Multiple currencies Sample Clauses

Multiple currencies. The Employer will pay for these items or activities in the currencies stated Items & activities Other currency [●] [●] [●] [●] The exchange rates are those published in [●] on [●] (date) Maximum payment in other currency The items & activities will be paid in the other currency - to a foreign Bank account nominated by the Contractor - to a valid SARB approved CFC account in South Africa - in accordance with an alternative payment method agreed with the Employer before the Contract Date. (select one of the three methods as agreed with the successful tenderer prior to contract award and delete the others and this note) X4 Parent company guarantee There is no reference to Contract Data in this Option and terms in italics are identified elsewhere in this Contract Data.
Sample 1Sample 2Sample 3See All (5)
AutoNDA by SimpleDocs
Multiple currencies. Holding a PayPal balance in a currency other than Australian dollars PayPal may allow you to hold a balance in currencies other than Australian dollars. If you hold a PayPal balance, • we may allow you to convert it to balance in another currency. If you convert your balance, PayPal’s transaction exchange rate (including our currency conversion fee) will be used. We may, at our discretion, impose limits on the amount of money you can convert or the number of conversions you can perform; • you may only withdraw it in Australian dollars, or US dollars (only when you withdraw the US dollars into your US bank account linked to your PayPal account). In order to withdraw balance held in another currency you will have to convert the currency to Australian dollars, or it will be converted for you at the time of your withdrawal. PayPal’s currency conversion rate, including our currency conversion fees, will be used. You are responsible for all risks associated with maintaining multiple currencies in a PayPal account. You may not manage or convert currencies for speculative trading purposes, conversion arbitrage, conversion options, or any other activity that PayPal determines is primarily for the purpose of gaining or making money based on currency conversion rates. PayPal may hold, cancel, or reverse any transaction we determine to violate this policy. How we convert currency If PayPal converts currency, it will be completed at the transaction exchange rate we set for the relevant currency exchange. The transaction exchange rate is adjusted regularly and includes a currency conversion fee (described below) applied and retained by us on a base exchange rate to form the rate applicable to your conversion. The base exchange rate is based on rates within the wholesale currency markets on the conversion day or the prior business day; or, if required by law or regulation, set at the relevant government reference rate(s). For some uses of your PayPal account, PayPal may determine currency conversion is necessary. For any of the following transactions that involve a currency conversion, the currency conversion fee is 4.0%: • Paying for goods or services in a currency other than the currency the goods or services are listed in. • Receiving a refund beyond 1 day of the original payment. • Sending money to a friend or family member such that they receive a different currency from the currency you pay in. • Sending money using PayPal’s Payouts or MassPay products such that yo...
Sample 1
Multiple currencies. E4F offers Clients the ability to receive funds into their Payment Accounts in multiple currencies which are subject to change with or without notice from E4F.
Sample 1
Multiple currencies. The Employer will pay for these items or activities in the currencies stated Items & activities Other currency [●] [●] [●] [●] Maximum payment in other currency The exchange rates are those published in the Eskom Treasury web site The items & activities will be paid in the other currency - to a foreign Bank account nominated by the Contractor - to a valid SARB approved CFC account in South Africa - in accordance with an alternative payment method agreed with the Employer before the Contract Date. (select one of the three methods as agreed with the successful tenderer prior to contract award and delete the others and this note) X17 Low Service damages
Sample 1
Multiple currencies. The Employer will pay for these items or activities in the currencies stated Items & activities Other currency Maximum payment in other currency X3.1 [●] [●] [●] [●] The exchange rates are those published in [●] on [●] (date) [●] [●] [●] [●] [●] [●] [●] [●] The items & activities will be paid in the other currency - to a foreign Bank account nominated by the Contractor - to a valid SARB approved CFC account in South Africa - in accordance with an alternative payment method agreed with the Employer before the Contract Date. (select one of the three methods as agreed with successful tenderer and delete the others and this note) X4 Parent company guarantee There is no reference to Contract Data in this Option and terms in italics are identified elsewhere in this Contract Data. X5 Sectional Completion X5.1 The completion date for each section of the works is: Section Description Completion date 1 [●] [●] 2 [●] [●] 3 [●] [●] X5 & X6 Sectional Completion and bonus for early Completion used together X6.1 X5.1 The bonuses for early Completion of the sections of the works are: section Description Amount per day 1 [●] R[●] 2 [●] R[●] 3 [●] R[●] Remainder of the works R[●] X5 & X7 Sectional Completion and delay damages used together X7.1 X5.1 Delay damages for late Completion of the sections of the works are: section Description Amount per day 1 [●] R[●] 2 [●] R[●] 3 [●] R[●] Remainder of the works R[●] The total delay damages payable by the Contractor does not exceed: R [●] X6 Bonus for early Completion (but not if Option X5 is also used) X6.1 The bonus for early Completion of the whole of the works is [●] per day X7 Delay damages (but not if Option X5 is also used) X7.1 Delay damages for Completion of the whole of the works are R[●] per day up to a limit of R[●] X12 Partnering
Sample 1
Multiple currencies. The Employer will pay for these items or activities in the currencies stated Items & activities Other currency Maximum payment in other currency X3.1 [●] [●] [●] [●] The exchange rates are those published in [●] on [●] (date) [●] [●] [●] [●] [●] [●] [●] [●] The items & activities will be paid in the other currency - to a foreign Bank account nominated by the Contractor - to a valid SARB approved CFC account in South Africa - in accordance with an alternative payment method agreed with the Employer before the Contract Date. (select one of the three methods as agreed with successful tenderer and delete the others and this note) X4 Parent company guarantee There is no reference to Contract Data in this Option and terms in italics are identified elsewhere in this Contract Data. X5 Sectional Completion
Sample 1

Related to Multiple currencies

  • Alternative Currencies In the case of a Credit Extension to be denominated in an Alternative Currency, there shall not have occurred any change in national or international financial, political or economic conditions or currency exchange rates or exchange controls which in the reasonable opinion of the Administrative Agent, the Required Revolving Credit Lenders (in the case of any Loans to be denominated in an Alternative Currency) or the L/C Issuer (in the case of any Letter of Credit to be denominated in an Alternative Currency) would make it impracticable for such Credit Extension to be denominated in the relevant Alternative Currency.

  • Currencies 46.1 All payments shall be made in Indian Rupees.

  • Optional Currencies 25 8. Repayment....................................................... 29 9.

  • Managing Your Money in Multiple Currencies When you open your account, it is configured for use with the opening currency of your account. The opening currency of your account is Euro (EUR). We may configure your account further so that you can use it to store money and send and receive payments in currencies other than the opening currency of your account. If you hold a PayPal balance, we may allow you to convert it to balance in another currency. If your PayPal balance is not enough to cover the amount of a payment you instruct us to make in a particular currency, we may perform a currency conversion from any PayPal balance in another currency to cover the shortfall. There may be some restrictions on where you can send payments in certain currencies. We may allow you to choose the way in which your account treats and/or converts payments received in currencies other than the opening currency of your account. To receive money in a currency other than the opening currency of your account, it may be necessary to create a balance in that currency or convert the money into another currency that we allow you to hold. Payments in certain currencies can only be received by automatic conversion of the money into another currency that we allow you to hold. If you receive a payment from anyone who doesn’t have a PayPal account and that payment is in a currency which your account is not currently configured to use, we may automatically convert the amount received into a currency that your account is configured to use at the time the payment is made. Please see the Withdrawing Money section above to see how withdrawals in different currencies can be made. If one of the currency balances in your account shows that you owe us an amount of funds for any reason, we may set off the amount you owe us by using funds you maintain in a different currency balance or by deducting amounts you owe us from money you receive into your account, or money you attempt to withdraw or send from your account, or in a different account, and by deducting funds from any withdrawals you attempt to make. If, for a period of 21 Days, you have a PayPal balance that reflects an amount owing to us that is not in Euros, we may convert the amount you owe us to Euros. We may, at our discretion, impose limits on the amount of money you can convert or the number of conversions you can perform. You are responsible for all risks associated with maintaining multiple currencies in a PayPal account. You may not manage or convert currencies for speculative trading purposes, conversion arbitrage, conversion options, or any other activity that we determine is primarily for the purpose of gaining or making money based on currency conversion rates. We may hold, cancel, or reverse any transaction we determine to violate this policy. How we convert currency If PayPal converts currency, it will be completed at the transaction exchange rate we set for the relevant currency exchange. The transaction exchange rate is adjusted regularly and includes a applied and retained by us on a base exchange rate to form the rate applicable to your conversion. The base exchange rate is based on rates within the wholesale currency markets on the conversion day or the prior Business Day; or, if required by law or regulation, set at the relevant government reference rate(s). We may make a transaction exchange rate (including our ) available for your review during your transaction. If you complete the transaction, that transaction exchange rate may apply to the payment for the transaction whenever it is processed; or that rate may be valid only if the payment for that transaction is processed within a limited time, as stated during the transaction. After that limited time, we may use the transaction exchange rate in effect at the time the transaction is processed, or not perform the currency conversion. If you have authorised a payment under a billing agreement, and we perform currency conversion for that payment, we will use the transaction exchange rate in effect at the time the payment transaction is processed. The transaction exchange rate for each payment under a billing agreement may vary. We may provide you access to a “Currency Converter” tool to see what transaction exchange rate (including our currency conversion fee) may apply for certain currency conversions. Any rates shown using the Currency Converter tool only apply at the time you use the tool and are subject to change. Currency conversion choices When your payment is funded by a debit or credit card and PayPal determines currency conversion is necessary, you consent to and authorise us to convert the currency in place of your debit or credit card issuer. You may have the right to have your card issuer convert the currency of the card payment into the currency in which you send the payment from your PayPal account, if applicable for that card issuer and network. This selection may be presented to you in various forms, including a choice of which currency is used for the transaction, whether we or your card issuer performs the conversion, or which conversion rate is used for the transaction, among others. If your card issuer converts the currency, your card issuer will determine the currency conversion rate and what fees they may charge. PayPal will always perform the conversion for transactions where you use existing balance or your linked bank account is the funding source. If PayPal determines currency conversion is necessary for a transaction that also requires a backup funding source to be chosen, you may not be able to separately choose whether PayPal or your card issuer performs the currency conversion on the payment from your backup funding source. Where a currency conversion is offered at the point of sale by the merchant, not by PayPal, and you choose to authorise the payment transaction on the basis of the merchant's exchange rate and charges, PayPal has no liability to you for that currency conversion.

  • Additional Alternative Currencies (a) The Borrower may from time to time request that Eurocurrency Rate Loans be made and/or Letters of Credit be issued in a currency other than those specifically listed in the definition of “Alternative Currency;” provided that such requested currency is a lawful currency (other than Dollars) that is readily available and freely transferable and convertible into Dollars. In the case of any such request with respect to the making of Eurocurrency Rate Loans, such request shall be subject to the approval of the Administrative Agent and the Lenders; and in the case of any such request with respect to the issuance of Letters of Credit, such request shall be subject to the approval of the Administrative Agent and the L/C Issuer.

  • Canadian Dollars All references herein to dollar amounts are to lawful money of Canada.

  • Conversion of Currencies (a) If, for the purpose of obtaining judgment in any court, it is necessary to convert a sum owing hereunder in one currency into another currency, each party hereto agrees, to the fullest extent that it may effectively do so, that the rate of exchange used shall be that at which in accordance with normal banking procedures in the relevant jurisdiction the first currency could be purchased with such other currency on the Business Day immediately preceding the day on which final judgment is given.

  • Currency; Denominations Unless otherwise provided in or pursuant to this Indenture, the principal of, any premium and interest on and any Additional Amounts with respect to the Securities shall be payable in Dollars. Unless otherwise provided in or pursuant to this Indenture, Registered Securities denominated in Dollars shall be issuable in registered form without Coupons in denominations of $1,000 and any integral multiple thereof, and the Bearer Securities denominated in Dollars shall be issuable in the denomination of $5,000. Securities not denominated in Dollars shall be issuable in such denominations as are established with respect to such Securities in or pursuant to this Indenture.

  • Base Currency For the purposes of any calculation hereunder, we may convert amounts denominated in any other currency into the Base Currency at such rate prevailing at the time of the calculation as we shall reasonably select.

  • Currencies Currency Equivalents (a) At any time, any reference in the definition of the term “Alternative Currency” or in any other provision of this Agreement to the Currency of any particular nation shall mean the then lawful currency of such nation at such time whether or not the name of such Currency is the same as it was on the date of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.