Waiver or Delay No failure to exercise or delay by a party in exercising any right, power, or remedy under this License Agreement operates as a waiver of such right, power, or remedy. A single or partial exercise of any right, power, or remedy does not preclude any other or further exercise of that or any other right, power, or remedy. A waiver is not valid or binding on the party granting the waiver unless made in writing.
No Delay Work requiring correction shall be corrected immediately and shall be carried out in such a way not to delay the completion of the Project. If it is not feasible to correct said work immediately, the corrective work shall be done on a schedule acceptable to the Owner.
Effect of Failure or Delay in Requesting Compensation Failure or delay on the part of any Lender or the Issuing Bank to demand compensation pursuant to this Section 5.01 shall not constitute a waiver of such Lender’s or the Issuing Bank’s right to demand such compensation; provided that the Borrower shall not be required to compensate a Lender or the Issuing Bank pursuant to this Section 5.01 for any increased costs or reductions incurred more than 180 days prior to the date that such Lender or the Issuing Bank, as the case may be, notifies the Borrower of the Change in Law giving rise to such increased costs or reductions and of such Lender’s or the Issuing Bank’s intention to claim compensation therefor; provided further that, if the Change in Law giving rise to such increased costs or reductions is retroactive, then the 180-day period referred to above shall be extended to include the period of retroactive effect thereof.
Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.
Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.
Lenders’ Failure to Perform All Advances (other than Swing Loans and Agent Advances) shall be made by the Lenders contemporaneously and in accordance with their Pro Rata Shares. It is understood that (i) no Lender shall be responsible for any failure by any other Lender to perform its obligation to make any Advance (or other extension of credit) hereunder, nor shall any Commitment of any Lender be increased or decreased as a result of any failure by any other Lender to perform its obligations hereunder, and (ii) no failure by any Lender to perform its obligations hereunder shall excuse any other Lender from its obligations hereunder.
Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”
Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.
Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).
Six-Month Delay Notwithstanding anything to the contrary in this Agreement, no compensation or benefits, including without limitation any severance payments or benefits payable under this Section 4, shall be paid to the Executive during the six-month period following the Executive’s Separation from Service if the Company determines that paying such amounts at the time or times indicated in this Agreement would be a prohibited distribution under Section 409A(a)(2)(B)(i) of the Code. If the payment of any such amounts is delayed as a result of the previous sentence, then on the first day of the seventh month following the date of Separation from Service (or such earlier date upon which such amount can be paid under Section 409A without resulting in a prohibited distribution, including as a result of the Executive’s death), the Company shall pay the Executive a lump-sum amount equal to the cumulative amount that would have otherwise been payable to the Executive during such period.
