Settlement Proposal. After termination, Design-Builder shall submit a final termination settlement proposal to Department in the form and with the certification prescribed by Department. Design-Builder shall submit the proposal promptly, but no later than thirty (30) days from the effective date of termination unless Design-Builder has requested a time extension in writing within such 30-day period and Department has agreed in writing to allow such an extension.
Settlement Proposal. After termination under this Article 8, or for any other category of termination for which the Contract Documents expressly permit Design-Builder to recover under this Article 8, Design-Builder shall submit a final termination settlement proposal to Department in the form and with the certification prescribed by Department. Design-Builder shall submit the proposal promptly, but no later than ninety (90) days from the effective date of termination unless Design-Builder has requested a time extension in writing within such ninety (90)-day period and Department has agreed in writing to allow such an extension.
Settlement Proposal. After receipt of a Notice of Termination, the DB Contractor shall submit a final termination settlement proposal to the District in the form and with the certification prescribed by the District. The DB Contractor shall submit the proposal promptly, but no later than 1 year from the effective date of termination, unless the DB Contractor has requested a time extension in writing within such period and the District has agreed in writing to allow such an extension. The District will then review the DB Contractor’s termination settlement proposal and will act upon it, return it with comments or reject it. If the DB Contractor fails to submit the proposal within the time allowed, the District may determine, on the basis of information available to it, the amount, if any, due to the DB Contractor because of the termination and shall pay the DB Contractor the amount so determined.
Settlement Proposal. Each party shall present an overall settlement proposal to the arbitrator which shall encompass all issues to be resolved. The two proposals shall set the outer limits of the range within which the arbitrator can make a determination as to the appropriate settlement result. All costs of the arbitration process shall be borne by the party determined by the arbitrator to have lost the arbitration. In the event the arbitrator makes a determination which reflects a 50-50 settlement, the Seller and the Purchaser shall share equally the costs of the arbitration. In the event the arbitrator makes a determination which reflects a divided settlement, the arbitrator shall determine the proportion in which the parties shall share the costs of arbitration.
Settlement Proposal. Section 13.04(a).
Settlement Proposal. After receipt of a Notice of Termination, Design/Builder shall submit a final termination settlement proposal to the Alamo RMA in the form and with the certification prescribed by the Alamo RMA. Design/Builder shall submit the proposal promptly, but no later than 90 Days from the effective date of termination unless Design/Builder has requested a time extension in writing within such 90-Day period and the Alamo RMA has agreed in writing to such extension. If Design/Builder fails to submit the proposal within the time allowed, the Alamo RMA may conclusively determine, on the basis of information available to it, the amount, if any, due Design/Builder because of the termination and shall pay Design/Builder the amount so determined. The provisions of Section 17 shall govern any termination of this Agreement as a result of an Event of Default.
Settlement Proposal. This Contract represents OWNER’s settlement proposal and is expressly subject to and contingent upon acceptance and approval of SBCAG’s Board of Directors. SBCAG shall not be bound to the terms and conditions herein unless and until this Contract has been approved and ratified by the SBCAG Board of Directors.
Settlement Proposal. 93 14.6 Amount of Negotiated Termination Settlement Amount ...................... 94
Settlement Proposal. After receipt of a Notice of Termination or Notice of Partial Termination for Convenience, Maintenance Contractor shall submit a final termination settlement proposal to TxDOT in the form and with the certification prescribed by TxDOT. Texas Department of Transportation Execution Version Horseshoe Project 94 Capital Maintenance Agreement Maintenance Contractor shall submit the proposal promptly, but no later than 90 Days from the effective date of termination unless Maintenance Contractor has requested a time extension in writing within such 90-Day period and TxDOT has agreed in writing to such extension. Maintenance Contractor’s termination settlement proposal shall then be reviewed by TxDOT and acted upon, returned with comments, or rejected. If Maintenance Contractor fails to submit the proposal within the time allowed, TxDOT may conclusively determine, on the basis of information available to it, the amount, if any, due Maintenance Contractor because of the termination and shall pay Maintenance Contractor the amount so determined.
Settlement Proposal a) Aclima will replenish its security deposit in the amount of $109,715.60 in the aggregate for the 3 leases as Port has applied all the security deposit under each of the 3 leases.
