first-mentioned Competent Authority has determined that there is significant non-compliance with the obligations under this Agreement with respect to a Reporting Financial Institution in the other jurisdiction. The Competent Authority of such other Party shall apply its domestic law (including applicable penalties) to address the significant non-compliance described in the notice.
Termination Due to Force Majeure Event If the period of Force Majeure continues or is in the reasonable judgment of the Parties likely to continue beyond a period of 120 (one hundred and twenty) Days, the Parties may mutually decide to terminate this Agreement or continue this Agreement on mutually agreed revised terms. If the Parties are unable to reach an agreement in this regard, the Affected Party shall after the expiry of the said period of 120 (one hundred and twenty ) Days be entitled to terminate the Agreement in which event, the provisions of Articles 16 and 17 shall, to the extent expressly made applicable, apply.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:
Termination due to Force Majeure 13.5.1 If the Force Majeure Event or its effects continue to be present beyond the period as specified in Article 4.5.3, either Party shall have the right to cause termination of the Agreement. In such an event, this Agreement shall terminate on the date of such Termination Notice.
