Final Working Drawings. Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. Tenant shall cause the approved Final Space Plan to be converted by the Architect and the Engineers to complete architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall immediately revise the Final Working Drawings in accordance with such review and any disapproval of Landlord in connection therewith. Landlord and Tenant acknowledge that the Final Space Plans may not depict certain structural elements of the Building and/or various elements of the Building systems which may result in material modifications to the Final Working Drawings (“Space Plan Modifications”) Furthermore, the Final Space Plans for the construction of the Tenant Improvements may require modification to account for the requirements of building codes and other legal requirements of applicable governmental entities, including, but not limited to, Title 24 and the Americans with Disabilities Act (collectively the “Building Codes”). The Final Working Drawings shall materially conform to the Final Space Plans, taking into account (i) Space Plan Modifications, (ii) the requirements of the Building Codes, (iii) other modifications resulting from physical constraints of the Premises and (iv) modifications requested by Tenant and consented to by Landlord, which consent shall not be unreasonably withheld. Tenant agrees that, in addition to other factors and considerations Landlord may take into account, it shall not be unreasonable...
Final Working Drawings. The Architect and Engineers shall prepare the architectural and engineering drawings for the Premises based on the Final Space Plan, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings (collectively, the “Final Working Drawings”) in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (the “Permits”). Tenant shall cooperate with the Architect and the Engineers and provide to the Architect and Engineers such information as they may request in order to prepare and complete such Final Working Drawings and obtain Tenant’s approval thereof on or before the date set forth in Schedule 2. On or before said date, the Final Working Drawings approved by Tenant shall be delivered by the Architect to Landlord for review, and Landlord shall approve or disapprove such Final Working Drawings, in Landlord’s reasonable judgment, within five (5) Business Days after delivery thereof by the Architect. If Landlord disapproves such Final Working Drawings or any portion thereof, Landlord shall specify in writing the reasons for such disapproval, and the Architect, in consultation with Tenant, shall, within five (5) Business Days after receipt of Landlord’s disapproval, revise such Final Working Drawings and resubmit them to Landlord for Landlord’s review and approval or disapproval within five (5) Business Days after delivery thereof by the Architect, This process shall be repeated, if necessary, until the Final Working Drawings have been approved by Landlord.
Final Working Drawings. On or before the date set forth in Schedule 1, Tenant, the Architect and the Engineers shall complete the architectural and engineering drawings for the Premises, and the final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval. Following Landlord’s approval of the applicable Final Space Plan, Tenant, the Architect and the Engineers shall complete (except to the extent certain construction is being completed on a “design-build” basis) the Final Working Drawings for the applicable EXHIBIT B phase of the Tenant Improvements in a form which is sufficient to allow contractors to bid on the work and to obtain all applicable permits and shall submit the same to Landlord for Landlord’s approval. The Final Working Drawings may be submitted in one or more stages at one or more times, provided that Tenant shall ultimately supply Landlord with four (4) completed copies signed by Tenant of such Final Working Drawings. Landlord shall, within five (5) business days after Landlord’s receipt of all of the Final Working Drawings, either (i) approve the Final Working Drawings, (ii) approve the Final Working Drawings subject to specified conditions which must be stated in a reasonably clear and complete manner to be satisfied by Tenant prior to submitting the Approved Working Drawings for permits as set forth in Section 3.4, below of this Tenant Work Letter, to the extent the Final Working Drawings contain a Design Problem, or (iii) disapprove and return the Final Working Drawings to Tenant with requested revisions to the extent the Final Working Drawings contain a Design Problem. If Landlord disapproves the Final Working Drawings, Tenant may resubmit the Final Working Drawings to Landlord at any time, and Landlord shall approve or disapprove the resubmitted Final Working Drawings, based upon the criteria set forth in this Section 3.3, within three (3) business days after Landlord receives such resubmitted Final Working Drawings. Such procedure shall be repeated until the Final Working Drawings are approved. Landlord’s failure to timely respond to Tenant within any applicable response period referenced herein shall be deemed Landlord’s approval of the Final Working Drawings.
Final Working Drawings. After the Final Space Plan has been approved by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and cause the Architect to compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits for the Tenant Improvements (collectively, the “Final Working Drawings”), and shall submit the same to Landlord for Landlord’s approval. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) revise the Final Working Drawings in accordance with such review and any disapproval of Landlord in connection therewith, and (ii) deliver such revised Final Working Drawings to Landlord.
Final Working Drawings. On or before the date set forth in Schedule 1, Tenant, the Architect and the Engineers shall complete the architectural and engineering drawings for the Premises, and the final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”) and shall submit the same to Landlord for Landlord’s approval.
Final Working Drawings. After the Final Space Plan has been approved, working drawings for the Tenant Improvements shall be prepared by the Architect and the Engineers and approved in accordance with Schedule 1 to this Work Letter. Tenant shall supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the “Final Working Drawings” (as that term is defined below) in the manner as set forth below. The Architect and the Engineers shall complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings”), which shall be approved as provided in such Schedule. Tenant shall supply Landlord with four (4) copies signed by Tenant of such Final Working Drawings. In addition, promptly after the Substantial Completion of the Tenant Improvements, Tenant shall cause the Architect to prepare and deliver to Landlord and Tenant “as built” plans and specifications (including all working drawings) for the Tenant Improvements.
Final Working Drawings. See definition in Paragraph 2(a) hereof.
Final Working Drawings. After the Final Space Plan has been approved by Landlord, Tenant shall promptly supply the Engineers with a complete listing of standard and non-standard equipment and specifications, including, without limitation, B.T.U. calculations, electrical requirements and special electrical receptacle requirements for the Premises, to enable the Engineers and the Architect to complete the "Final Working Drawings" (as that term is defined below) in the manner as set forth below. Landlord shall provide Tenant with copies of any documentation containing the foregoing information that is in Landlord's possession or control. Upon the approval of the Final Space Plan by Landlord and Tenant, Tenant shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. Tenant shall supply Landlord with two (2) copies signed by Tenant of such Final Working Drawings. Landlord shall advise Tenant within five (5) Business Days after Landlord's receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any reasonable respect. If Tenant is so advised, Tenant shall promptly revise the Final Working Drawings to correct any deficiencies or other matters Landlord may reasonably require.
Final Working Drawings. Architect and the Engineers shall complete the architectural and engineering drawings for the Premises, and the final architectural working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the “Final Working Drawings “) and shall submit the same to Landlord for Landlord’s approval.
Final Working Drawings. After the approval of the Final Space Plan by Lessor and Lessee, Lessee shall promptly cause the Architect and the Engineers to complete the architectural and engineering drawings for the Premises, and Architect shall compile a fully coordinated set of architectural, structural, mechanical, electrical and plumbing working drawings in a form which is complete to allow subcontractors to bid on the work and to obtain all applicable permits (collectively, the "Final Working Drawings") and shall submit the same to Lessor for Lessor's approval. Lessee shall supply Lessor with four (4) copies signed by Lessee of such Final Working Drawings. Lessor shall advise Lessee within five (5) business days after Lessor's receipt of the Final Working Drawings for the Premises if the same is unsatisfactory or incomplete in any respect, provided that Lessor's approval of the Final Working Drawings shall not be unreasonably withheld or conditioned. If Lessee is so advised, the parties shall promptly meet and reasonably reach agreement upon the Final Working Drawings, correcting any deficiencies therein.
