Minimum Customer Support Requirements for TIPS Sales Vendor shall provide timely and commercially reasonable support for TIPS Sales or as agreed to in the applicable Supplemental Agreement.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Progress Update Information included with the annual Data Access Request (DAR) renewal or Closeout summarizing the analysis of controlled-access datasets obtained through the DAR and any publications and presentations derived from the work.
Changes to Specifications All Specifications and any changes thereto agreed to by the Parties from time to time shall be in writing, dated and signed by the Parties. No change in the Specifications shall be implemented by Cardinal Health, whether requested by Reliant or requested or required by any Regulatory Authority, until the Parties have agreed in writing to such change, the implementation date of such change, and any increase or decrease in costs, expenses or fees associated with such change. Cardinal Health shall respond promptly to any request made by Reliant for a change in the Specifications, and both Parties shall use commercially reasonable, good faith efforts to agree to the terms of such change in a timely manner. If after initial Product qualification, Reliant requests a change in the Specifications for its own benefit or to comply with the requirements of a Regulatory Authority, the Specifications shall be amended as soon as [***]: Certain information on this page has been omitted and filed separately with the Commission. Confidential treatment has been requested with respect to the omitted portions. possible after a request is made for any change in Specifications, and Cardinal Health shall notify Reliant of the costs associated with such change and shall provide such supporting documentation as Reliant may reasonably require. Reliant shall pay all costs associated with such Reliant-requested changes or changes required by a Regulatory Authority as may be agreed upon by the Parties. Changes, agreed to between the Parties, for the benefit of Cardinal Health, shall be at the expense of Cardinal Health. If there is a conflict between the terms of this Agreement and the terms of the Specifications, this Agreement shall control.
Drug-Free Workplace Certification As required by Executive Order No. 90-5 dated April 12, 1990, issued by the Governor of Indiana, the Contractor hereby covenants and agrees to make a good faith effort to provide and maintain a drug-free workplace. The Contractor will give written notice to the State within ten (10) days after receiving actual notice that the Contractor, or an employee of the Contractor in the State of Indiana, has been convicted of a criminal drug violation occurring in the workplace. False certification or violation of this certification may result in sanctions including, but not limited to, suspension of contract payments, termination of this Contract and/or debarment of contracting opportunities with the State for up to three (3) years. In addition to the provisions of the above paragraph, if the total amount set forth in this Contract is in excess of $25,000.00, the Contractor certifies and agrees that it will provide a drug-free workplace by:
ODUF Packing Specifications 6.3.1 The data will be packed using ATIS EMI records. A pack will contain a minimum of one (1) message record or a maximum of ninety-nine thousand nine hundred and ninety-nine (99,999) message records plus a pack header record and a pack trailer record. One transmission can contain a maximum of ninety-nine (99) packs and a minimum of one (1) pack.
Alternative Work Schedule An alternate forty (40) hour work schedule (other than five (5) uniform and consecutive eight (8) hour days in a seven (7) day period), or for hospital personnel an eighty (80) hour workweek in a fourteen (14) day period and other mutually agreed upon schedules that comply with applicable federal and state law. Employee work schedules normally include two (2) consecutive days off.
Child Abuse Reporting Requirement Grantee will:
Technical Specifications 1. A procuring entity shall not prepare, adopt or apply any technical specification or prescribe any conformity assessment procedure with the purpose or effect of creating an unnecessary obstacle to trade between the Parties.
