Lighting Plans Sample Clauses

Lighting Plans. 16 Developer shall prepare lighting system Plans for the Project. The lighting system Plans must 17 show all existing and new electrical features, all details, pole schedules, conductor, and lighting 18 circuit schedules, distribution schedule for each lighting service, notes, and special provisions. 19 The plans must include information regarding conduit used to intercept existing circuits to be 20 used for new lighting and for new conduit crossing locations for median lighting. The lighting 22 pull box, and load centers, and the conductor summary.
Sample 1Sample 2
AutoNDA by SimpleDocs
Lighting Plans. 5 Developer shall prepare lighting system Plans for the Project. The lighting system Plans must 6 show all existing and new electrical features, all details, pole and conductor schedules, 7 distribution schedule for each lighting service, notes, and special provisions. The plans must 8 include information regarding conduit used to intercept existing circuits to be used for new 10 must also include lighting summary sheets giving the location of the lighting poles, pull box, and 11 load centers, and the conductor summary. 12 460.4 SUBMITTALS‌ 13 Table 460-2 reflects a nonexclusive list of Submittals identified in Section DR 460 of the TPs 14 and is not intended to be an all-inclusive or exhaustive listing of Submittals. Developer shall 15 determine and submit all Submittals as required by the Contract Documents, Governmental 16 Approvals, and Governmental Entities. Unless otherwise indicated, Developer shall submit all 17 Submittals in both electronic format and hardcopy format. At a minimum and unless otherwise 18 specified in the Contract Documents, Developer shall submit the following to ADOT in the 19 formats described in Section GP 110.10.2.1 of the TPs: Table 460-2 Nonexclusive Submittals List Submittals Level of Number of Copies Submittal Section
Sample 1
Lighting Plans. Upon editing the plans, the consultant will also update the Civil 3d Model that generates the contours and quantities on the estimate. Deliverables: Updated Plans and Estimate Exclusions
Sample 1
Lighting Plans. 10. Sediment and/or Detention Basin construction Details (If required) 11. Post Construction Stormwater BMP Construction Details
Sample 1
Lighting Plans. The Design-Build Firm shall prepare Lighting Plans in accordance with County and FDOT criteria.
Sample 1

Related to Lighting Plans

  • Meal Plans Residents living in Residence Facility are required to purchase a University meal plan. Information regarding the meal plan options can be obtained by contacting the meal plan office at 000-000-0000.

  • Improvement Plans A. A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.

  • Final Plans No later than thirty (30) days following the approval of the Preliminary Plans, Tenant shall submit to Landlord a proposed set of Final Plans for approval by Landlord. Landlord’s approval of such proposed Final plans shall not be unreasonably withheld, conditioned or delayed, provided that (a) the Tenant Improvements, as set forth on such plans, comply with all applicable governmental laws, codes, rules, and regulations, and (b) such plans are sufficiently detailed to allow construction of the Tenant Improvements in a good and workmanlike manner. Landlord shall advise Tenant of Landlord’s approval or disapproval of the proposed Final Plans. If Landlord disapproves any aspect of the proposed Final Plans, Landlord shall so notify Tenant and specify how any such disapproved item may be made acceptable to Landlord. The proposed Final Plans shall then be revised and re-submitted to Landlord and Landlord and Tenant shall agree upon and sign the Final Plans as soon as reasonably practicable. The proposed Final Plans will be deemed to be complete and become the Final Plans upon execution thereof by Landlord and Tenant, and thereupon such Final Plans shall be deemed to be a part of this Lease and incorporated into this Lease by reference. Approval by Landlord of the Final Plans shall not be a representation or warranty of Landlord that such plans are adequate for any use, purpose, or condition, or that such plans comply with any applicable law or code, but shall merely be the consent of Landlord to the Final Plans. All changes in the Final Plans must receive the prior written approval of Landlord, and in the event of any such approved change, Tenant shall, upon completion of the Tenant Improvements, furnish Landlord with an accurate, reproducible “as-built” plan of the Tenant Improvements as constructed.

  • Marketing Plans Contractor and the Exchange recognize that Enrollees and other health care consumers benefit from efforts relating to outreach activities designed to increase heath awareness and encourage enrollment. The parties shall share marketing plans on an annual basis and with respect to periodic updates of material changes. The marketing plans of the Exchange and Contractor shall include proposed and actual marketing approaches, messaging and channels and provide samples of any planned marketing materials and related collateral as well as planned, and when completed, expenses for the marketing budget. The Contractor shall include this information for both the Exchange and the outside individual market. The Exchange shall treat all marketing information provided under this Section as confidential information consistent with Section 1.4.1. The obligation of the Exchange to maintain confidentiality of this information shall survive termination or expiration of this Agreement.

  • Service Plans 2.1 Standard Price Service Standard Price Term Home Basic Broadband 100 HK$168 Monthly Plan 24 consecutive months HomeFibre 500 HK$178 Monthly Plan 24 consecutive months HomeFibre 1000 HK$198 Monthly Plan 24 consecutive months

  • Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.

  • Work Plans Tenant shall prepare and submit to Landlord for approval schematics covering the Tenant Improvements prepared in conformity with the applicable provisions of this Work Letter (the “Draft Schematic Plans”). The Draft Schematic Plans shall contain sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Draft Schematic Plans whether Landlord approves or objects to the Draft Schematic Plans and of the manner, if any, in which the Draft Schematic Plans are unacceptable. Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Draft Schematic Plans, then Tenant shall revise the Draft Schematic Plans and cause Landlord’s objections to be remedied in the revised Draft Schematic Plans. Tenant shall then resubmit the revised Draft Schematic Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord’s approval of or objection to revised Draft Schematic Plans and Tenant’s correction of the same shall be in accordance with this Section until Landlord has approved the Draft Schematic Plans in writing or been deemed to have approved them. The iteration of the Draft Schematic Plans that is approved or deemed approved by Landlord without objection shall be referred to herein as the “Approved Schematic Plans.”

  • Project Plans The Contractor: must carry out the Contractor's Activities in accordance with, and otherwise implement, the Project Plans; and for the purposes of subparagraph (i), must: prepare Project Plans based, where applicable, on the draft Project Plans lodged by the Contractor in its tender for the Contractor's Activities, and otherwise in accordance with the requirements of the Contract and submit them to the Contract Administrator so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event no later than the number of days specified in the Contract Particulars after the Award Date for each Project Plan; not commence any of the Contractor's Activities to which any Project Plan applies, unless the Contract Administrator has had the number of days specified in the Contract Particulars for each Project Plan to review the Project Plan and has not rejected the Project Plan; if any Project Plan is rejected, submit an amended Project Plan to the Contract Administrator; in any event, finalise each Project Plan so as to ensure that there is no delay or disruption to the Contractor's Activities and in any event in accordance with the requirements of the Contract to the satisfaction of the Contract Administrator; after each Project Plan has been finalised: regularly review, update and amend each Project Plan in accordance with the process set out in each Project Plan (and otherwise at least on each anniversary of the Award Date); update or amend a Project Plan on request of the Contract Administrator; and continue to correct any defects in or omissions from a Project Plan (whether identified by the Contract Administrator or the Contractor), and submit an updated or amended Project Plan to the Contract Administrator, after which: the Contractor must continue to comply with the requirements of the then current Project Plan until the process in subparagraph (ii) has been completed in respect of the updated or amended Project Plan; and subsubparagraphs B - E will apply (to the extent applicable); and document and maintain detailed records of all: reviews, updates, amendments and submissions of each Project Plan; audits or other monitoring of each Project Plan; and training and awareness programs and communications provided to Contractor and subcontractor personnel in respect of each Project Plan (including each updated or amended Project Plan). The Contractor will not be relieved from compliance with any of its obligations under the Contract or otherwise at law or in equity as a result of: the implementation of, and compliance with, the requirements of any Project Plan; any direction by the Contract Administrator concerning a Project Plan or the Contractor's compliance or non-compliance with a Project Plan; any audit or other monitoring by the Contract Administrator or anyone else acting on behalf of the Commonwealth of the Contractor's compliance with a Project Plan; or any failure by the Contract Administrator, or anyone else acting on behalf of the Commonwealth, to detect any defect in or omission from a Project Plan including where any such failure arises from any negligence on the part of the Contract Administrator or other person.

  • Business Plans The Approved Full-Term Operating Business -------------- Plan and Approved Annual Operating Business Plan, if any, have been prepared in all material respects in accordance with GAAP (except for the treatment of Indebtedness owing to the FCC, which has been reflected in such plans at historical cost).

  • Development Plans 4.3.1 For each Licensed Indication and corresponding Licensed Product in the Field, Licensee will prepare and deliver to Licensor a development plan and budget (each a “Development Plan”). The initial Development Plans for each Licensed Indication will be delivered within […***…] after the Grant Date for such Licensed Indication.

Time is Money Join Law Insider Premium to draft better contracts faster.