Notice Regarding First Article Sample Clauses
Notice Regarding First Article. (a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Procuring Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.
(b) When any of the conditions above occurs, the Contractor shall notify the Procuring Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.
(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule. ************ End of Narrative E.25 ************
(a) DESIGN CHANGES TO ITEMS NOT UNDER GOVERNMENT DESIGN CONTROL. Once the Government accepts the first production test item, or accepts the first end item you deliver, (whichever comes first) you must not make design changes to any item or part that is not under Government design control.
Notice Regarding First Article. E.1.1.3.2.1 Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Government in writing when (i) a major change is made to the technical data, such as a Class I ECP, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.
E.1.1.3.2.2 When any of the conditions above occurs, the contractor shall notify the Government so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.
E.1.1.3.2.3 Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined IAW FAR clause 52.249-14. Such delays shall not form the basis for adjustment in contract price or delivery schedule.
Notice Regarding First Article. (a) Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Contracting Officer in writing when (i) a major change is made to the technical data, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.
(b) When any of the conditions above occurs, the Contractor shall notify the Contracting Officer so that a determination can be made concerning the need for the additional first article sample (or portion thereof), and instructions can be provided concerning the submission, inspection, and notification of results.
(c) Costs of any additional testing and inspection resulting from conditions specified above shall be borne by the Contractor, unless the change was directed by the Government. Further, any production delays caused by additional testing and inspection will not be the basis for an excusable delay as defined in the default clause of this contract. Such delays shall not form the basis for adjustment in contract price or delivery schedule. ************ End of Narrative E.25 ************ This document incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at these addresses: ▇▇▇▇://▇▇▇▇▇▇▇.▇▇▇▇.▇▇.▇▇▇/ or ▇▇▇▇▇://▇▇▇.▇▇▇▇▇▇▇▇▇▇▇.▇▇▇/ If the clause requires additional or unique information, then that information is provided immediately after the clause title. Regulatory Cite Title Date E-1 52.246-2 INSPECTION OF SUPPLIES--FIXED-PRICE AUG/1996 E-2 52.246-16 RESPONSIBILITY FOR SUPPLIES APR/1984 E-3 (a) The 52.246-11 contractor shall comply HIGHER-LEVEL CONTRACT QUALITY REQUIREMENT with the higher-level quality standard(s) listed below. DEC/2014 ISO 9001:2008 *Contractors have until September 2018 to become compliant to ISO 9001:2015
Notice Regarding First Article. Notwithstanding the provisions for waiver of first article, an additional first article sample (or portion thereof) may be ordered by the Government in writing when (i) a major change is made to the technical data, such as a Class I ECP, (ii) whenever there is a lapse in production for a period in excess of one year, or (iii) whenever a change occurs in place of performance, manufacturing process, material used, drawing, specification or source of supply.