Final Space Plan Tenant shall supply Landlord with four (4) copies signed by Tenant of its final space plan for the Premises before any architectural working drawings or engineering drawings have been commenced. The final space plan (the “Final Space Plan”) shall include a layout and designation of all offices, rooms and other partitioning, their intended use, and equipment to be contained therein. Landlord may request clarification or more specific drawings for special use items not included in the Final Space Plan. Landlord shall advise Tenant within five (5) business days after Landlord’s receipt of the Final Space Plan for the Premises if the same is unsatisfactory or incomplete in any respect. If Tenant is so advised, Tenant shall promptly (i) cause the Final Space Plan to be revised to correct any deficiencies or other matters Landlord may reasonably require, and (ii) deliver such revised Final Space Plan to Landlord.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
Additional Space Commencing on May 1, 2001, Sublessor herein grants unto the Sublessee a Right of First Refusal on any space that shall be and/or becomes available in the building during the remaining Term of this Sublease. Prior to May 1, 2001 and thereafter prior to the first day of May of any calendar year during the remaining Term hereof, Sublessor shall notify Sublessee by written notice of the availability of any such space in the building. Should Sublessee desire to exercise its Right of First Refusal and sublease such available space, Sublessee must notify Sublessor in writing of its desire to sublease the available space within seven (7) calendar days of Sublessee's receipt of Landlord's notice of availability. Within thirty (30) days of the receipt of Sublessee's notice exercising the right to sublease such available space, Sublessee and Sublessor shall enter into an amendment of this agreement setting forth the terms under which the additional space is subleased to Sublessee. The Base Rental shall be at a rental mutually agreed between Sublessee and Sublessor. Failure by Sublessee to exercise its Right of First Refusal within said seven (7) calendar day period, or if exercised, failure to enter into an amendment of this agreement within thirty (30) days of Sublessor's receipt of Sublessee's notice, shall be deemed a waiver of such right and Sublessor shall thereafter be free of any obligation under this Article 2.04 for a period of 12 months. Any exercise by Sublessee of this Right of First Refusal shall be for a minimum of 5,000 rental square feet.
Expansion Space As used in this paragraph, the term “Expansion Space” means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Tenant’s Work Section 5.1 Except as may be expressly provided in this lease, Tenant shall not replace any fixtures in the Premises or make any changes, improvements, alterations or additions (collectively, “Tenant’s Work”), to the Premises, the Real Property, the Building systems, or any part thereof, without Xxxxxxxx’s prior consent. Landlord’s consent shall not be unreasonably withheld or delayed if Tenant’s Work (a) is nonstructural, and (b) does not (i) affect any part of the Real Property outside the Premises (including the Building roof) or the exterior of the Premises, (ii) affect any structural element of the Building, (iii) adversely affect any Building system, or (iv) require an amendment of the certificate of occupancy for the Premises or the Building, ( c) is not visible outside the Premises and (d) is performed only by contractors and subcontractors first approved by Landlord (which approval shall not be unreasonably withheld or delayed). Xxxxxxxx’s consent shall not be required with respect to such of Tenant’s Work as are cosmetic alterations (such as painting the interior of the Premises, carpeting, and installation of shelving and display cases) inside the Premises (“Cosmetic Alterations”), provided Tenant complies with the other applicable provisions of this lease. Tenant’s Work shall be performed, at Tenant’s expense, with diligence when started so as to promptly complete it in a good and worker-like manner using new materials of first class quality and in compliance with this lease, all Laws and Tenant’s Plans (as defined in Section 5.2) as approved by Landlord. As part of Tenant’s Work, Tenant shall soundproof the Premises and install appropriate ventilation if required so that Tenant’s use of the Premises shall not result in noise and/or odors being transmitted outside the Premises. Tenant’s Work shall be fully paid for by Tenant when payment is due and shall not be financed with any conditional sales or title retention agreements or by the granting of any security interests, liens, encumbrances or financing statements. Tenant’s Work shall be deemed, upon installation, to be improvements and betterments that become the property of Landlord at installation, and shall remain upon and be surrendered with the Premises, at the expiration of the Term (or the sooner termination of this lease in accordance with its provisions) unless Landlord notifies Tenant in accordance with the provisions of this Article that Landlord relinquishes its rights thereto, in which case Tenant shall be obligated to remove such Tenant’s Work.
Drawings and Specifications 9.1 A complete list of all Drawings that form a part of the Contract Documents are to be found as an index on the Drawings themselves, and/or may be provided to Developer and/or in the Table of Contents.
Expansion Premises In addition to the Original Premises, commencing on the Expansion Premises Commencement Date (as defined below), Landlord leases to Tenant, and Tenant leases from Landlord, the Expansion Premises.
Tenant Improvement Allowance Subject to the terms of this Section 38 set forth below, there shall be paid by the Landlord as the Landlord’s contribution toward Tenant’s Initial Alterations, the sum (“Allowance”) of $7,191,555.84, based upon a contribution of $68.04 per rentable square foot for 105,696 rentable square feet in the Initial Premises. Tenant shall submit to Landlord Tenant’s good faith estimate (“Qualified Cost Estimate”) of the Qualified Costs (hereinafter defined) to be incurred by Tenant in connection with its move to and the construction of Initial Alterations in the Premises. Installments of the Allowance shall be payable in accordance with the procedures set forth below. Installments of the Allowance, which shall in no event exceed in the aggregate the amount of the Allowance, shall be paid to Tenant (or, at Landlord’s option if Landlord reasonably determines that Tenant is not paying its contractors and such failure to pay may give rise to a lien against the Building, to the order of the contractor that performed the work set forth in the respective invoices) or, at Tenant’s option to Tenant’s contractors, with respect to Qualified Costs theretofore incurred by Tenant (and not theretofore paid to Tenant or which were Tenant’s responsibility as set forth in this Article 38) for which Tenant has submitted a requisition consisting of, (i) in the case of other than costs incurred under architectural and engineering contracts (collectively “Professional Services Contracts”) or under construction contracts, such as furniture or moving or professional fees that are contracted for by Tenant separate from construction and Professional Services Contracts, paid invoices, (ii) in the case of Professional Services Contracts, invoices, and (iii) in the case of construction costs (a) an application for payment and sworn statement of a contractor performing general contracting work in the Premises substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein which is part of the construction contract; (b) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment which is located on AIA Document G702, Application and Certificate of Payment; (c) contractor’s, project managers and subcontractor’s waivers of liens which shall cover all applicable items of Qualified Costs under such construction contracts for which disbursement is being requested and any other statements and forms required for compliance with the mechanics’ lien laws of the Commonwealth of Massachusetts, together with invoices with respect to such Qualified Costs and such other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing the work included in Qualified Costs for which a request for disbursement under such construction contracts is being made; (v) copies of all construction contracts for the such Alterations, together with copies of all change orders, if any; and (iii) a request to disburse from Tenant containing an acknowledgement by Tenant of the work done and a good faith estimate of the cost to complete the Initial Alterations to the Premises. Upon completion of the Initial Alterations, and as part of the requisition for final disbursement of the Allowance for hard construction costs, Tenant shall furnish Landlord with: (1) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Alterations, and (5) the certification of Tenant’s architect to the Landlord that, based on on-site observation and the data comprising the application for disbursement, to the best of the architect’s knowledge, information and belief, the Alterations have progressed as indicated in the application, the quality of the Alterations is in accordance with the construction contract documents and the contractor is entitled to; payment of the amount certified in the application. Notwithstanding the foregoing, if the Qualified Cost Estimate exceeds the Allowance, Tenant shall be entitled to payments with respect to any requisition in accordance with the terms hereof except that each individual disbursement of the Allowance by Landlord shall be in the same ratio to the amount properly requisitioned as the Allowance bears to the Adjusted Qualified Cost Estimate (hereinafter defined). “Adjusted
