Material Delays Sample Clauses

Material Delays. If required material(s) are unavailable at the time of assembly, LM Aero will provide an estimated delivery date. If the estimated material delivery date creates an unreasonable delay as determined by the 309 CMXG, LM Aero will retrieve and store the asset until all required material is available unless otherwise mutually agreed to by the parties. If the asset is removed from work, the work order will be closed and LM Aero will be billed for the amount of labor hours expended. Upon receipt of all required material, LM Aero will notify 309 CMXG that the asset is ready for induction. The asset will be scheduled for induction under a new work order. The 309 CMXG metrics for RTAT may be adjusted, as appropriate, to reflect impacts caused by material delays.
Sample 1
AutoNDA by SimpleDocs

Related to Material Delays

  • Material Delivery Within 60 days after award date, Purchaser shall provide Forest Service a written schedule showing the desired delivery dates of any material to be supplied by Forest Service. With reasonable notice, schedule may be amended by agreement. Forest Service agrees to make delivery within 15 days after the scheduled delivery dates that are at least 60 days after the schedule is submitted, unless prevented by causes beyond control of Forest Service. If Purchaser does not provide Forest Service the written schedule within the period provided in this Subsection, Forest Service agrees to make delivery within 90 days after a late schedule is submitted, unless prevented by causes beyond control of Forest Service. After delivery to and written receipt by Purchaser, Purchaser is responsible for installation of needed material and for any loss of or damage to such material due to Purchaser's negligence prior to installation or return of unused material to Forest Service. At Purchaser’s option, Forest Service deliveries shall be to Purchaser’s storage area, as agreed, or to the nearest practicable point to the job site along existing roads. Unused material shall be returned to Forest Service at location of delivery, unless agreed otherwise.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:

  • Unavoidable Delays Delays due to acts of God, acts of public agencies, labor disputes, strikes, fires, freight embargoes, inability (despite the exercise of due diligence) to obtain supplies, materials, fuels or permits, or other causes or contingencies (excluding financial inability) beyond the reasonable control of Landlord or Tenant, as applicable. Landlord shall use commercially reasonable efforts to provide Tenant with prompt notice of any Unavoidable Delays.

  • Operation Delays STATE shall have the authority to delay or suspend the operations of PURCHASER and contractors of PURCHASER, wholly or in part, under this contract for such period or periods necessary due to fire hazard conditions, severe weather occurrence, surveying for threatened or endangered species listed under the state or federal Endangered Species Act, or any other activity STATE determines to be necessary for identification, management, or protection of a threatened or endangered species. PURCHASER agrees to cooperate with surveying efforts of STATE or its contractors. In no event shall STATE be liable for any costs incurred by PURCHASER by reason of delay or suspension under this section, including but not limited to costs of additional move-in/move-out of equipment and personnel, extra fire and equipment security, and insurance or bonding expenses.

  • Significant deficiencies (1) The Contracting Officer will provide an initial determination to the Contractor, in writing, of any significant deficiencies. The initial determination will describe the deficiency in sufficient detail to allow the Contractor to understand the deficiency.

  • Unavoidable Delay When construction is impeded as a result of strikes, lockouts, acts of God or other factors beyond the control, and ability to remedy, of the Developer.

  • Strikes Nothing in this Agreement permits or grants to any employee the right to strike or refuse to perform their official duties.

  • Complete Work without Extra Cost Except to the extent otherwise specifically stated in this contract, the Contractor shall obtain and provide, without additional cost to the City, all labor, materials, equipment, transportation, facilities, services, permits, and licenses necessary to perform the Work.

Time is Money Join Law Insider Premium to draft better contracts faster.