Initial Term This Agreement shall become effective as of the date first written above (the “Start Date”) and shall continue thereafter throughout the period that ends two (2) years after the Start Date (the “Initial Term”).
Years The determination of the arbitrators shall be limited solely to the issue of whether Landlord's or Tenant's submitted Market Rent is the closest to the actual Market Rent as determined by the arbitrators, taking into account the requirements of item (b), above.
months All unpaid principal and accrued and unpaid interest with respect to each Term Loan is due and payable in full on the Maturity Date. Each Term Loan may only be prepaid in accordance with Sections 2.2(c) and 2.2(d).
Vesting Commencement Date Exercise Price per Share: Total Number of Shares: Type of Option: Non-Qualified Stock Option/Incentive Stock Option
Term Commencement Date The term of this Agreement shall commence on , 2020 (the “Commencement Date”) and, unless earlier terminated in accordance with the terms of this Agreement, shall end on June 30, 2055 (the “Term”).
Original Term The weighted average original term for the Receivables is at least 65 months.
Commencement Date Landlord shall deliver possession of the Premises to Tenant on the date (the “Delivery Date”) that Landlord’s Market Ready Improvements described on EXHIBIT C attached hereto and the Tenant Improvements to be completed by Landlord pursuant to the Work Letter Agreement attached hereto as EXHIBIT D are substantially completed. For purposes of this Lease, Landlord’s Market Ready Improvements and the Tenant Improvements shall be deemed to be “substantially completed” when Landlord’s Market Ready Improvements and the Tenant Improvements have been completed in accordance with any plans and specifications therefor, subject only to the completion of any minor punch-list items, and the City of Sunnyvale has completed a final inspection of such work and issued a temporary certificate of occupancy or other written approvals permitting legal occupancy of the Premises. The term of this Lease (“Term”) shall be seventy-six (76) months commencing on the date (the “Commencement Date”) which is thirty (30) days from the Delivery Date. If the Delivery Date does not occur on or before May 1, 2018, for any reason other than (i) ArcTec’s failure to complete the Final Plans and Specifications (as such term is defined in the Work Letter attached as EXHIBIT D) and submit such Final Plans and Specifications (and any other documentation required by the City of Sunnyvale for the issuance of a building permit for the Tenant Improvements) to Landlord’s general contractor by January 8, 2018, (ii) the City requiring Landlord to stop construction due to its commencement of the Tenant Improvements before the permits therefor were issued or (iii) delays caused by the acts or omission of Tenant, as defined in Paragraph 3(c) below, then the date Tenant is otherwise obliged to commence payment of Rent shall be delayed by one (1) additional day for each day the Delivery Date is delayed beyond such date.
Transition Period Upon termination of this Agreement, and for 90 consecutive calendar days thereafter (the “TRANSITION PERIOD”), Executive agrees to make himself available to assist the Company with transition projects assigned to him by the Board. Executive will be paid at a reasonable, agreed upon hourly rate for any work performed for the Company during the Transition Period.
Renewal Deadline If, immediately prior to the third anniversary of the initial effective date of the Registration Statement (the “Renewal Deadline”), any Notes remain unsold by the Underwriters, the Company will, prior to the Renewal Deadline, (i) promptly notify the Representatives in writing and (ii) promptly file, if it is eligible to do so, a new automatic shelf registration statement relating to the Notes, in a form and substance satisfactory to the Underwriters. If, at the Renewal Deadline, the Company is not eligible to file an automatic shelf registration statement, the Company will, prior to the Renewal Deadline, (i) promptly notify the Representatives in writing, (ii) promptly file a new shelf registration statement or post-effective amendment on the proper form relating to such Notes, in a form and substance satisfactory to the Underwriters, (iii) use its best efforts to cause such registration statement or post-effective amendment to be declared effective within 60 days after the Renewal Deadline and (iv) promptly notify the Representatives in writing of such effectiveness. The Company will take all other action necessary or appropriate to permit the offering and sale of the Notes to continue as contemplated in the expired Registration Statement. References herein to the “Registration Statement” shall include such new automatic shelf registration statement or such new shelf registration statement or post-effective amendment, as the case may be.
Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.
