Payment Methodology The Contractor shall be compensated based on the Service Rates in Attachment for units of service authorized by the Institution in a total amount not to exceed the Contract Maximum Liability established in Section C.1. The Contractor’s compensation shall be contingent upon the satisfactory completion of units of service or project milestones identified in Attachment B. The Contractor shall submit invoices, in form and substance acceptable to the Institution with all of the necessary supporting documentation, prior to any payment. Such invoices shall be submitted for completed units of service or project milestones for the amount stipulated.
Payment Calculation District shall pay Contractor at a rate of $ per . OR District shall pay Contractor as described in attached Exhibit A
Payment Schedule Except as provided in section 6.10 Travel, Meals and Lodging, payments will only be made based on Deliverables outlined within the Authorized User Agreement. Any invoice not related directly to a completed deliverable will be rejected. Any charge included on the invoice without backup documentation as specified in the Authorized User Agreement (travel receipts, etc.) may be removed. Any outstanding charges un-invoiced or removed from the invoice must be submitted/resubmitted within 120 Calendar days or may not be reimbursed. Each Deliverable may contain a retainage allotment as specified within the Authorized User Agreement. Each invoice is to include a detailed and itemized list of all retainage withholds that are in place since the activation of the Authorized User Agreement. Payment schedule shall be based on the final Authorized User Agreement as negotiated by the Authorized User and Contractor. Payment is only to be made after the deliverable within the Authorized User Agreement is accepted by the Authorized User. A Contractor is encouraged to submit no more than one invoice per month. Invoices must include cumulative retainage holdback. Invoices submitted to an Authorized User must include backup documentation as defined in the negotiated Authorized User Agreement.
Payment Frequency As of the Cutoff Date and as shown on the books of CNHCA: (A) Receivables having an aggregate Statistical Contract Value equal to 76.22% of the Aggregate Statistical Contract Value had annual scheduled payments, (B) Receivables having an aggregate Statistical Contract Value equal to 2.94% of the Aggregate Statistical Contract Value had semi-annual scheduled payments, (C) Receivables having an aggregate Statistical Contract Value equal to 0.82% of the Aggregate Statistical Contract Value had quarterly scheduled payments, (D) Receivables having an aggregate Statistical Contract Value equal to 16.40% of the Aggregate Statistical Contract Value had monthly scheduled payments, and (E) Receivables having an aggregate Statistical Contract Value equal to 3.62% of the Aggregate Statistical Contract Value had irregularly scheduled payments.
Payment Amount Payment for the Services shall be as follows: (choose one) ☐ - $______________________ for the Services (“Payment”). ☐ - At an hourly rate of $____ per hour (“Payment”). ☐ - Other. ______________________________________________ (“Payment”) If the Subcontractor asserts a claim which involves, in whole or in part, acts or omissions which are the responsibility of the Client or another person for whom a claim may be submitted, including but not limited to, claims for failure to pay, an extension of time, impacts, delay damages, or extra work, the Contractor shall present the Subcontractor's claim to the Client or other responsible party provided the Subcontractor presents to Contractor competent supporting evidence and in sufficient time for the Contractor to do so. The Subcontractor shall cooperate fully with the Contractor in any and all steps the Contractor takes in connection with prosecuting such a claim and shall hold harmless and reimburse the Contractor for all expenses, including legal expenses, incurred by the Contractor which arise out of the Contractor's submission of the Subcontractor's claims to the Client or other responsible party(ies). The Subcontractor shall be bound by any adjudication or award in any action or proceeding resolving such a claim.
Payment Methods A. Except as otherwise provided by this Contract, the payment method will be one or more of the following:
Prompt Payment Schedule Except as otherwise provided by law or regulation or in Sections 504.4 and 504.5 of this Exhibit, the Date of Payment by NYSERDA of an amount properly due and owing under this Agreement shall be no later than thirty (30) calendar days, excluding legal holidays, after Receipt of a Proper Invoice.
Payment Plan Despite the payment terms in Annexure B, We may, but are not obliged to, enter into a specific payment plan with You if You can demonstrate a financial need. However, any payment plans:
Payment Structure You must pay the fees listed on the relevant Services Order. Subscription payments will be structured differently based on the term you select from the three options below and the payment structure will be set forth in the Services Order. The fees identified in the Services Order are exclusive of shipping fees, and you will pay the shipping fees (if applicable) identified in the invoice.
Payment of Fee The cash management fee referred to in Clause 9.1 (Fee Payable) shall only be payable to the Current Issuer Cash Manager on each Payment Date in the manner contemplated by, in accordance with and subject to the provisions of the Current Issuer Pre-Enforcement Revenue Priority of Payments or, as the case may be, the Current Issuer Post-Enforcement Priority of Payments.
