Separate Work Sample Clauses

Separate Work. Owner will perform, either with its own forces or through other contractors and subcontractors, the activities described as Work or services to be provided by or on behalf of Owner or the Separate Contractors and as work or services to be provided by Owner in Appendix A.
AutoNDA by SimpleDocs
Separate Work. Owners reserve the right to perform either with its own forces or through other contractors and subcontractors construction or operations related to the Work or the Unit as part of the Work or any other construction or other work at the Job Site or the Big Stone Site.
Separate Work. PSGC will perform, either with its own forces or through other contractors and subcontractors, the activities described in Appendix B.

Related to Separate Work

  • Outside Work All work necessary to the assembling, installation, erection, operation, maintenance, repair, control, in- spection and supervision of all electrical apparatus, devices, wires, cables, supports, insulators, conduc- tors, ducts and raceways when part of distributing systems outside of buildings, railroads and outside the directly related railroad property and yards. In- stalling and maintaining the catenary and trolley work on railroad property, and bonding of rails. All underground ducts and cables when they are in- stalled by and are part of the system of a distrib- uting company, except in power stations during new construction, including ducts and cables to adjacent switch racks or substations. All outdoor substations and electrical connections up to and including the setting of transformers and the connecting of the secondary buses thereto. Outside work to include renewable electrical energy sources such as solar photovoltaic, geothermal, wind, biomass, wave, etc., and other distributed en- ergy installations such as fuel cells, microturbines, etc.

  • EMPLOYEE WORK YEAR A. In-School Work Year

  • Extra Work At any time during the Term of this Agreement, City may request that Consultant perform Extra Work. As used herein, “Extra Work” means any work which is determined by City to be necessary for the proper completion of the Project, but which the Parties did not reasonably anticipate would be necessary at the execution of this Agreement. Consultant shall not perform, nor be compensated for, Extra Work without written authorization from City’s Representative.

  • Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.

  • Employee Workload ‌ The Employer shall ensure that an employee’s workload is not unsafe as a result of employee absence(s). Employees may refer safety related workload concerns to the Occupational Health and Safety Committee for investigation under Article 22.3 (Occupational Health and Safety Committee).

  • Creative Work The Executive agrees that all creative work and work product, including but not limited to all technology, business management tools, processes, software, patents, trademarks, and copyrights developed by the Executive during the term of this Agreement, regardless of when or where such work or work product was produced, constitutes work made for hire, all rights of which are owned by the Employer. The Executive hereby assigns to the Employer all rights, title, and interest, whether by way of copyrights, trade secret, trademark, patent, or otherwise, in all such work or work product, regardless of whether the same is subject to protection by patent, trademark, or copyright laws.

  • Shift Work Shift work is work not in excess of ordinary hours (ie 38 hours per week), but carried out wholly or partly between the hours of 7.00pm and 7.00am, Monday to Friday. Shift work is work scheduled at least 24 hours prior to the commencement of the shift. Employees required to work shift work will be paid at time and one quarter of the ordinary rate per hour for ordinary hours worked.

  • Contractor’s Project Manager and Key Personnel Contractor shall appoint a Project Manager to direct the Contractor’s efforts in fulfilling Contractor’s obligations under this Contract. This Project Manager shall be subject to approval by the County and shall not be changed without the written consent of the County’s Project Manager, which consent shall not be unreasonably withheld. The Contractor’s Project Manager shall be assigned to this project for the duration of the Contract and shall diligently pursue all work and services to meet the project time lines. The County’s Project Manager shall have the right to require the removal and replacement of the Contractor’s Project Manager from providing services to the County under this Contract. The County’s Project manager shall notify the Contractor in writing of such action. The Contractor shall accomplish the removal within five (5) business days after written notice by the County’s Project Manager. The County’s Project Manager shall review and approve the appointment of the replacement for the Contractor’s Project Manager. The County is not required to provide any additional information, reason or rationale in the event it The County is not required to provide any additional information, reason or rationale in the event it requires the removal of Contractor’s Project Manager from providing further services under the Contract.

  • Improvement Plans A. A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.

  • Complete Work without Extra Cost Except to the extent otherwise specifically stated in this contract, the Contractor shall obtain and provide, without additional cost to the City, all labor, materials, equipment, transportation, facilities, services, permits, and licenses necessary to perform the Work.

Time is Money Join Law Insider Premium to draft better contracts faster.