Maintenance Work Landlord reserves the right from time to time, but subject to payment by and/or reimbursement from Tenant as otherwise provided herein: (i) to install, use, maintain, repair, replace, relocate and control for service to the Premises and/or other parts of the Project pipes, ducts, conduits, wires, cabling, appurtenant fixtures, equipment spaces and mechanical systems, wherever located in the Premises or the Project, (ii) to alter, close or relocate any facility in the Premises or the common areas or otherwise conduct any of the above activities for the purpose of complying with a general plan for fire/life safety for the Project or otherwise, and (iii) to comply with any federal, state or local law, rule or order. Landlord shall attempt to perform any such work with the least inconvenience to Tenant as is reasonably practicable, but in no event shall Tenant be permitted to withhold or reduce Basic Rental or other charges due hereunder as a result of same, make any claim for constructive eviction or otherwise make any claim against Landlord for interruption or interference with Tenant's business and/or operations.
Outside Work All work necessary to the assembling, installation, erection, operation, maintenance, repair, control, in- spection and supervision of all electrical apparatus, devices, wires, cables, supports, insulators, conduc- tors, ducts and raceways when part of distributing systems outside of buildings, railroads and outside the directly related railroad property and yards. In- stalling and maintaining the catenary and trolley work on railroad property, and bonding of rails. All underground ducts and cables when they are in- stalled by and are part of the system of a distrib- uting company, except in power stations during new construction, including ducts and cables to adjacent switch racks or substations. All outdoor substations and electrical connections up to and including the setting of transformers and the connecting of the secondary buses thereto. Outside work to include renewable electrical energy sources such as solar photovoltaic, geothermal, wind, biomass, wave, etc., and other distributed en- ergy installations such as fuel cells, microturbines, etc.
Tenant’s Work Section 5.1 Tenant will not make any changes to the Premises, the Building, the Building systems, or any part thereof (collectively, “Tenant’s Work”), without Landlord’s consent. Tenant’s Work will be performed, at Tenant’s expense, in a professional manner using new materials of first class quality as reasonably determined by Landlord and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2). Section 5.2 Prior to performing any Tenant’s Work which, pursuant to this Article, requires Landlord’s consent, Tenant will, at Tenant’s expense (a) deliver to Landlord, detailed plans and specifications for Tenant’s Work in form reasonably satisfactory to Landlord prepared and certified by a registered architect or licensed engineer, and suitable for filing with the applicable Authority, if filing is required by Law (“Tenant’s Plans”), (b) obtain Landlord’s approval of Tenant’s Plans (which will not be unreasonably withheld or delayed to the extent Landlord’s consent to Tenant’s Work shown on Tenant’s Plans is not to be unreasonably withheld or delayed pursuant to this Article), (c) obtain (and deliver to Landlord copies of) all required authorizations of any Authority, (d) deliver to Landlord certificates (in form reasonably acceptable to Landlord) of worker’s compensation insurance (covering all persons to be employed by Tenant, and all contractors and subcontractors performing any Tenant’s Work), commercial general liability insurance (naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds) and Builder’s all risk insurance (issued on a completed value basis), in form, with companies, for periods and in amounts reasonably required by Landlord, naming Landlord, Landlord’s managing agent, if any, any Superior Landlord and any Mortgagee as additional insureds. Tenant will promptly reimburse Landlord for any reasonable out-of-pocket expenses incurred by Landlord in connection with Landlord’s review of Tenant’s Plans and inspection of Tenant’s Work, including outside experts retained by Landlord for that purpose. Following the completion of Tenant’s Work, Tenant will, at Tenant’s expense, obtain and deliver to Landlord copies of all authorizations of any Authority required upon the completion of Tenant’s Work and “as-built” plans and specifications for Tenant’s Work prepared as reasonably required by Landlord. Section 5.3 If, in connection with Tenant’s Work or any other act or omission of Tenant or Tenant’s employees, agents or contractors, a mechanic’s lien, financing statement or other lien or violation is filed against Landlord, or any part of the Premises, the Building or Tenant’s Work, Tenant will, at Tenant’s expense, have it removed by bonding or otherwise within 30 days after Tenant receives notice of the filing. Section 5.4 Tenant will not employ, or permit the employment of, any contractor, subcontractor or other worker for purposes of conducting physical work in the Premises, whether in connection with Tenant’s Work or otherwise, if such employment will, in Landlord’s reasonable judgment, interfere or cause conflict with other contractors, subcontractors or workers in the Building. Section 5.5 At Tenant’s request, Landlord will join in any applications for any authorizations required from any Authority in connection with Tenant’s Work (to which Landlord has consented, if required pursuant to this Article), and otherwise cooperate with Tenant in connection with Tenant’s Work, but Landlord will not be obligated to incur any expense or obligation in connection with any such applications or cooperation. Section 5.6 Tenant will not place a load on any floor of the Premises exceeding the floor load per square foot which the floor was designed to carry and which is allowed by any Law. Section 5.7 On or before the Expiration Date, Tenant will, at Tenant’s expense, remove from the Premises and the Building (a) Tenant’s trade fixtures, equipment and personal property which are removable without material damage to the Premises or the Building (“Tenant’s Property”), and (b) any Tenant’s Work which is not an ordinary nonstructural office installation and which Landlord designates for removal in a notice given by Landlord to Tenant on or before the date which is 90 days prior to the Fixed Expiration Date (or five days prior to the Earlier Expiration Date, if applicable), and repair any damage to the Premises or the Building caused by the installation or removal of Tenant’s Property or Tenant’s Work. If, at the time Tenant requests Landlord’s consent to Tenant’s Plans, Tenant requests Landlord to designate the portions of Tenant’s Work which must be removed pursuant to this Section, Landlord will make that designation on the date Landlord gives Landlord’s consent to Tenant’s Plans. Except as expressly provided in this Section, Tenant’s Work will not be removed and will, on the Expiration Date, become the property of Landlord. Any Tenant’s Property or Tenant’s Work (which Tenant was required to remove) which is not removed by Tenant by the Expiration Date will be deemed abandoned and may, at Landlord’s option, be retained as Landlord’s property or disposed of by Landlord at Tenant’s expense.
Project Work PURCHASER shall complete the following projects in accordance with the specifications provided in Exhibits B, C, D, E, and F and written instructions from STATE. Project locations are shown on Exhibit A unless otherwise described. PURCHASER shall furnish all material unless otherwise specified.
Tenant Improvements Tenants construction of the Tenant Improvements in the Suite 120 Premises shall be subject to the terms of the Work Letter attached to the Lease as Exhibit C, except that, notwithstanding anything to the contrary contained in the Work Letter: a. The Tenant Improvements in the Suite 120 Premises shall be constructed pursuant to the space plans attached to this First Amendment as Exhibit B (the “Suite 120 Space Plans”) and the tenant improvement specifications attached to this First Amendment as Exhibit C (the “Suite 120 TI Specifications”), which have been approved by both Landlord and Tenant, and the TI Construction Drawings for the Tenant Improvements for the Suite 120 Premises shall be prepared substantially in accordance with the Suite 120 Space Plans and the Suite 120 TI Specifications (and Landlord may not disapprove any matter in connection therewith that is consistent with the Suite 120 Space Plans and the Suite 120 TI Specifications). b. The Tenant Improvement Allowance and the Additional Tenant Improvement Allowance provided for in Section 6(b) of the Work Letter shall not apply with respect to the Suite 120 Premises and Landlord shall provide a tenant improvement allowance with respect to the Tenant Improvements in the Suite 120 Premises, as follows: (i) a “Suite 120 Tenant Improvement Allowance” in the maximum amount of $185.00 per rentable square foot in the Suite 120 Premises, which is included in the Base Rent set forth in the Lease; and (ii) an “Additional Suite 120 Tenant Improvement Allowance” in the maximum amount of $40.00 per rentable square foot in the Suite 120 Premises, which shall, to the extent used, result in Suite 120 TI Rent as set forth in Section 5(c) below. For the avoidance of doubt, (A) the definition of “TI Allowance” in the Work Letter shall include the Tenant Improvement Allowance, the Additional Tenant Improvement Allowance, the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, as applicable, and (B) in connection with the Tenant Improvements in the Suite 120 Premises, Landlord shall be entitled to Administrative Rent equal to 1.5% of the “hard” TI Costs incurred in connection with such Tenant Improvements and a fee shall be payable to Tenant’s third party project manager, ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇▇ of ▇▇▇▇▇ ▇▇▇▇ LaSalle, not to exceed 1.5% of the “hard” TI Costs of such Tenant Improvements, which amounts shall be payable out of the TI Fund. Landlord and Tenant acknowledge and agree that the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance, to the extent utilized, must be used toward the cost of Tenant Improvements in the Suite 120 Premises. c. Pursuant to the terms of the Work Letter (as amended by this First Amendment), Landlord shall, subject to the terms of the Work Letter (as amended by this First Amendment), make available to Tenant the Suite 120 Tenant Improvement Allowance and the Additional Suite 120 Tenant Improvement Allowance. Commencing on the Rent Commencement Date and continuing thereafter on the first day of each month during the Base Term, Tenant shall pay the amount necessary to fully amortize the portion of the Additional Suite 120 Tenant Improvement Allowance actually funded by Landlord, if any, in equal monthly payments with interest at a rate of 7% per annum over the Base Term, which interest shall begin to accrue on the date that Landlord first disburses such Additional Suite 120 Tenant Improvement Allowance or any portion(s) thereof (“Suite 120 TI Rent”). Any outstanding and unamortized Suite 120 TI Rent remaining unpaid as of the expiration or earlier termination of the Lease shall be paid to Landlord in a lump sum at the expiration or earlier termination of this Lease. For the avoidance of doubt, Landlord and Tenant acknowledge and agree that Suite 120 TI Rent, if any, shall not be subject to adjustment pursuant to Section 4(a) of the Lease during the Term.
