Partially Untenantable Sample Clauses

Partially Untenantable. If the Premises shall be rendered partially untenantable by reason of such occurrence, the Owner shall, at its own expense, cause the damage to be repaired and the Annual Base Rent for the part of the Premises rendered untenantable shall be abated proportionately on a square footage basis as long as said part remains untenantable. As used herein, “partially untenantable” shall mean that the Tenant is unable to use the Premises for the purposes leased for a period of ten (10) or more consecutive days.
AutoNDA by SimpleDocs
Partially Untenantable. If the Premises shall be rendered partially untenantable by reason of such occurrence, the Tenant shall promptly cause the damage to be repaired and the Premises restored to the condition and specifications which existed immediately prior to such occurrence in accordance with plans and specifications approved by the Owner, which approval shall not be unreasonably withheld, conditioned or delayed. Notwithstanding such partial untenantability, the rent shall not be abated unless the Tenant has purchased rent loss insurance pursuant to Section 9.02, above, in which case the rent shall be abated in an amount equal to the amount of rent loss insurance paid or payable to the Owner by reason of such occurrence. The Owner agrees that, to the extent proceeds from insurance are paid to the Owner, the Owner shall reimburse the Tenant for the actual costs paid by the Tenant to repair such damage.
Partially Untenantable. 32 Profit .................................................................... 35

Related to Partially Untenantable

  • DAMAGE OR DESTRUCTION OF PREMISES (a) If the Premises or any part thereof shall be damaged by fire or other insured casualty, then, subject to the last paragraph of this Section, Landlord shall proceed with diligence, subject to then applicable statutes, building codes, zoning ordinances and regulations of any governmental authority, and at the expense of Landlord (but only to the extent of insurance proceeds made available to Landlord by any mortgagee of the Building and any ground lessor) to repair or cause to be repaired such damage (other than any Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and Tenant Work, which Tenant shall promptly commence, and proceed with diligence, to restore). All such repairs made necessary by any act or omission of Tenant shall be made at the Tenant’s expense to the extent that the cost of such repairs are less than the deductible amount in Landlord’s insurance policy. All repairs to and replacements of Tenant Property not deemed to be fixtures covered by Landlord’s property insurance and any Initial Tenant Improvements and Tenant Work shall be made by and at the expense of Tenant. The cost of any repairs performed under this Section by Landlord at Tenant’s request and at Tenant’s expense (including costs of design fees, financing, and charges for administration, overhead and construction management services by Landlord and Landlord’s contractor) shall constitute Additional Rent hereunder. If the Premises or any part thereof shall have been rendered unfit for use and occupation hereunder by reason of such damage, the Base Rent or a just and proportionate part thereof, according to the nature and extent to which the Premises shall have been so rendered unfit, shall be abated until the Premises (except as to Tenant Property, Initial Tenant Improvements not deemed to be fixtures covered by Landlord’s property insurance and any Tenant Work) shall have been restored as nearly as practicable to the condition in which they were immediately prior to such fire or other casualty; and that if and to the extent Landlord shall be unable to collect the insurance proceeds (including rent insurance proceeds) applicable to such damage because of some action or inaction on the part of Tenant, or the employees, licensees or invitees of Tenant, the cost of repairing such damage shall be paid by Tenant and there shall be no abatement of rent. Landlord shall not be liable for delays in the making of any such repairs that are due to government regulation, casualties, and strikes, unavailability of labor and materials, delays in obtaining insurance proceeds, and other causes beyond the reasonable control of Landlord, nor shall Landlord be liable for any inconvenience or annoyance to Tenant or injury to the business of Tenant resulting from delays in repairing such damage. If the Premises or the Building are substantially damaged so as to prevent Tenant from using the Premises for the Permitted Use and the Premises have not been restored to the condition required pursuant to the terms of this Lease within two hundred and seventy (270) days following said casualty (or if such casualty occurs during the last 18 months of the term, within ninety (90) days after the date of such casualty), then Tenant may terminate this Lease upon thirty (30) days written notice to Landlord unless Landlord shall substantially complete such repair and restoration within such thirty (30) day period in which event Tenant’s termination shall be void and of no further force or effect.

  • Damage or Destruction If, during the Term of this Agreement, the entire Parking Facility or such portion thereof as shall render the Premises unsuitable for the continued conduct of the Tenant’s and its invitees activities thereon, shall be damaged or destroyed by fire or other casualty, then Landlord shall be entitled to retain all insurance proceeds payable by reason of and with respect to the damage or destruction to the Premises and Landlord shall rebuild or reconstruct the Parking Facility in a commercially reasonable and efficient manner subject to the following terms and conditions: (i) the casualty must be insured under Landlord's insurance policies, and Landlord’s obligation is limited to the extent of the insurance proceeds received by Landlord, (ii) Landlord’s duty to repair and restore the Premises shall not begin until receipt of the insurance proceeds, (iii) Landlord’s lender(s) must permit the insurance proceeds to be used for such repair and restoration, (iv) Landlord shall have no obligation to repair and restore any personal property on the Premises belonging to Tenant or any of Tenant’s employees, contractors, agents or invitees, (v) Landlord shall have no obligation to restore the damage or destruction (or to complete any restoration) during the last year of the Term or of any Option Period if Tenant has delivered notice that it is not renewing the Term of this Agreement pursuant to Section 2.2 or if Tenant has no more extension options pursuant to this Agreement, and (vi) Landlord shall rebuild or reconstruct the Parking Facility to a configuration substantially equivalent to that configuration which existed as of the Commencement Date. During the period in which the Parking is unavailable to a Tenant for any reason caused by Landlord during the Term of this Agreement for a period of more than thirty (30) consecutive days, including, without limitation, any such period during which Landlord is repairing and restoring the Parking Facility, the rental payable by Tenant shall xxxxx. The abatement of the rent shall be the exclusive remedy of Tenant against Landlord in the event of a casualty involving the Premises. Tenant hereby waives all claims against Landlord for any compensation or damage for loss of use of the whole or any part of the Premises and/or for any inconvenience or annoyance occasioned by any casualty and any resulting damage, destruction, repair, or restoration.

  • Damage or Destruction Condemnation 16.1. If the Hotel is damaged by fire or other casualty, Operator shall promptly notify Owner. This Agreement shall remain in full force and effect subsequent to such casualty provided that either party may terminate this Agreement upon thirty days’ prior written notice to the other party if (a) Owner shall elect to close the Hotel as a result of such casualty (except on a temporary basis for repairs or restoration) or (b) Owner shall determine in good faith not to proceed with the restoration of the Hotel; provided further, Operator may terminate this Agreement upon thirty days’ prior written notice to Owner if forty percent (40%) or more of the rooms in the Hotel are unavailable for rental for a period of one hundred eighty (180) days or more as a result of such casualty.

  • TENANT PARKING Subject to the terms of this Article 28, Tenant shall have the right to rent from Landlord, commencing on the Rent Commencement Date, the amount of unreserved parking passes set forth in Section 9 of the Summary (of which up to five (5) may be converted to reserved parking passes), on a monthly basis throughout the Lease Term, which parking passes shall pertain to the Property parking facility. Tenant shall pay to Landlord for automobile parking passes on a monthly basis the prevailing rate charged from time to time at the location of such parking passes; provided, however, during the first year of the Lease Term following the Rent Commencement Date only, Tenant shall be entitled to rent the unreserved parking passes at a rate of One Hundred Fifty and 00/100 Dollars ($150.00) per unreserved parking pass per month; and provided, further, that thereafter, the prevailing rate charged by Landlord shall be subject to market rate increases consistent with the parking rates being charged by landlords of Comparable Buildings in the Mid-Market/Civic Center Area. The foregoing parking rates may only be utilized by Tenant, its Permitted Transferee Assignees and any other assignee, sublessee, or transferee of the Tenant’s interest in this Lease. In addition, Tenant shall be responsible for the full amount of any taxes imposed by any governmental authority in connection with the renting of such parking passes by Tenant or the use of the parking facility by Tenant. Tenant may change the number of parking passes rented pursuant to this Article 28 upon thirty (30) days prior written notice to Landlord; provided that notwithstanding any contrary provision of this Lease, if Tenant elects to rent less than all of the unreserved parking passes at any time during the Lease Term, then Tenant’s right to again increase the number of parking passes that it elects to rent under this Lease shall be subject to availability (as determined by Landlord in its reasonable discretion); and provided, further, that in no event shall Tenant be entitled to rent more than the amount and type of parking passes allocated to Tenant as set forth in Section 9 of the Summary during the Lease Term. Tenant’s continued right to use the parking passes is conditioned upon Tenant abiding by all rules and regulations which are reasonably prescribed from time to time for the orderly operation and use of the parking facility where the parking passes are located, including any sticker or other identification system established by Landlord and Tenant’s cooperation in seeing that Tenant’s employees and visitors also comply with such rules and regulations. So long as the same do not unreasonably interfere with Tenant’s parking rights, Landlord specifically reserves the right to change the size, configuration, design, layout and all other aspects of the Property parking facility at any time and Tenant acknowledges and agrees that Landlord may, without incurring any liability to Tenant and without any abatement of Rent under this Lease, from time to time, close-off or restrict access to the Property parking facility for purposes of permitting or facilitating any such construction, alteration or improvements. Landlord may delegate its responsibilities hereunder to a parking operator in which case such parking operator shall have all the rights of control attributed hereby to the Landlord. The parking passes rented by Tenant pursuant to this Article 28 are provided to Tenant solely for use by Tenant’s own personnel and such passes may not be transferred, assigned, subleased or otherwise alienated by Tenant, except in connection with a Transfer of the Premises pursuant to Article 14 of this Lease, without Landlord’s prior approval. Tenant may validate visitor parking by such method or methods as the Landlord may establish, at the validation rate from time to time generally applicable to visitor parking. If Landlord adds a parking valet, Tenant shall have the right to use such valet’s services at the rate established by Landlord for the Building. In addition, if Landlord expands the parking area, Tenant shall have the right to its proportionate share of such additional spaces.

  • Complete Destruction In the event the Premises are completely destroyed by fire, explosion, the elements, a public enemy, Act of God, or other casualty or are so damaged as to render the entire Premises untenable, and the Premises cannot be repaired within 120 days, Company will give Authority immediate notice thereof, and Authority will be under no obligation to repair, replace, and reconstruct said Premises. In the event Authority elects not to repair, replace, and reconstruct said Premises, Authority will not be required to grant alternative premises and this Agreement and the obligations of the Parties hereunder will terminate.

  • Ready for Occupancy For purposes of Section 1.3.2 of this Agreement, the Premises shall be deemed “Ready for Occupancy” upon the substantial completion of the Tenant Improvement Work. Subject to Section 4.2 below, the Tenant Improvement Work shall be deemed to be “substantially complete” upon the completion of the Tenant Improvement Work pursuant to the Approved Construction Drawings (as reasonably determined by Landlord), with the exception of any details of construction, mechanical adjustment or any other similar matter the non-completion of which does not materially interfere with Tenant’s use of the Premises.

  • DAMAGE TO LEASED PREMISES In the event the building housing the Premises shall be destroyed or damaged as a result of any fire or other casualty which is not the result of the intentional acts or neglect of Lessee and which precludes or adversely affects the Lessee’s occupancy of the Premises, then in every such cause, the rent herein set forth shall be abated or adjusted according to the extent to which the leased Premises have been rendered unfit for use and occupation by the Lessee and until the demised Premises have been put in a condition at the expense of the Lessor, at least to the extent of the value and as nearly as possible to the condition of the Premises existing immediately prior to such damage. It is understood, however, in the event of total or substantial destruction to the Premises that in no event shall the Lessor's obligation to restore, replace or rebuild exceed an amount equal to the sum of the insurance proceeds available for reconstruction with respect to said damage.

  • MULTIPLE TENANT OR OCCUPANT(S) Each individual that is considered a Tenant is jointly and individually liable for all of this Agreement's obligations, including but not limited to rent monies. If any Tenant, guest, or Occupant(s) violates this Agreement, the Tenant is considered to have violated this Agreement. Landlord’s requests and notices to the Tenant or any of the Occupant(s) of legal age constitutes notice to the Tenant. Notices and requests from the Tenant or any one of the Occupant(s) (including repair requests and entry permissions) constitutes notice from the Tenant. In eviction suits, the Tenant is considered the agent of the Premise for the service of process.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Leased Premises Lessor hereby leases to Lessee, and Lessee leases and takes from Lessor, the Leased Premises subject to the conditions of this Lease.

Time is Money Join Law Insider Premium to draft better contracts faster.