Non-Liability Except (and only if and) to the extent directly caused by the willful misconduct or gross negligence of Landlord or Agent or any other Indemnitee, none of Landlord, Agent, any other managing agent, or their respective affiliates, owners, partners, directors, officers, agents and employees shall be liable to Tenant for any loss, injury, or damage, to Tenant or to any other person, or to its or their property, irrespective of the cause of such injury, damage or loss. Further, except (and only if and) to the extent directly caused by the willful misconduct or gross negligence of Landlord or Agent or any other Indemnitee, none of Landlord, Agent, any other managing agent, or their respective affiliates, owners, partners, directors, officers, agents and employees shall be liable to Tenant (a) for any damage caused by other persons in, upon or about the Premises, or caused by operations in construction of any public or quasi-public work; (b) with respect to matters for which Landlord is liable, for consequential or indirect damages purportedly arising out of any loss of use of the Premises or any equipment or facilities therein by Tenant or any person claiming through or under Tenant; (c) for any defect in the Premises; (d) for injury or damage to person or property caused by fire, or theft, or resulting from the operation of HVAC or lighting apparatus, or from falling plaster, or from steam, gas, electricity, water, rain, snow, ice, or dampness, that may leak or flow from any part of the Premises, or from the pipes, appliances or plumbing work of the same.
Certain Liabilities To the Credit Parties’ best knowledge, none of the present or previously owned or operated Property of any Credit Party or of any Subsidiary thereof, wherever located, (i) has been placed on or proposed to be placed on the National Priorities List, the Comprehensive Environmental Response Compensation Liability Information System list, or their state or local analogs, or have been otherwise investigated, designated, listed, or identified as a potential site for removal, remediation, cleanup, closure, restoration, reclamation, or other response activity under any Environmental Laws; (ii) is subject to a Lien, arising under or in connection with any Environmental Laws, that attaches to any revenues or to any Property owned or operated by any Credit Party, wherever located, which could reasonably be expected to cause a Material Adverse Change; or (iii) has been the site of any Release of Hazardous Substances or Hazardous Wastes from present or past operations which has caused at the site or at any third-party site any condition that has resulted in or could reasonably be expected to result in the need for Response that could cause a Material Adverse Change.
Indemnification Liability a. To the fullest extent permitted by law, Contractor agrees to defend, indemnify, and hold the City, its officers, agents, and employees, harmless from and against any and all liabilities, demands, claims, suits, losses, damages, causes of action, fines or judgments, including costs, attorneys’, witnesses’, and expert witnesses’ fees, and expenses incident thereto, relating to, arising out of, or resulting from: (i) the services provided by Contractor personnel under this Agreement; (ii) any negligent acts, errors, mistakes or omissions by Contractor or Contractor personnel; and (iii) Contractor or Contractor personnel’s failure to comply with or fulfill the obligations established by this Agreement.
Cap on Liability EXCEPT FOR EACH PARTY’S INDEMNITY OBLIGATIONS, AND YOUR PAYMENT OBLIGATIONS HEREUNDER, UNDER NO CIRCUMSTANCES WILL EITHER PARTY’S TOTAL LIABILITY OF ALL KINDS ARISING OUT OF OR RELATED TO THIS MSA (INCLUDING TO WARRANTY CLAIMS), REGARDLESS OF THE FORUM AND REGARDLESS OF WHETHER ANY ACTION OR CLAIM IS BASED ON CONTRACT, TORT, OR OTHERWISE, EXCEED THE TOTAL AMOUNT PAID BY YOU TO US DURING THE 12 MONTHS IMMEDIATELY PRECEDING THE CLAIM (DETERMINED AS OF THE DATE OF ANY FINAL JUDGMENT IN AN ACTION). UNDER NO CIRCUMSTANCES WILL OUR TOTAL LIABILITY OF ALL KINDS ARISING OUT OF OR RELATED TO OUR INDEMNITY OBLIGATIONS EXCEED THREE TIMES THE TOTAL AMOUNT PAID BY YOU TO US DURING THE 12 MONTHS IMMEDIATELY PRECEDING THE CLAIM (DETERMINED AS OF THE DATE OF ANY FINAL JUDGMENT IN AN ACTION).
Termination Liability In the event of termination pursuant to this Article 23.1, subject to Article 23.1.3, Purchaser shall be entitled to refund by Contractor of all payments made by Purchaser for the terminated Work plus interest thereon at the interest rate stipulated in Article 5.3.1 hereof from the date payment was received to the date the refund is received (provided, however, in the case of termination in part, the Parties shall negotiate an equitable refund amount to be paid by Contractor to Purchaser for the portion of the Work so terminated). In addition, Purchaser shall be entitled to payment of any liquidated damages for delay accrued prior to the effective date of termination pursuant to Article 22. Contractor shall pay the foregoing amounts no later than thirty (30) days after Contractor’s receipt of Purchaser’s written notice requesting such amounts. Payment of such amounts shall be Purchaser’s sole remedy in case of a termination pursuant to this Article 23.1. Upon payment in full of all amounts due in accordance with the preceding sentences of this Article 23.1.2, any Security Interest or other right or interest that Purchaser has in the terminated Deliverable Items, Raw Materials, Work-in-Process and Finished Goods (except with respect to Deliverable Items retained by Purchaser pursuant to Article 23.1.3) hereunder or otherwise shall be released and extinguished and Purchaser shall take all action reasonably requested by Contractor to terminate any document or instrument filed of record (including without limitation UCC financing statements) to perfect any such Security Interest.
Our Liability Except as specifically provided for in this Agreement or where the law requires a different standard, you agree that neither the Bank nor the Internet Service Provider shall be responsible for any loss, property damage or bodily injury, whether caused by the Bank, equipment, software, or Internet access providers or any agent or subcontractor of any of the foregoing. Nor shall the Bank or the Internet Service Providers be responsible for any direct, indirect, special or consequential, economic, or other damages arising in any way out of the installation, use or maintenance of the equipment, software or Internet browser, or access software.
Limits on Liability EXCEPT FOR THE INDEMNIFICATION PROVISIONS HEREIN THIS AGREEMENT, NEITHER PARTY IS LIABLE UNDER THIS AGREEMENT FOR ANY LOST PROFITS, LOSS OF DATA, OR ANY INCIDENTAL, INDIRECT, OR CONSEQUENTIAL DAMAGES, EXCEPT FOR ANY WILLFUL UNAUTHORIZED DISCLOSURE OF CONFIDENTIAL INFORMATION OR LICENSEE’S WILLFUL BREACH. EXCEPT FOR THE INDEMNIFICATION PROVISIONS HEREIN, LICENSOR’S AGGREGATE LIABILITY IN CONNECTION WITH THIS AGREEMENT UNDER ANY THEORY OF LIABILITY (INCLUDING BREACH OF CONTRACT OR INDEMNITY) IS LIMITED TO THE AGGREGATE OF FEES PAID BY LICENSEE TO LICENSOR. UNDER NO CIRCUMSTANCES WILL LICENSOR (OR ITS AGENTS) HAVE LIABILITY RELATING TO PRODUCT USED OR DISTRIBUTED BY LICENSOR OR BY THIRD PARTIES.
Limit on Liability In acting under this Agreement, the Registrar and any Paying Agent are acting solely as agents of the Province and do not assume any obligation or relationship of agency or trust for or with any of the registered holders of the Bonds, except that all funds held by the Registrar or any Paying Agent for payment of principal or interest shall be held in trust for the registered holders of the Bonds as provided in this Agreement.
Entire Liability THE FOREGOING PROVISIONS OF THIS SECTION 5 STATE THE ENTIRE LIABILITY AND OBLIGATIONS OF LICENSOR AND THE EXCLUSIVE REMEDY OF LICENSEE AND ANY OTHER ENTITY, WITH RESPECT TO ANY ALLEGED INFRINGEMENT OF INTELLECTUAL PROPERTY RIGHTS.
Your Liability Tell us at once if you believe your card and/or code has been lost or stolen or if you believe that an EFT has been made without your permission using information from your personal check. Telephoning is the best way of keeping your possible losses down. You could lose all the money in your account (plus your maximum overdraft line of credit). If you tell us within two (2) business days after you learn of the loss or theft of your card and/or code, you can lose no more than $50 if someone used your card and/or code without your permission. Also, if you do NOT tell us within two (2) business days after you learn of the loss or theft of your card and/or code, and we can prove we could have stopped someone from using your card and/or code without your permission if you had told us, you could lose as much as $500. If your statement shows transfers that you did not make, including those made by card, code or other means, tell us at once. If you do not tell us within sixty (60) days after the statement was mailed to you, you may not get back any money you lost after the sixty (60) days if we can prove that we could have stopped someone from taking the money if you had told us in time. If a good reason (such as a long trip or a hospital stay) kept you from telling us, we will extend the time period.