Increase (a) The Company may by giving prior notice to the Agent by no later than the date falling 20 Business Days after the effective date of a cancellation of: (i) the Available Commitments of a Defaulting Lender in accordance with Clause 9.5 (Right of cancellation in relation to a Defaulting Lender); or (ii) the Commitments of a Lender in accordance with Clause 9.1 (Illegality), request that the Total Commitments be increased (and the Total Commitments shall be so increased) in an aggregate Base Currency Amount of up to the amount of the Available Commitments or Commitments so cancelled as follows: (iii) the increased Commitments will be assumed by one or more Lenders or other banks, financial institutions, trusts, funds or other entities (each an “Increase Lender”) selected by the Company (each of which shall not be an Investor Affiliate or a member of the Group) and which is further acceptable to the Agent (acting reasonably) and each of which confirms its willingness to assume and does assume all the obligations of a Lender corresponding to that part of the increased Commitments which it is to assume, as if it had been an Original Lender; (iv) each of the Obligors and any Increase Lender shall assume obligations towards one another and/or acquire rights against one another as the Obligors and the Increase Lender would have assumed and/or acquired had the Increase Lender been an Original Lender; (v) each Increase Lender shall become a Party as a “Lender” and any Increase Lender and each of the other Finance Parties shall assume obligations towards one another and acquire rights against one another as that Increase Lender and those Finance Parties would have assumed and/or acquired had the Increase Lender been an Original Lender; (vi) the Commitments of the other Lenders shall continue in full force and effect; and (vii) any increase in the Total Commitments shall take effect on the date specified by the Company in the notice referred to above or any later date on which the conditions set out in paragraph (b) below are satisfied. (b) An increase in the Total Commitments will only be effective on: (i) the execution by the Agent of an Increase Confirmation from the relevant Increase Lender; (ii) in relation to an Increase Lender which is not a Lender immediately prior to the relevant increase: (A) the Increase Lender entering into the documentation required for it to accede as a party to the Intercreditor Agreement; and (B) the performance by the Agent of all necessary “know your customer” or other similar checks under all applicable laws and regulations in relation to the assumption of the increased Commitments by that Increase Lender, the completion of which the Agent shall promptly notify to the Company and the Increase Lender. (c) Each Increase Lender, by executing the Increase Confirmation, confirms (for the avoidance of doubt) that the Agent has authority to execute on its behalf any amendment or waiver that has been approved by or on behalf of the requisite Lender or Lenders in accordance with this Agreement on or prior to the date on which the increase becomes effective. (d) Unless the Agent otherwise agrees or the increased Commitment is assumed by an existing Lender, the Company shall, on the date upon which the increase takes effect, pay to the Agent (for its own account) a fee of £1,500 and the Company shall within three (3) Business Days of demand pay the Agent and the Security Agent the amount of all reasonable and documented costs and expenses (including legal fees) reasonably incurred by either of them and, in the case of the Security Agent, by any Receiver or Delegate in connection with any increase in Commitments under this Clause 2.2. (e) The Company may pay to the Increase Lender a fee in the amount and at the times agreed between the Company and the Increase Lender in a Fee Letter. (f) Clause 27.4 (Limitation of responsibility of Existing Lenders) shall apply mutatis mutandis in this Clause 2.2 in relation to an Increase Lender as if references in that Clause to: (i) an “Existing Lender” were references to all the Lenders immediately prior to the relevant increase; (ii) the “New Lender” were references to that “Increase Lender”; and (iii) a “re-transfer” and “re-assignment” were references to respectively a “transfer” and “assignment”.
Reduction A. No regular employee or limited-term regular employee shall be reduced to a position in a lower class for reasons of unsatisfactory performance or physical disability except for reasonable cause. B. A written notice of such reduction stating specifically the cause of the reduction shall be given to the employee. C. In accordance with the provisions of Article X, an appeal of reduction for reasons of unsatisfactory performance or physical disability shall be initiated at the Step 2 of the grievance/appeal procedure; except for reductions imposed by the County Executive Officer which may be referred directly to arbitration.
Optional Reductions The Borrower may, upon notice to the Administrative Agent, terminate the Aggregate Revolving Commitments, or from time to time permanently reduce the Aggregate Revolving Commitments to an amount not less than the Outstanding Revolving Amount of Revolving Loans, Swing Line Loans and L/C Obligations; provided that (i) any such notice shall be received by the Administrative Agent not later than 1:00 p.m., five (5) Business Days prior to the date of termination or reduction, (ii) any such partial reduction shall be in an aggregate amount of $2,000,000 or any whole multiple of $1,000,000 in excess thereof and (iii) the Borrower shall not terminate or reduce (A) the Aggregate Revolving Commitments if, after giving effect thereto and to any concurrent prepayments hereunder, the Total Revolving Outstandings would exceed the Aggregate Revolving Commitments, (B) the Letter of Credit Sublimit if, after giving effect thereto, the Outstanding Revolving Amount of L/C Obligations not fully Cash Collateralized hereunder would exceed the Letter of Credit Sublimit, or (C) the Swing Line Sublimit if, after giving effect thereto and to any concurrent prepayments hereunder, the Outstanding Revolving Amount of Swing Line Loans would exceed the Swing Line Sublimit.
Add is unable to take full responsibility for the adequacy, stability and safety of all Site operations and methods of construction as stipulated in sub-clause 8.2 of the conditions of contract. a) Fails to comply with Subclause 10.1 and 10.2 of the Conditions of Contract b) Fails to comply with Sub-Clause 14.2 and Sub-Clause 14.3 of the Conditions of Contract and Appendix to Form of Bid. c) Fails to observe the safety as stipulated in Subclause 19.1 and amendments therein. d) Fails to Conform to Service levels as detailed in the Appendix to Form of Bid and as required in subclause 13.1. e) Incurs the maximum amount of Liquidated damages as stated in the Appendix to Form of Bid or the liquidated damages amount, exceeds the performance security then the contract would be automatically Terminated. f) Has not completed the works despite the lapse of the Contract Period as stated in the Appendix to form of Bid SUBCLAUSE 67.1 – ENGINEER’S DECISION Delete the entire sub clause 67.1 and add the following; “If a dispute of any kind whatsoever arises between the Employer and the Contractor in any connection with, or arising out of, the Contract or the execution of the works, whether during the execution of the works or after their completion and whether before or after repudiation or other termination of the Contract including any dispute as to any opinion, instruction, determination, certificate or valuation of the Engineer, the matter in dispute shall, in the first place, be referred in writing to the Engineer, with a copy to the other party. Such reference shall state it is made pursuant to this clause. No later than 28 (twenty eight) day after the day on which he received such reference the Engineer shall give notice of his decision to the Employer and the Contractor. Such decision shall state it is made pursuant to this clause. Unless the Contract has already been repudiated or terminated, the Contractor shall, in every case, continue to proceed with the works with all due diligence and the Contractor and the Employer shall give effect forthwith to every such decision of the Engineer unless and until the same shall be revised, as hereinafter provided, in an Amicable Settlement, Adjudicator’s or Arbitrator’s award. If either the Employer or the Contractor be dissatisfied with the any decision of the Engineer, or if the Engineer fails to give notice of his decision on or before the 28th (twenty eighth) after the day on which he received the reference, then either the Employer or the Contractor may, on or before the 28th (twenty eighth) day after the day the day on which he received notice of such decision, or on or before the 28th (twenty eighth) day after the day the day on which the said period of 28 days expired, as the case may be, give notice to the other party, with a copy for information to the Engineer, of his intention to commence Adjudication, as hereinafter provided, as to the matter in dispute. Such notice shall establish the entitlement of the party giving the same to commence Adjudication, as hereinafter provided, as to such dispute; no adjudication in respect thereof may be commenced unless such notice is given. If the Engineer has given notice of his decision as to a matter in dispute to the Employer and the Contractor and no notice of intention to commence adjudication as to such dispute has been given by either the Employer or the Contractor on or before the twenty eighth day after the day on which the parties received notice as to such decision from the Engineer, the said decision shall become final and binding upon the Employer and the Contractor. “ SUBCLAUSE 67.2 – AMICABLE SETTLEMENT Delete the entire sub clause 67.2 and add the following; “Where notice to of intention to commence adjudication as to a dispute has been in accordance with sub clause 67.1, the parties shall attempt to settle such dispute in amicably before the commencement of Adjudication; provided that, unless the parties otherwise agree, Adjudication may be commenced on or after the 14th (fourteenth) day after the day on which notice of intention to commence adjudication of such dispute was given, even if an attempt at amicable settlement thereto has been made.” SUBCLAUSE 67.3 – ADJUDICATION Delete the entire sub clause 67.3 and add the following; “The Adjudicator shall be appointed by the Chartered Institute of Arbitrators (Kenya) unless the appointment is agreed by the parties within 7 (seven) days of the notice to adjudication. The adjudication process shall be conducted according to the Laws of Kenya and the Rules of the Chartered Institute of Arbitrators (Kenya).”
Commitment Reduction The Borrower shall have the right, upon at least two Business Days’ notice to the Administrative Agent, to terminate in whole or, upon same day notice, from time to time to permanently reduce ratably in part the unused portion of the Commitments; provided that each partial reduction shall be in the aggregate amount of $5,000,000 or in an integral multiple of $1,000,000 in excess thereof; provided, further, that the Commitments may not be reduced to an amount that is less than the aggregate Stated Amount of outstanding Letters of Credit. Subject to the foregoing, any reduction of the Commitments to an amount below $100,000,000 shall also result in a reduction of the L/C Commitment Amount to the extent of such deficit (with automatic reductions in the amount of each L/C Fronting Bank Commitment ratably in proportion to the amount of such reduction of the L/C Commitment Amount). Each such notice of termination or reduction shall be irrevocable. Without limiting subsection (b) below, any Commitment reduced or terminated pursuant to this subsection (a) may not be reinstated.