Signage All signs, notices and graphics of every kind or character, visible in or from public corridors, the Building Common Area or the exterior of the Premises shall be subject to Landlord’s prior written approval, not to be unreasonably withheld, conditioned or delayed. Without limiting the foregoing and subject to Landlord’s prior approval of the plans and specifications thereof (including, without limitation, the design, location, and size), Tenant shall have the right (“Exterior Signage Rights”) to install tenant identification signage on the exterior of the Building (the “Sign”), at Tenant’s sole cost and expense and in accordance with all applicable Laws (including any requirements set forth by the applicable agencies in the City and County of San Francisco) (the “Signage Requirements”). Tenant shall erect the Sign in accordance with the plans and specifications approved by Landlord, in a good and workmanlike manner, and at all times thereafter, Tenant shall maintain, at its sole cost and expense, the Sign in a good, clean and safe condition and in accordance with the Signage Requirements, including all repairs and replacements thereto. Upon the occurrence of any event of default and/or upon the termination or earlier expiration of this Lease, Tenant shall promptly remove the Sign, in which event Tenant shall be responsible for and shall repair any damage to the Building resulting therefrom. Tenant’s Exterior Signage Rights hereunder are personal to Dolby California, and, except with respect to an assignment to a Tenant Affiliate or Dolby Entity in connection with an assignment of this Lease, may not be assigned or transferred without the prior written consent of Landlord, which consent may be given or withheld or given upon conditions in Landlord’s sole and absolute discretion. Tenant shall be responsible for obtaining all permits and approvals (governmental and private) necessary for the installation and maintenance of the Sign. If Tenant fails to remove the Sign as required under this Section 32, Landlord shall have the right, at Tenant’s expense, to remove the Sign. Tenant shall indemnify, defend and protect Landlord and the Landlord Parties and hold Landlord and the Landlord Parties harmless from and against any and all, proceedings, losses, costs, damages, causes of action, liabilities, injuries or expenses arising out of or related to Tenant’s exercise of the Exterior Signage Rights granted hereunder, including, without limitation, any claims of injury to or death of persons or damage to property occurring or resulting directly or indirectly from the installation or maintenance of the Sign on the Building.
Meal Plan The Student who resides in a university residence hall is required to purchase a full residential dining plan (commuter plans are not acceptable). The Student who resides in Bobcat Village may choose either a residential or a commuter plan, but is not obligated to make a dining plan purchase due to availability of kitchen in each apartment unit.
Monument Signage Tenant shall have the right to have its logo listed on the monument sign for the Building (the “Monument Sign”), subject to the terms of this Section 23. The design, size and color of Tenant’s signage with Tenant’s logo to be included on the Monument Sign, and the manner in which it is attached to the Monument Sign, shall comply with all Applicable Laws and shall be subject to the reasonable approval of Landlord and any applicable governmental authorities. Landlord reserves the right to withhold consent to any signage that, in the reasonable judgment of Landlord, is not harmonious with the design standards of the Building and Monument Sign. Landlord shall have the right to require that all names or logos on the Monument Sign be of the same size and style. Tenant must obtain Landlord’s written consent to any proposed signage and lettering or logo design prior to its fabrication and installation. The location of Tenant’s logo on the Monument Sign shall be subject to Landlord’s reasonable approval. To obtain Landlord’s consent, Tenant shall submit design drawings to Landlord showing the type and sizes of all lettering; the colors, finishes and types of materials used; and (if applicable and Landlord consents in its reasonable discretion) any provisions for illumination. Although the Monument Sign will be maintained by Landlord, Tenant shall pay its proportionate share of the cost of any maintenance and repair associated with the Monument Sign. Tenant’s signage on the Monument Sign shall be designed, constructed, installed, insured, maintained, repaired and removed from the Monument Sign all at Tenant’s sole risk, cost and expense. Landlord shall be responsible for the maintenance, repair or replacement of Tenant’s signage on the Monument Sign, the cost of which shall be included in Operating Expenses. Landlord may, at any time during the Term (or any extension thereof), upon five (5) business days prior written notice to Tenant, relocate the position of Tenant’s signage on the Monument Sign (provided that if Tenant is the sole tenant on the monument sign, Landlord shall make no such relocation without Tenant’s prior written consent, which consent shall not be unreasonably withheld) without materially impairing its visibility. The cost of such relocation shall be at the cost and expense of Landlord. The rights provided in this Section 23 shall be non-transferable unless otherwise agreed by Landlord in writing in its sole discretion.
Site Plan It is Licensee’s responsibility before signing this Agreement to ensure that the Site Plan correctly shows the work that Licensee intends to perform, that the Site Plan correctly shows all improvements and equipment that Licensee intends be located on the Use Areas, that the Site Plan shows no work, improvements or equipment outside the Exclusive Areas and Shared Areas properly depicted and labeled on the Boundary Plan, and that all work, improvements and equipment is encompassed within the purposes enumerated in the Standard Terms for that particular Exclusive Area or Shared Area. Any work, improvements or equipment not conforming to all the foregoing is prohibited, even if it is clearly shown on the Site Plan or discussed in the Standard Terms. Any refinement or other change to the Site Plan after Licensor executes this Agreement is void unless Licensee obtains Licensee’s approval of the change pursuant to the plans approval processes set out in the Standard Terms and pursuant to all applicable regulatory requirements.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Exterior Signage Provided Tenant is then in compliance with the below-listed conditions, Tenant shall have the non-exclusive right at its sole cost and expense, to install, maintain, repair and replace one (1) tenant illuminated (if and to the extent permitted by law) identification sign consisting of the name of Tenant (the “Exterior Signage”) (which shall be for the exclusive use of Tenant) on the exterior of the Building in a location to be designated by Landlord and approved by Tenant, which approval shall not be unreasonably withheld, conditioned, or delayed, provided that (a) no Monetary Default of Tenant has occurred hereunder and is then continuing, and (b) such Exterior Signage is in compliance with all applicable laws, codes and ordinances, and Tenant has obtained all governmental permits and approvals requited in connection therewith, and (c) Tenant is leasing and occupying at least 25,000 rentable square feet of space in the Building throughout the Lease Term. The size and the appearance of the Exterior Signage shall be subject to the prior approval of Landlord, which approval shall not unreasonably be withheld, conditioned or delayed. The installation, maintenance and removal of such Exterior Signage shall be performed at Tenant’s expense in accordance with the terms and conditions governing alterations pursuant to Section 9 of the Lease. Notwithstanding the foregoing provisions of this Section XI to the contrary, within thirty (30) days after the date on which (i) there occurs, and remains uncured, a Monetary Default of Tenant (beyond applicable notice and period of cure), (ii) Imprivata, Inc. (or an Affiliate or successor to Tenant by Ownership Change) is no longer leasing at least 25,000 rentable square feet in the Building, or (iii) the Term of the Lease expires or is terminated, then Tenant shall, at its cost and expense, remove the Exterior Signage and restore all damage to the Building caused by the installation and/or removal of such Exterior Signage, which removal and restoration shall be performed in accordance with the terms and conditions governing alterations pursuant to Section 9 of the Lease. The right to the Exterior Signage granted pursuant to this Section XI is personal to Imprivata, Inc. (and its Affiliates or successor to Tenant by Ownership Change) and may not be exercised by any occupant, subtenant, or other assignee of Imprivata, Inc., other than an Affiliate or successor to Tenant by Ownership Change. Landlord shall cooperate with Tenant’s efforts to obtain any permit or approval required or desirable in connection with the installation of the Exterior Signage, and Tenant shall reimburse Landlord for its reasonable third party out-of-pocket costs incurred in connection with providing such cooperation.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Improvement Plan A written plan developed by the evaluator, utilized when a teacher received a Rating of Ineffective on his/her Evaluation or on any individual deficiency in the evaluation system.
Final Plans No later than thirty (30) days following the approval of the Preliminary Plans, Tenant shall submit to Landlord a proposed set of Final Plans for approval by Landlord. Landlord’s approval of such proposed Final plans shall not be unreasonably withheld, conditioned or delayed, provided that (a) the Tenant Improvements, as set forth on such plans, comply with all applicable governmental laws, codes, rules, and regulations, and (b) such plans are sufficiently detailed to allow construction of the Tenant Improvements in a good and workmanlike manner. Landlord shall advise Tenant of Landlord’s approval or disapproval of the proposed Final Plans. If Landlord disapproves any aspect of the proposed Final Plans, Landlord shall so notify Tenant and specify how any such disapproved item may be made acceptable to Landlord. The proposed Final Plans shall then be revised and re-submitted to Landlord and Landlord and Tenant shall agree upon and sign the Final Plans as soon as reasonably practicable. The proposed Final Plans will be deemed to be complete and become the Final Plans upon execution thereof by Landlord and Tenant, and thereupon such Final Plans shall be deemed to be a part of this Lease and incorporated into this Lease by reference. Approval by Landlord of the Final Plans shall not be a representation or warranty of Landlord that such plans are adequate for any use, purpose, or condition, or that such plans comply with any applicable law or code, but shall merely be the consent of Landlord to the Final Plans. All changes in the Final Plans must receive the prior written approval of Landlord, and in the event of any such approved change, Tenant shall, upon completion of the Tenant Improvements, furnish Landlord with an accurate, reproducible “as-built” plan of the Tenant Improvements as constructed.
Improvement Plans A. A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.