Common use of Early Access Clause in Contracts

Early Access. Subtenant shall have the right to enter the Demised ------------ Premises prior to the Commencement Date following full execution of this Sublease, for the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premises.

Early Access. Subtenant shall have After Landlord determines that the right Landlord’s Third Floor Expansion Premises TI Work has sufficiently progressed to the point where permitting Tenant to enter the Demised ------------ Third Floor Expansion Premises will not adversely affect the timely completion of the remaining elements of Landlord’s Third Floor Expansion Premises TI Work, then prior to the Third Floor Expansion Premises Commencement Date following full execution of this Sublease, Landlord shall permit Tenant to enter the Third Floor Expansion Premises for the purpose of (i) testing preparing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Third Floor Expansion Premises for occupancy by Tenant. Any such early entry shall be at Tenant’s sole risk and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoingexpense, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entryand, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, excepting only to the extent same arises from caused by the gross negligence or willful misconduct of Landlord or and of Landlord’s agents, employees or contractors, Landlord shall have no liabilities or obligations to Tenant in connection therewith, including any act liability for damage or negligence injury to persons or property in connection therewith. Upon such entry, Tenant shall be bound by and shall comply with all provisions of Subtenant's employeesthis Lease (excepting only the obligations to pay Base Rent, contractor or any Tenant’s Pro Rata Share of its subcontractorsExpenses, Tenant’s Pro Rata Share of Laboratory Expenses, Tenant’s Pro Rata Share of Taxes or the agents or employees Amenity Fee with respect to the Third Floor Expansion Premises), including the provisions of any of same while they are engaged in this Lease regarding obtaining and maintaining insurance coverages, and the performance of Alterations in the Third Floor Expansion Premises, notwithstanding that the Third Floor Expansion Premises Commencement Date may not yet have occurred. Without limitation, all of such work performed by Tenant in the Third Floor Expansion Premises shall be coordinated with any work within the Demised Premises, or while being performed by Landlord and in or about the Building, arising from such manner as to maintain harmonious labor relations. In no event shall any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into such work by Tenant damage the Building or the Demised Third Floor Expansion Premises by Subtenant and or interfere with the timely performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Landlord’s Third Floor Expansion Premises TI Work, nor its move-in process to the Demised Premises.

Early Access. Subtenant Tenant shall have the right be permitted to enter the Demised ------------ Premises prior to the Commencement Date following full execution (the "Early Access Period") for purposes of installing Tenant's cabling, security system, furniture, fixtures and equipment; provided, however, that Tenant's entry into the Premises during the Early Access Period shall be subject to and conditioned upon Tenant's coordination of such entry with Landlord and Landlord's general contractor(s) so as not to delay Substantial Completion, Tenant providing Landlord with copies of certificates of insurance, complying in all respects with the terms of this SubleaseLease for all insurance required to be provided hereunder prior to entering the Premises, for and Tenant complying with such restrictions and conditions on such access which Landlord deems reasonably necessary (and Tenant acknowledges and agrees that any restrictions and conditions imposed by Landlord with the purpose of (i) testing the equipment attempting to avoid any delay in the Building; (ii) commencing Subtenant's Work Commencement Date shall be deemed reasonable). Except as provided in this Section 2.8, such early access and the Demised Premises installation of such cabling, security system, furniture, fixtures and in other areas equipment shall be subject to all of the Building terms and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms conditions of this Sublease Lease. Tenant will not be obligated to pay rent during its the Early Access Period. In no event shall Tenant or Tenant's employees, agents, consultants, contractors or invitees interfere with any construction being undertaken by or on behalf of Landlord, nor with any inspections or issuance of final approvals by any applicable governmental authority, and if Tenant fails to cease such interference promptly after notice from Landlord specifying the nature of such interference, Landlord shall have the right to terminate Tenant's early entry, other access. Other than those terms relating with respect to the payment gross negligence of any rental amounts. Subtenant shall indemnify Landlord or Landlord's agents, Tenant hereby releases and save Sublandlord harmless discharges Landlord and Landlord's employees, agents, consultants, contractors and manager from and against any and all loss and damageclaims of loss, including damage or injury to person, persons or property, including without limitation any product inventory, which is alleged to the extent same arises from any act have occurred during such period of early access. Landlord makes no representation or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or warranty about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none safety of the above-described work or Premises during any period of early entry shall interfere with or delay in any manner any work to access, as construction and other activities may be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premisesongoing.

Early Access. Subtenant shall Provided and on the express condition that Tenant uses ▇▇▇▇ ▇▇▇▇▇▇▇▇ & Associates as the general contractor to perform the Tenant Work, Landlord will permit Tenant and Tenant’s contractors to access the Premises from and after September 15, 2017 in order to commence the performance of the Tenant Work so long as, in Landlord’s reasonable determination, such access and work can be performed without interference with or delay in the timely performance of any remaining Landlord’s Work. If Tenant does not use ▇▇▇▇ ▇▇▇▇▇▇▇▇ & Associates as the general contractor for the Tenant Work, Tenant will have the no right to enter access the Demised ------------ Premises for the performance of the Tenant Work until the Substantial Completion Date, provided, however, upon the request of Tenant, Landlord shall grant Tenant reasonable access to the Premises following completion of Landlord’s demolition work to the Premises to allow Tenant to perform Customary Pre-Construction Activities (as hereinafter defined), provided such access, in Landlord’s reasonable discretion, is coordinated with and will not interfere with the timely performance of Landlord’s Work. Any early access by Tenant prior to the Commencement Date following full execution of this Sublease, for the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas substantial completion of the Building Landlord’s Work shall be subject to reasonable rules and (iii) regulations as may be established by Landlord from time to test Subtenant's equipment time, including, without limitation, hours of access and systems installed in that the Building and performance of Landlord’s Work shall have priority over any activities that Tenant is conducting or shall propose to conduct during the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating period prior to the payment Substantial Completion of any rental amountsLandlord’s Work. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damageAny interference by Tenant, including damage to person, persons or property, to the extent same arises from any act or negligence of Subtenant's its employees, contractor agents, invitees or any of its subcontractors, or the agents or employees of any of same while they are engaged contractors that causes an actual delay in the performance of any work within the Demised PremisesLandlord’s Work as a result of Tenant’s early access to the Premises shall constitute a Tenant Delay under this Lease. “Customary Pre-Construction Activities” shall mean such architectural and engineering activities that are generally performed in preparation for the construction of first class office space in the financial district of Boston, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for Massachusetts and which do not involve the performance of Subtenant's Work work which physically alters in any way any portion of the Premises or arising from the Building and which do not affect or interfere with the operation of any accident Building systems. Examples of Customary Pre-Construction Activities are the taking or injurypreparation of measurements, surveys, elevations, sketches and layouts. Prior Any such access to the initial entry into the Building or the Demised Premises by Subtenant Tenant and Tenant’s employees, agents, contractors, subcontractors material suppliers and laborers prior to the Substantial Completion Date shall be (i) at Tenant’s sole risk and expense, (ii) coordinated with the timely performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant the Landlord’s Work and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall not interfere with or delay in any manner any work material respect the performance of the Landlord’s Work, and (iii) subject to such reasonable access rules as Landlord may impose based upon the status of completion of Landlord’s Work and the remaining Landlord’s Work to be performed in the Premises, (iv) subject to and upon all of the same terms and conditions of this Lease except for the obligation to pay Rent, (v) conditioned upon Tenant’s complying with and performing, and causing its employees, agents, contractors, subcontractors, material suppliers and laborers to comply with and perform, all of Tenant’s insurance and indemnity obligations and other obligations governing the conduct of Tenant at the ACTIVE/91437610.6 Property under the Lease (provided that no Basic Rent, or Additional Rent shall accrue or be payable during such time), and (vi) to the fullest extent permitted by Sublandlord under this Sublease. Furtherapplicable Laws, Subtenant the installation or placement of any furniture, equipment, construction materials and supplies and other property in the Premises shall be at the sole risk and hazard of Tenant and Landlord shall not be charged by Sublandlord liable for any theft, loss, injury or damage to any such property therein and Tenant shall be solely responsible for the use security of any freight elevatorssuch Tenant’s property, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning materials and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premisessupplies.

Early Access. Subtenant Landlord shall have the right permit Tenant and its agents to enter the Demised ------------ Premises approximately six (6) weeks prior to the Commencement Date (“Early Access Period”) for the sole purpose of examining the Tenant Improvements (to the extent permitted under the Work Letter Agreement or otherwise agreed to by Landlord), installing, at Tenant’s sole cost and expense, its furniture, fixtures, equipment and cabling in the Premises and as otherwise reasonably necessary to perform any facility validations required by Governmental Authorities for Tenant’s Permitted Use, but in no event shall Tenant’s failure to complete such installations or validations during the Early Access Period extend the Commencement Date. Any such entry shall be in a manner and upon terms and conditions and at times reasonably satisfactory to Landlord’s representative. The foregoing license to enter the Premises prior to the Commencement Date following full execution of is, however, conditioned upon Tenant’s agents, contractors and their subcontractors and employees reasonably cooperating and not unreasonably interfering with the work being performed by Landlord. If at any time such entry shall unreasonably interfere with the work being performed by Landlord, this Sublease, license may be withdrawn by Landlord upon twenty-four (24) hours written notice to Tenant. Tenant shall be liable for any damages caused by Tenant’s activities at the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, except to the extent caused by Landlord’s or Landlord’s contractors’ gross negligence or willful misconduct. Such license is further conditioned upon the compliance by Tenant’s contractors with all requirements imposed by Landlord on third party contractors, including, without limitation, the maintenance by Tenant and its contractors and subcontractors of workers’ compensation and public liability and property damage insurance in amounts and with companies and on forms satisfactory to Landlord, with certificates of such insurance being furnished to Landlord prior to proceeding with any such entry. The entry shall be deemed to be under all of the provisions of this Lease except as expressly set forth in this Section 41.2. During the Early Access Period, Tenant shall have no obligation to pay Basic Rent, Operating Expenses, Real Property Taxes or costs for electricity, gas or HVAC (provided that Tenant’s usage thereof during such Early Access Period is not excessive). Landlord shall not be liable in any way for any injury, loss or damage which may occur to any such work being performed by Tenant, the same arises from any act being solely at Tenant’s risk, except to the extent caused by Landlord’s or Landlord’s contractors’ gross negligence or willful misconduct. All costs and expenses in connection with or arising out of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or Tenant during such early entry shall interfere be borne by Tenant, and all payments therefor shall be made by Tenant promptly as they become due. Tenant shall, at its sole cost and expense, comply with all applicable laws, ordinances, regulations and policies governing its work. Tenant shall defend, indemnify and hold Landlord and its members, agents, employees, partners, and their respective employees, partners, officers, directors, agents, representatives, successors and assigns, harmless from and against any and all suits, claims, actions, losses, costs, liabilities or delay expenses (including reasonable attorneys’ fees and claims for workers’ compensation) to the extent arising out of or in connection with any manner any and all work to be performed by Sublandlord under this Subleaseor (excepting the Tenant Improvements or any other work performed by Landlord) on behalf of Tenant or Tenant’s contractors during such early entry (including, but not limited to, claims for breach of warranty, personal injury or property damage), except to the extent caused by Landlord’s or Landlord’s contractors’ gross negligence or willful misconduct. FurtherLandlord shall have the right, Subtenant shall not be charged by Sublandlord for the use in Landlord’s sole and absolute discretion, to settle, compromise, or otherwise dispose of any freight elevatorsand all suits, access to claims, and actions against any of the Building's loading docksindemnified parties arising out of or in connection with the work performed by Tenant during any early entry. Tenant shall coordinate such entry with Landlord’s building manager, utility usage or and such entry shall, except as expressly set forth in this Section 41.2, be made in compliance with all terms and conditions of this Lease and the use of any other Building facilities or services during the initial planning Rules and subsequent construction of Subtenant's Work, nor its move-in process to the Demised PremisesRegulations attached hereto.

Early Access. Subtenant From and after the execution of this First Amendment and continuing up and until the Expansion Date (the “Early Access Period”), to the extent it does not interfere with the Landlord Work, Tenant may enter into the Expansion Space for the sole purpose of completing Landlord-approved work to fixture the Expansion Space for Tenant’s business operations, which shall have the be performed at Tenant’s sole cost and expense and shall be subject to all applicable ordinances and building codes or other laws governing Tenant’s right to enter occupy or perform in the Demised ------------ Expansion Space prior to the Expansion Date. Such entry into the Expansion Space shall also be subject to the requirements that (1) prior to Tenant or any of the Tenant Parties obtaining access or entry to the Expansion Space, Tenant must first satisfy the Access Conditions (as hereinafter defined), and (2) Tenant and any and all Tenant Parties shall not disturb the tenancies of any tenants near the Expansion Space or unreasonably interfere with the business operations of such tenants. Tenant agrees that any such entry onto the Expansion Space during the Early Access Period shall be deemed to be under all of the terms, covenants, conditions and provisions of the Lease (except as to the covenant to pay Rent). Subject to Landlord’s indemnity under Section 17.3 of the Lease, Tenant further agrees that Landlord shall not be liable in any way for any injury or death to any person or persons, loss or damage to any of Tenant’s property at the Expansion Space or loss or damage to property placed thereon prior to the Expansion Date, the same being at Tenant’s sole risk and expense. Any such access or performance in the Premises prior to the Commencement Date following full execution shall also be subject to (A) Tenant first providing to Landlord the Certificates of this Sublease, for the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas Insurance required under Section 10.2 of the Building and Lease (iiithe conditions described in clause (A) are collectively referred to test Subtenant's equipment and systems installed in herein as the Building and the Demised Premises“Access Conditions”). Notwithstanding the foregoing, Subtenant Tenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by place all terms of this Sublease during its early entry, other than those terms relating utilities into their name prior to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none commencement of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premises.Early Access Period

Early Access. Subtenant So long as such access does not interfere with Landlord’s construction of the Landlord’s Work, Tenant shall have the right to enter access the Demised ------------ Expansion Premises prior to the Commencement Date following full execution completion of this Sublease, the Landlord’s Work for the purpose of installing its equipment, data, telecommunications systems and trade fixtures (i“Tenant’s Work”). Such access shall be subject to reasonable scheduling by Landlord. In connection with such access, Tenant agrees (a) testing to cease promptly upon notice from Landlord any Tenant’s Work which has not been approved by Landlord or is not in compliance with the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas provisions of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons Lease or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry which shall interfere with or delay the performance of Landlord’s Work, and (b) to comply promptly with all reasonable procedures and regulations prescribed by Landlord from time to time for coordinating the Landlord’s Work and the Tenant’s Work, each with the other and with any other activity or work in the Building. Such access shall be subject to all of the terms of the Lease except the obligation to pay Rent until otherwise required by the terms of the Lease; provided, however, that if Tenant commences operation of its business in all or any manner any work portion of the Expansion Premises, the date on which Tenant commences operation of its business shall be deemed the Expansion Date and Tenant shall be obligated to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access pay Rent pursuant to the Building's loading docksterms of this First Amendment. Without limiting the foregoing, utility usage prior to accessing the Expansion Premises, Tenant shall provide to Landlord, in form and substance reasonably acceptable to Landlord: (i) a detailed description of and schedule for Tenant’s Work; (ii) the names and addresses of all contractors who or which will be entering the use Expansion Premises on behalf of any other Building facilities Tenant to perform Tenant’s Work or services during will be supplying materials for such work, and the initial planning approximate number of individuals who will be present in the Expansion Premises; (iii) copies of all contracts pertaining to Tenant’s Work; (iv) copies of all plans and subsequent construction specifications pertaining to Tenant’s Work; (v) copies of Subtenant's all licenses and permits required in connection with the performance of Tenant’s Work; and (vi) certificates of insurance (in amounts reasonably satisfactory to Landlord and with the parties identified in, nor its move-in process to or required by, the Demised PremisesLease named as additional insureds).

Early Access. Subtenant shall have the right to enter the Demised ------------ Premises prior to the Commencement Date following Following full execution of this Sublease, Sublandlord shall provide Subtenant with early access to the Subleased Premises commencing on October 16, 2017 (the “Access Date”). Such early occupancy shall be subject to all of the terms and conditions of this Sublease, except for Subtenant’s obligation to pay Sublease Base Rent, which obligation shall commence upon the Sublease Commencement Date. Such period of early occupancy, if any, shall commence on the Access Date and continue through the date immediately preceding the Sublease Commencement Date (the “Early Occupancy Period”). During the Early Occupancy Period, Subtenant may enter the Subleased Premises for the purpose of general business setup, including installation of fixtures, furniture, equipment, telephones, data lines and other telecommunications equipment, and for 10 – 15 of Tenant’s general, finance and administration employees to use the Subleased premises during the Early Occupancy Period for office purposes; provided, however, that (ia) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises Subtenant shall be solely responsible for all fixtures, furniture, equipment, telephones and in other areas of the Building items installed by Subtenant and for any loss or damage thereto from any cause whatsoever and (iiib) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence begin any of Subtenant's Work construction or demolition in the Demised Subleased Premises until after obtaining without the consent prior written approval of Sublandlord and Prime Landlord Master Landlord. Subject to Section 10.2 below, the provisions of plans Sections 9 and specifications for same. 23 of the Master Lease shall apply in full during the Early Occupancy Period, and Subtenant shall abide (x) provide certificates of insurance evidencing the existence and amounts of liability insurance carried by all terms Subtenant and its agents and contractors, reasonably satisfactory to Sublandlord, prior to and as a condition of this Sublease during its such early entry, other than those terms relating and (y) comply with all Laws applicable to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged ’s activities in the performance of any work within Subleased Premises during the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by SublandlordEarly Occupancy Period. Subtenant acknowledges and agrees that none Sublandlord may be completing the process of moving its personnel and personal property out of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Subleased Premises during the Early Occupancy Period. Sublandlord under this Sublease. Further, and Subtenant shall not be charged by Sublandlord for the cooperate with one another to coordinate use of any freight elevators, the Subleased Premises during the Early Occupancy Period to facilitate efficient completion of Subtenant’s move-out with Subtenant’s access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised PremisesSubleased Premises as provided above.

Early Access. Subtenant Tenant shall have be given access to the right Premises prior to enter installation of the Demised ------------ ceiling grid in order to allow Tenant to install telephone and other communications and media lines and systems, computer cabling, and related similar matters. The date of Early Access to the Premises and the time by which installation of Tena▇▇'▇ ▇ork must be completed will be coordinated with the General Contractor. Tenant and General Contractor shall work together to ensure that Tena▇▇'▇ ▇ork is completed in an efficient and timely manner and will not unreasonably impede, interfere with or delay the progress of construction of the Tenant Improvements. Tenant shall perform such installation in accordance with all guidelines promulgated by General Contractor and shall execute and require its contractors and subcontractors to execute such releases, indemnifications and other documents that General Contractor requires of its own subcontractors. Any and all costs of installation of such items shall be at Tenant's sole cost and expense. Tenant shall also be given Early Access to the Premises for purposes of storing its furniture and personal property in portions of the Premises in which Tenant Improvements are substantially complete. General Contractor shall designate the areas in which such storage can occur to ensure that such storage will not interfere with the construction of the Tenant Improvements. Tenant hereby releases Landlord, General Contractor and all of their agents, employees, licensees, invitees and subcontractors from all liability for loss or damage to Tenant's personal property stored on the Premises prior to the Commencement Date following Date. Tena▇▇ ▇▇▇ees to maintain insurance on all said property and hereby assumes full execution risk of this Subleaseloss or damage to said personal property and here▇▇ ▇▇rees to defend, for the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord hold Landlord, General Contractor, their agents, employees, licensees, invitees and subcontractors harmless from and against all any claims, loss and damage, including damage or liability related to person, persons or said stored personal property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premises.

Early Access. Subtenant shall have Neither Tenant nor any person claiming by, through or under Tenant (collectively, the right to “Tenant Parties”) may enter the Demised ------------ Premises for any purpose prior to the Commencement Date; provided, however, upon written request by Tenant (which may be made by email), Landlord shall, subject to the terms and conditions set forth in this Section 9, grant to Tenant and certain other Tenant Parties a license for Tenant and certain other Tenant Parties to have access to the Premises prior to the Expected Commencement Date following full execution of this SubleaseDate. Any such access shall, prior to the date which is twenty-one (21) days preceding the Expected Commencement Date, be solely for the purpose of allowing Tenant to install its voice and data equipment and cabling in accordance at the appropriate times necessary to conform with the “critical path” of the Tenant Improvements, and on or after the date which is twenty-one (21) days preceding the Expected Commencement Date, for the additional purpose of installing in the Premises Tenant’s furniture, fixtures, and equipment as may be necessary to make the Premises ready for Tenant’s use and occupancy (as applicable, “Tenant’s Pre-Occupancy Work”). Tenant shall deliver to Landlord Tenant’s written request for early access to the Premises not less than one (1) business day prior to the date on which Tenant desires such access and such notice shall be accompanied by each of the following items: (i) testing the equipment names and addresses of all Tenant Parties who will be entering the Premises on behalf of Tenant to perform Tenant’s Pre-Occupancy Work; and (ii) certificates of insurance evidencing such coverages reasonably required by Landlord to be maintained by contractors and occupants in the Building; (ii) commencing Subtenant's . Any and all access to the Premises and the performance of the Tenant’s Pre-Occupancy Work shall be subject to Landlord’s reasonable scheduling requirements. Tenant shall cause all Tenant Parties to observe all construction rules and regulations promulgated by Landlord from time to time in connection with the performance of work in the Demised Building. If at any time any Tenant Party shall fail to observe such rules and regulations, then Landlord may revoke such license with respect to the offending Tenant Party immediately upon notice to Tenant. Tenant’s Pre-Occupancy Work shall be performed at Tenant’s sole risk, cost and expense and no delay in the delivery of the Premises to Tenant caused by Tenant’s entry to the Premises or Tenant’s Pre-Occupancy Work shall delay the Commencement Date. Landlord shall not be liable for any injury, loss or damage which may occur to Tenant’s Pre-Occupancy Work (including without limitation any property of Tenant placed in the Premises) and Tenant shall indemnify and hold harmless Landlord for any damage to Tenant’s Pre-Occupancy Work, the Premises or to any portion of the Tenant Improvements arising from Tenant’s Pre-Occupancy Work or otherwise caused by any Tenant Party. Upon written request by Tenant prior to the installation of Tenant’s Pre-Occupancy Work, Landlord agrees to provide a written list of any improvements constituting part of Tenant’s Pre-Occupancy Work that Landlord will require Tenant to remove from the Premises at the end of the Lease Term. At the end of the Lease Term, Tenant shall not be required to remove any improvements constituting part of Tenant’s Pre-Occupancy Work which are not identified on such list (such items being the “Non-Removal Tenant’s Pre-Occupancy Work”). Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 ROOM # ROOM NAME DOOR NO. WIDTH HEIGHT THICK MATL SELF CLOSURE LOCKING GLASS TYPE FRAME MATL FUNCTION NOTES 400 Waiting 400a 6’-0’’ 8“0” — GLASS Y Y Y — FRAMELESS SWIPECARD BUILDING STANDARD HERCULTE 402 Interview Room 402a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 403 Interview Room 403a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 405 Visitor Servery/Coats 405a 6’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE 406 Executive Conference 406a 6’-0” 8“0” — GLASS N N Y — Drywall return BUTT GLASS/FLAT TRACK BARN DOOR HARDWARE/SS 407 VP Office 407a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 408 MGR Office 408a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 409 MGR Office 409a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 410 Team RM/Phone Enclave 410a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 411 Open Office 411a 3’-0” 8“0” 1-3/4” MAPLE Y Y Y PASSAGE LITE HM CARD ACCESS SWIPE CARD ACCESS 412 VP Office 412a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 413 VP Office 413a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 414 VP Office 414a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 415 VP Office 415a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 417 MGR Office 417a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 418 MGR Office 418a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 419 MGR Office 419a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 421 MGR Office 421a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 422 MGR Office 422a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 423 MGR Office 423a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 424 VP Office 424a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 425 Director Office 425a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 426 Conference 426a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 428 Copy/Mail 428a 3’-6” 8“0” — — — — — — — FRAMED OPENING 429 Mgr Office 429a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 430 Mgr Office 430a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 434 Dining 434a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 436 Vending 436a 3’-0” 8“0” — — N N N — — FRAMED OPENING 436b 3’-0” 8“0” — — N N N — — FRAMED OPENING 438 Kitchen Storage 438a 3’-0” 8“0” 1-3/4” MAPLE — Y — — HM STOREROOM 440 Health Services 440a 3’-0” 8“0” 1-3/4” MAPLE N Y N — HM PRIVACY PRIVACY LOCK 442 Hardware Storage 442a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM STOREROOM 443 LAN Room 443a 3’-0” 8“0” 1-3/4” MAPLE N Y Y PASSAGE LITE HM CARD ACCESS SWIPECARD 445 Director Office 445a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 446 Phone Enclave 446a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 447 Director Office 447a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 448 Open Office 448a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SIDELITE 448b 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SIDELITE 449 HR Storage 449a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PRIVACY PRIVACY LOCK NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 450 Director Office 450a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 452 Team Rm/Phone Enclave 452a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 454 Open Office 454a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SWIPECARD 455 Director Office 455a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 456 Director Office 456a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 457 Director Office 457a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 459 Mgr Office 459a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 460 Mgr Office 460a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 461 Mgr Office 461a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 462 Passage 462a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SWIPECARD 463 Phone Enclave 463a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE 465 Mgr Office 465a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 466 Mgr Office 466a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 467 Mgr Office 467a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 468 Director Office 468a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 469 Director Office 469a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 470 Director Office 470a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 471 Conference 471a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 474 Mgr Office 474a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 475 Mgr Office 475a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 477 Passage 477a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM SWIPE CARD ACCESS SWlPECARD/SIDE LITE 478 Mgr Office 478a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 479 Mgr Office 479a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 480 Mgr Office 480a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 481 Conference 481a 3’-0” 8“0” 1-3/4” MAPLE N N Y — HM PASSAGE SIDELITE 482 Director Office 482a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 483 VP Office 483a 3‘-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 484 VP Office 484a 3‘-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 485 Passage 485a 3‘-0” 8“0” 1-3/4” MAPLE Y Y Y PASSAGE LITE HM SWIPE CARD ACCESS SWlPECARD/SIDE LITE 486 Executive Lounge 486a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS Plumbing Fixture Schedule Client: Connecture Atlanta Project No: 13004-01 Date: September 20, 2013 Revised: 404 Visitor Servery sink Kohler K3362-3 Staccato 25” single bowl sink, 3-hole, self rimming stainless steel faucet Kohler K15850-4M Coralis Faucet w/Lever Handles polished chrome disposal by LL Engineer 435 Kitchen sink Kohler K3362-3 Staccato 25” single bowl sink, 3-hole, self rimming stainless steel faucet Kohler K-15888-K Coralis Faucet w/Leverl Handles disposal by LL Engineer 439 Health Services toilet Kohler K-3949 Highline Comfort Height, 1.28 GPF, left hand lever White sink Kohler ▇▇▇▇▇-▇-▇ ▇▇▇▇▇▇▇▇▇ dropinsink w/concentricecircles, cast iron, 8” centers White faucet Kohler ▇-▇▇▇▇▇-▇ ▇▇▇▇▇▇ widespread faucet w/lever handles White PROVIDE ALL RELATED KOHLER ACCESSOSSORIES Hot water at all sink locations Reference is made to the following plans prepared by InteriorLOGIC for Connecture in other areas the Brookfield ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇, dated April 27, 2012: 1. Drawings A200 – Connecture Second Floor Demolition Plan prepared by InteriorLOGIC, dated 4/27/12 A201 – Connecture Second Floor Partition Plan prepared by InteriorLOGIC, dated 4/27/12 A203 – Connecture Second Floor Finish Plan prepared by InteriorLOGIC, dated 4/27/12 A204 – Connecture Second Floor Electrical Plan prepared by InteriorLOGIC, dated 4/27/12 A204 – Connecture Second Floor Ceiling Plan prepared by InteriorLOGIC, dated 4/27/12 A300 – Connecture Third Floor Demolition Plan prepared by InteriorLOGIC, dated 4/27/12 A301 – Connecture Third Floor Partition Plan prepared by InteriorLOGIC, dated 4/27/12 A303 – Connecture Third Floor Finish Plan prepared by InteriorLOGIC, dated 4/27/12 A304 – Connecture Elevations and Details prepared by InteriorLOGIC, dated 4/27/12 A305 – Connecture Elevations and Details prepared by InteriorLOGIC, dated 4/27/12 A306 – Connecture Floor Pattern Plan prepared by InteriorLOGIC, dated 4/27/12 A307 – Connecture Electrical Schematic prepared by InteriorLOGIC, dated 4/27/12 A308 – Connecture Third Floor Ceiling Plan prepared by InteriorLOGIC, dated 4/27/12 2. Schedules and Specifications A. Workletter Finish and Material Specification B. Room Finish Schedule C. Product Cut Sheets D. Casework Schedule E. Door Schedule 3. AutoCAD Files A. Second Floor B. Third Floor 1. The sidewalks, and public portions of the Building, such as entrances, passages, courts, elevators, vestibules, stairways, corridors or halls, and the streets, alleys or ways surrounding or in the vicinity of the Building shall not be obstructed, even temporarily, or encumbered by Tenant or used for any purpose other than ingress and egress to and from the Premises. 2. No awnings or other projections shall be attached to the outside walls of the Building. No curtains, blinds, shades, louvered openings, tinted coating, film or screens shall be attached to or hung in, or used in connection with, any window, glass surface or door of the Premises, without the prior written consent of Landlord, unless installed by Landlord. 3. No sign, advertisement, notice or other lettering shall be exhibited, inscribed, painted or affixed by Tenant on any part of the outside of the Premises or Building or on corridor walls or windows or other glass surfaces (iii) including without limitation glass storefronts). Signs on entrance door or doors shall conform to test Subtenant's equipment building standard signs, samples of which are on display in Landlord’s rental office. Signs on doors shall, at Tenant’s expense, be inscribed, painted or affixed for each tenant by sign makers approved by Landlord. In the event of the violation of the foregoing by Tenant, Landlord may remove same without any liability, and systems installed may charge the expense incurred by such removal to Tenant. 4. The sashes, sash doors, skylights, windows, heating, ventilating and air conditioning vents and doors that reflect or admit light and air into the halls, passageways or other public places in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant building shall not commence be covered or obstructed by Tenant, nor shall any bottles, parcels, or other articles be placed on the window ▇▇▇▇▇. 5. No show cases or other articles shall be put in front of Subtenant's Work or affixed to any part of the exterior of the Building, nor placed in the Demised Premises until after obtaining public halls, corridors, or vestibules without the prior written consent of Sublandlord Landlord. 6. The water and Prime Landlord of plans wash closets and specifications other plumbing fixtures shall not be used for same. Subtenant shall abide by all terms of this Sublease during its early entry, any purposes other than those terms relating for which they were constructed, and no sweepings, rubbish, rags, or other substances shall be thrown therein. All damages resulting from any misuse of the fixtures shall be borne by Tenant. 7. Tenant shall not in any way deface any part of the Premises or the Building. If Tenant desires to use linoleum or other similar floor covering, an interlining of builder’s deadening felt shall be first affixed to the payment floor, by a paste or other material, soluble in water; the use of cement or other similar adhesive materials, which are not water soluble, are expressly prohibited. 8. No bicycles, vehicles, or animals of any rental amounts. Subtenant kind shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons be brought into or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while kept in or about the BuildingPremises. No cooking shall be done or permitted by Tenant on the Premises except in conformity to law and then only in the utility kitchen, arising if any, as set forth in Tenant’s layout, which is to be primarily used by Tenant’s employees for heating beverages and light snacks. Tenant shall not cause or permit any unusual or objectionable odors to be produced upon or permeate from any liens or claims the Premises. 9. No space in the Building shall be used for services rendered or labor or materials furnished in manufacturing, distribution, or for the performance storage of Subtenant's Work merchandise or arising from any accident for the sale of merchandise, goods, or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance property of any work therein, Subtenant shall furnish Sublandlord, kind at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premisesauction.

Early Access. Subtenant Tenant shall have be responsible for installing, at Tenant’s sole cost and expense, any and all work (other than Landlord’s Work) for the MMR Expansion Space (collectively, the “Additional Alterations”). Tenant’s right to enter perform the Demised ------------ Premises Additional Alterations shall be subject to Landlord’s prior written approval of the plans and specifications therefor (the “Additional Alterations Construction Drawings and Specifications”) and the contractors who will perform such work, such consent not to be unreasonably withheld, conditioned or delayed. Landlord shall respond to a request by Tenant for Landlord’s consent to the Commencement Date following full execution of this Sublease, for the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant the Additional Alterations and the contractors who will perform the Additional Alterations within ten (10) business days after such a request Tenant and its contractors, subcontractors, space planner/interior architect, engineers, consultants, vendors, suppliers and other representatives, and their respective employees, shall abide by all terms of this Sublease during its early entry, other than those terms relating be permitted to enter the MMR Expansion Space (“Early Access”) at least thirty (30) days prior to the payment MMR Expansion Space Completion Date (the “Early Access Period”) for the purposes of any rental amountsinspecting same, for performing the Additional Alterations, as well as installing fixtures and equipment (including, but not limited to, telephone, communications and computer equipment, further including wiring and cabling for same). Subtenant Any such permission shall indemnify constitute a license only, conditioned upon Tenant’s: (a) working in harmony with Landlord and save Sublandlord harmless from Landlord’s agents, contractors, workmen, mechanics and suppliers and with other tenants and occupants of the Building; and (b) furnishing Landlord with such insurance as Landlord may reasonably require against all loss and damageliabilities which may arise out of such entry. Notwithstanding anything in this Lease to the contrary, including damage to person, persons or property, the Early Access Period may be reduced by Landlord to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior such Early Access materially interferes with Landlord’s ability to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's complete Landlord’s Work, nor its move-in process to the Demised Premises.

Early Access. Subtenant Subject to the following provisions of this Section 3.3, Tenant shall have the right to enter the Demised ------------ Premises prior from and after the Effective Date solely for purposes of installing Tenant’s computer systems, telephone equipment, cabling, furniture, fixtures and special equipments (but not to operate Tenant’s business), and such early entry for such purposes shall not constitute occupancy for operation of Tenant’s business and shall not trigger the Lease Commencement Date following full execution of this SubleaseDate. Tenant agrees (a) any such early entry by Tenant shall be at Tenant’s sole risk, for the purpose of (ib) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in Tenant shall not unreasonably interfere with Landlord or other areas of the Building and (iii) to test Subtenant's equipment and systems installed tenants in the Building or the Building Park, (c) Tenant shall comply with and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide be bound by all terms provisions of this Sublease Lease during its the period of any such early entry, other than those terms relating to entry except for the payment of any rental amounts. Subtenant shall indemnify Base Rent and Tenant’s Pro Rata Share of Operating Expenses, (d) prior to entry upon the Premises by Tenant and subject to Section 13.4, Tenant agrees to pay for and provide to Landlord certificates evidencing the existence and amounts of liability insurance carried by Tenant, which coverage must comply with the provisions of this Lease relating to insurance, (e) Tenant and its agents and contractors agree to comply with all Laws (as defined below) required to perform its work during the early entry on the Premises, and (f) Tenant agrees to indemnify, protect, defend (with counsel selected by Landlord) and save Sublandlord the Indemnitees (as defined below) and the Premises harmless from and against any and all loss liens, liabilities, losses, damages, costs, expenses, demands, actions, causes of action and damageclaims (including, including damage to personwithout limitation, persons attorneys’ fees and legal costs) (collectively, “Claims”) arising out of the early entry, use, construction, or propertyoccupancy of the Premises by Tenant or its agents, employees or contractors, except to the extent same arises from any act such Claims arise out Landlord’s gross negligence or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premiseswillful misconduct.

Early Access. Subtenant Subject to the provisions below, from and after the Effective Date, Tenant shall have the right to enter the Demised ------------ Expansion Premises prior in order to generally prepare the Expansion Premises for occupancy including the storage of product, but not to conduct normal business operations (“Early Access”). Other than in connection with Landlord’s Work, the Repair Work or any emergency relating to the Commencement Expansion Premises, Landlord shall not grant access to the Expansion Premises to any party between the Effective Date following full execution and the First Expansion Date and the Second Expansion Date, as applicable. Tenant’s right to Early Access to the Expansion Premises is subject to, and conditioned upon, the following: a. Early Access is only permitted if, and to the extent, permitted by applicable Governmental Requirements. b. Tenant shall comply with all the terms and conditions of this Sublease, for the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence Lease during any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entryEarly Access, other than those terms relating the obligation to pay Base Rent and its share of Operating Expenses with respect to the payment Expansion Premises. Nothing herein shall relieve Tenant from its obligations under the Lease with respect to the Existing Premises. c. Tenant shall not unreasonably interfere with Landlord’s completion of the Landlord’s Work; d. Tenant will provide written notice to Landlord prior to any Early Access and Landlord shall have the right to have a representative present during such access so long as Landlord does not delay Tenant’s Early Access to the Expansion Premises. e. Tenant shall not begin its normal business operations from the Expansion Premises until the First Expansion Date with respect to the First Expansion Premises or the Second Expansion Date with respect to the Second Expansion Premises, as the case may be. f. Notwithstanding anything to the contrary contained herein, Tenant does hereby expressly acknowledge and agree that the storage and installation of fixtures and Tenant’s personal property (including equipment) in the Expansion Premises shall be at Tenant's sole risk, cost and expense, and that Landlord shall not be liable for and Tenant hereby releases Landlord from any and all liability for any damage thereto occasioned by any act of God or by any acts, omissions or negligence of any rental amountspersons; provided, however, that Landlord shall be responsible for its gross negligence or willful misconduct and the gross negligence or willful misconduct of its employees, officers, directors, agents, contractors, and subcontractors. Subtenant shall indemnify Tenant does hereby further agree to indemnify, defend (with counsel reasonably acceptable to Landlord), and save Sublandlord hold harmless Landlord and its employees, officers, directors, agents and contractors from and against any and all loss claims, liabilities, losses, actions, causes of action, demands, costs and damageexpenses (including, including damage without limitation, attorneys' fees at the trial and appellate levels) of any and every nature arising out of or in any way relating to personTenant's Early Access; provided, persons however, that Tenant shall not indemnify Landlord for any matter arising from Landlord’s gross negligence or property, to willful misconduct or the extent same arises from any act gross negligence or negligence willful misconduct of Subtenant's its employees, contractor or any of its subcontractorsofficers, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premisesdirectors, or while in or about the Buildingagents, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work thereincontractors, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premises.

Early Access. Subtenant and Subtenant’s representatives shall have the right to enter the Demised ------------ Subleased Premises during the period, if any, commencing on the date Subtenant enters the Subleased Premises for the purpose set forth in this Section 2.2 but in no event prior to the Effective Date (“Early Access Date”) and ending on the day immediately preceding the Commencement Date following full execution for the sole purposes of construction of the Initial Subtenant Alterations (defined in Section 14.2 below), installation of Subtenant’s personal property and the testing of equipment, furniture, fixtures and voice and data cabling, all subject to the terms, conditions and requirements of this Sublease. All of the rights and obligations of the parties under this Sublease (other than Subtenant’s obligation to pay Base Rent, but expressly including without limitation Subtenant’s obligation to pay excess utility charges, Subtenant’s obligation to carry insurance, Subtenant’s indemnification obligations, and/or Subtenant’s liability for damages, costs and expenses incurred by Sublandlord by reason of any default by Subtenant or failure on Subtenant’s part to comply with the terms of this Sublease) shall commence upon the Early Access Date, and Subtenant shall be deemed to occupy the Subleased Premises from and after the Early Access Date. Subtenant shall be liable for any damages to the Subleased Premises caused by Subtenant’s activities at the Subleased Premises from and after the Early Access Date and, prior to entering the Subleased Premises, Subtenant shall obtain all insurance it is required to obtain hereunder and shall provide certificates of such insurance to Sublandlord. Subtenant shall coordinate such entry with Sublandlord, and such entry shall be made in compliance with all terms and conditions of this Sublease, the Master Lease and the rules and regulations attached to the Master Lease. Notwithstanding the above, Subtenant and Subtenant’s representatives shall have the right to enter the Subleased Premises following the Effective Date with prior notice to Sublandlord, for the purpose of planning the Initial Subtenant Alterations (ino work of construction or demolition may be carried out during any such entry) testing and such access to the equipment in Subleased Premises shall not be deemed to trigger the Building; (ii) commencing Subtenant's Work in Early Access Date and the Demised Premises rights and in other areas obligations of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant parties under this Sublease shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premisessuch access.

Early Access. Subtenant Tenant shall have the right to enter the Demised ------------ Premises 15 days prior to the Commencement Date for the purpose of installing Tenant’s computer and telephone cabling, fixtures, furniture, and equipment provided that (a) such entry will not delay or hamper the completion of the Tenant Improvements, (b) Tenant and its vendors and contractors have obtained all governmentally required permits separate from any permits obtained by Landlord as to work to be performed by Landlord, if any, (c) Landlord may revoke or restrict Tenant’s or its contractors’ early access to the Premises if such access interferes with, hampers, or prevents completion of the Tenant Improvements at the earliest possible date, (d) Tenant’s access to the Premises shall be subject to all of the terms and provisions of the Lease, except as to the payment of Rent, (e) any entry by Tenant in the Premises prior to the Commencement Date following full execution shall be at Tenant’s sole risk and subject to Tenant coordination with Landlord’s project or property manager, and (f) all work by Tenant’s contractors is subject to the administrative supervision of this Sublease, Landlord and its contractor. Landlord assumes no responsibility or liability for injury to persons or damage to property caused by the purpose of (i) testing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised Premises and in other areas Tenant’s exercise of the Building rights and (iii) to test Subtenant's equipment privileges granted in this paragraph, and systems installed in the Building Tenant shall indemnify, defends, and the Demised Premises. Notwithstanding the foregoing, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime hold Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and any loss, cost, damage, including damage liability, or expense suffered or incurred by Landlord as a result thereof. Tenant shall adopt a schedule for its work in conformance with Landlord’s schedule for the Tenant Improvements and shall conduct its work in such a manner as to person, persons or property, maintain harmonious labor relations. All delays to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while in or about the Building, arising from any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises Tenant Improvements caused by Subtenant and the performance of any work therein, Subtenant Tenant’s early access shall furnish Sublandlord, at Subtenant's sole cost, be deemed a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord Tenant Delay under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised PremisesLease.

Early Access. Subtenant shall have Neither Tenant nor any person claiming by, through or under Tenant (collectively, the right to “Tenant Parties”) may enter the Demised ------------ Premises for any purpose prior to the Commencement Date; provided, however, upon written request by Tenant (which may be made by email), Landlord shall, subject to the terms and conditions set forth in this Section 9, grant to Tenant and certain other Tenant Parties a license for Tenant and certain other Tenant Parties to have access to the Premises prior to the Expected Commencement Date following full execution of this SubleaseDate. Any such access shall, prior to the date which is twenty-one (21) days preceding the Expected Commencement Date, be solely for the purpose of allowing Tenant to install its voice and data equipment and cabling in accordance at the appropriate times necessary to conform with the “critical path” of the Tenant Improvements, and on or after the date which is twenty-one (21) days preceding the Expected Commencement Date, for the additional purpose of installing in the Premises Tenant’s furniture, fixtures, and equipment as may be necessary to make the Premises ready for Tenant’s use and occupancy (as applicable, “Tenant’s Pre-Occupancy Work”). Tenant shall deliver to Landlord Tenant’s written request for early access to the Premises not less than one (1) business day prior to the date on which Tenant desires such access and such notice shall be accompanied by each of the following items: (i) testing the equipment names and addresses of all Tenant Parties who will be entering the Premises on behalf of Tenant to perform Tenant’s Pre-Occupancy Work; and (ii) certificates of insurance evidencing such coverages reasonably required by Landlord to be maintained by contractors and occupants in the Building; (ii) commencing Subtenant's . Any and all access to the Premises and the performance of the Tenant’s Pre-Occupancy Work shall be subject to Landlord’s reasonable scheduling requirements. Tenant shall cause all Tenant Parties to observe all construction rules and regulations promulgated by Landlord from time to time in connection with the performance of work in the Demised Building. If at any time any Tenant Party shall fail to observe such rules and regulations, then Landlord may revoke such license with respect to the offending Tenant Party immediately upon notice to Tenant. Tenant’s Pre-Occupancy Work shall be performed at Tenant’s sole risk, cost and expense and no delay in the delivery of the Premises to Tenant caused by Tenant’s entry to the Premises or Tenant’s Pre-Occupancy Work shall delay the Commencement Date. Landlord shall not be liable for any injury, loss or damage which may occur to Tenant’s Pre-Occupancy Work (including without limitation any property of Tenant placed in the Premises) and Tenant shall indemnify and hold harmless Landlord for any damage to Tenant’s Pre-Occupancy Work, the Premises or to any portion of the Tenant Improvements arising from Tenant’s Pre-Occupancy Work or otherwise caused by any Tenant Party. Upon written request by Tenant prior to the installation of Tenant’s Pre-Occupancy Work, Landlord agrees to provide a written list of any improvements constituting part of Tenant’s Pre-Occupancy Work that Landlord will require Tenant to remove from the Premises at the end of the Lease Term. At the end of the Lease Term, Tenant shall not be required to remove any improvements constituting part of Tenant’s Pre-Occupancy Work which are not identified on such list (such items being the “Non-Removal Tenant’s Pre-Occupancy Work”). SCHEDULE C-1 PROJECT SCHEDULE C-8 SCHEDULE C-2 FINAL SPACE PLAN C-10 C-11 InteriorLOGIC, Inc. Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 SIZE ROOM # ROOM NAME DOOR NO. WIDTH HEIGHT THICK MATL SELF CLOSURE LOCKING GLASS TYPE FRAME MATL FUNCTION NOTES 400 Waiting 400a 6’-0’’ 8“0” — GLASS Y Y Y — FRAMELESS SWIPECARD BUILDING STANDARD HERCULTE 402 Interview Room 402a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 403 Interview Room 403a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 405 Visitor Servery/Coats 405a 6’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE 406 Executive Conference 406a 6’-0” 8“0” — GLASS N N Y — Drywall return BUTT GLASS/FLAT TRACK BARN DOOR HARDWARE/SS 407 VP Office 407a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 408 MGR Office 408a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 409 MGR Office 409a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 410 Team RM/Phone Enclave 410a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 411 Open Office 411a 3’-0” 8“0” 1-3/4” MAPLE Y Y Y PASSAGE LITE HM CARD ACCESS SWIPE CARD ACCESS 412 VP Office 412a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 413 VP Office 413a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 414 VP Office 414a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 415 VP Office 415a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 417 MGR Office 417a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 418 MGR Office 418a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 419 MGR Office 419a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 421 MGR Office 421a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 422 MGR Office 422a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 423 MGR Office 423a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 424 VP Office 424a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS InteriorLOGIC, Inc. Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 ROOM ROOM DOOR SIZE SELF FRAME # NAME NO. WIDTH HEIGHT THICK MATL CLOSURE LOCKING GLASS TYPE MATL FUNCTION NOTES 425 Director Office 425a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 426 Conference 426a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 428 Copy/Mail 428a 3’-6” 8“0” — — — — — — — FRAMED OPENING 428b 3’-6” 8“0” — — — — — — — FRAMED OPENING 429 Mgr Office 429a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 430 Mgr Office 430a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 434 Dining 434a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 435 Kitchen 435a 6’-0” 8’-0” — — — — — — — FRAMED OPENING 436 Vending 436a 3’-0” 8“0” — — N N N — — FRAMED OPENING 436b 3’-0” 8“0” — — N N N — — FRAMED OPENING 438 Kitchen Storage 438a 3’-0” 8“0” 1-3/4” MAPLE — Y — — HM STOREROOM 439 Health Services 439a 3’-0” 8“0” — — — — — — — FRAMED OPENING 440 Health Services 440a 3’-0” 8“0” 1-3/4” MAPLE N Y N — HM PRIVACY PRIVACY LOCK 442 Hardware Storage 442a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM STOREROOM 443 LAN Room 443a 3’-0” 8“0” 1-3/4” MAPLE N Y Y PASSAGE LITE HM CARD ACCESS SWIPECARD 445 Director Office 445a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 446 Phone Enclave 446a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 447 Director Office 447a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 448 Open Office 448a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SIDELITE 448b 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SIDELITE 449 HR Storage 449a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PRIVACY PRIVACY LOCK NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS InteriorLOGIC, Inc. Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 ROOM ROOM DOOR SIZE SELF FRAME # NAME NO. WIDTH HEIGHT THICK MATL CLOSURE LOCKING GLASS TYPE MATL FUNCTION NOTES 450 Director Office 450a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 452 Team Rm/Phone Enclave 452a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE SIDELITE 454 Open Office 454a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SWIPECARD 455 Director Office 455a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 456 Director Office 456a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 457 Director Office 457a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 459 Mgr Office 459a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 460 Mgr Office 460a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 461 Mgr Office 461a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 462 Passage 462a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM CARD ACCESS SWIPECARD 463 Phone Enclave 463a 3’-0” 8“0” 1-3/4” MAPLE N N Y PASSAGE LITE HM PASSAGE 464 Copy/Mail 464a — — — — — — — — FRAMED OPENING 465 Mgr Office 465a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 466 Mgr Office 466a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 467 Mgr Office 467a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 468 Director Office 468a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 469 Director Office 469a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 470 Director Office 470a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 471 Conference 471a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 474 Mgr Office 474a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS InteriorLOGIC, Inc. Door Schedule Client: Connecture Atlanta Project No.: 13004-01 Date: September 20, 2013 ROOM ROOM DOOR SIZE SELF FRAME # NAME NO. WIDTH HEIGHT THICK MATL CLOSURE LOCKING GLASS TYPE MATL FUNCTION NOTES 475 Mgr Office 475a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 477 Passage 477a 3’-0” 8“0” 1-3/4” MAPLE Y Y N — HM SWIPE CARD ACCESS SWlPECARD/SIDE LITE 478 Mgr Office 478a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 479 Mgr Office 479a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 480 Mgr Office 480a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 481 Conference 481a 3’-0” 8“0” 1-3/4” MAPLE N N Y — HM PASSAGE SIDELITE 482 Director Office 482a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 483 VP Office 483a 3‘-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 484 VP Office 484a 3‘-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE 485 Passage 485a 3‘-0” 8“0” 1-3/4” MAPLE Y Y Y PASSAGE LITE HM SWIPE CARD ACCESS SWlPECARD/SIDE LITE 486 Executive Lounge 486a 3’-0” 8“0” 1-3/4” MAPLE N N N — HM PASSAGE SIDELITE NOTE: DOORS AND FRAMES ARE LONG LEAD TIME ITEMS InteriorLOGIC, Inc. Plumbing Fixture Schedule Client: Connecture Atlanta Project No: 13004-01 Date: September 20, 2013 Revised: ROOM # ROOM NAME ITEM MFG. PRODUCT DESC FINISH 404 Visitor Servery sink Kohler K3362-3 Staccato 25” single bowl sink, 3-hole, self rimming stainless steel faucet Kohler K15850-4M Coralis Faucet w/Lever Handles polished chrome disposal by LL Engineer 435 Kitchen sink Kohler K3362-3 Staccato 25” single bowl sink, 3-hole, self rimming stainless steel faucet Kohler K-15888-K Coralis Faucet w/Leverl Handles disposal by LL Engineer 439 Health Services toilet Kohler K-3949 Highline Comfort Height, 1.28 GPF, left hand lever White sink Kohler ▇▇▇▇▇-▇-▇ ▇▇▇▇▇▇▇▇▇ dropinsink w/concentricecircles, cast iron, 8” centers White faucet Kohler ▇-▇▇▇▇▇-▇ ▇▇▇▇▇▇ widespread faucet w/lever handles White PROVIDE ALL RELATED KOHLER ACCESSOSSORIES Hot water at all sink locations SCHEDULE C-3 SAMPLE LEVEL OF DETAIL FOR DESIGN DEVELOPMENT DRAWINGS AND SPECIFICATIONS Reference is made to the following plans prepared by InteriorLOGIC for Connecture in other areas the Brookfield ▇▇▇▇▇ ▇▇▇▇▇▇▇▇▇ ▇▇▇▇▇▇ ▇▇▇▇▇▇▇▇ ▇▇▇▇, ▇▇▇▇▇▇▇ ▇▇. ▇▇▇▇▇, dated April 27, 2012: Improvements Index 1. Drawings A200 – Connecture Second Floor Demolition Plan prepared by InteriorLOGIC, dated 4/27/12 A201 – Connecture Second Floor Partition Plan prepared by InteriorLOGIC, dated 4/27/12 A203 – Connecture Second Floor Finish Plan prepared by InteriorLOGIC, dated 4/27/12 A204 – Connecture Second Floor Electrical Plan prepared by InteriorLOGIC, dated 4/27/12 A204 – Connecture Second Floor Ceiling Plan prepared by InteriorLOGIC, dated 4/27/12 A300 – Connecture Third Floor Demolition Plan prepared by InteriorLOGIC, dated 4/27/12 A301 – Connecture Third Floor Partition Plan prepared by InteriorLOGIC, dated 4/27/12 A303 – Connecture Third Floor Finish Plan prepared by InteriorLOGIC, dated 4/27/12 A304 – Connecture Elevations and Details prepared by InteriorLOGIC, dated 4/27/12 A305 – Connecture Elevations and Details prepared by InteriorLOGIC, dated 4/27/12 A306 – Connecture Floor Pattern Plan prepared by InteriorLOGIC, dated 4/27/12 A307 – Connecture Electrical Schematic prepared by InteriorLOGIC, dated 4/27/12 A308 – Connecture Third Floor Ceiling Plan prepared by InteriorLOGIC, dated 4/27/12 2. Schedules and Specifications A. Workletter Finish and Material Specification B. Room Finish Schedule C. Product Cut Sheets D. Casework Schedule E. Door Schedule 3. AutoCAD Files A. Second Floor B. Third Floor C-17 EXHIBIT D RULES AND REGULATIONS 1. The sidewalks, and public portions of the Building, such as entrances, passages, courts, elevators, vestibules, stairways, corridors or halls, and the streets, alleys or ways surrounding or in the vicinity of the Building shall not be obstructed, even temporarily, or encumbered by Tenant or used for any purpose other than ingress and egress to and from the Premises. 2. No awnings or other projections shall be attached to the outside walls of the Building. No curtains, blinds, shades, louvered openings, tinted coating, film or screens shall be attached to or hung in, or used in connection with, any window, glass surface or door of the Premises, without the prior written consent of Landlord, unless installed by Landlord. 3. No sign, advertisement, notice or other lettering shall be exhibited, inscribed, painted or affixed by Tenant on any part of the outside of the Premises or Building or on corridor walls or windows or other glass surfaces (iii) including without limitation glass storefronts). Signs on entrance door or doors shall conform to test Subtenant's equipment building standard signs, samples of which are on display in Landlord’s rental office. Signs on doors shall, at Tenant’s expense, be inscribed, painted or affixed for each tenant by sign makers approved by Landlord. In the event of the violation of the foregoing by Tenant, Landlord may remove same without any liability, and systems installed may charge the expense incurred by such removal to Tenant. 4. The sashes, sash doors, skylights, windows, heating, ventilating and air conditioning vents and doors that reflect or admit light and air into the halls, passageways or other public places in the Building and the Demised Premises. Notwithstanding the foregoing, Subtenant building shall not commence be covered or obstructed by Tenant, nor shall any bottles, parcels, or other articles be placed on the window ▇▇▇▇▇. 5. No show cases or other articles shall be put in front of Subtenant's Work or affixed to any part of the exterior of the Building, nor placed in the Demised Premises until after obtaining public halls, corridors, or vestibules without the prior written consent of Sublandlord Landlord. 6. The water and Prime Landlord of plans wash closets and specifications other plumbing fixtures shall not be used for same. Subtenant shall abide by all terms of this Sublease during its early entry, any purposes other than those terms relating for which they were constructed, and no sweepings, rubbish, rags, or other substances shall be thrown therein. All damages resulting from any misuse of the fixtures shall be borne by Tenant. 7. Tenant shall not in any way deface any part of the Premises or the Building. If Tenant desires to use linoleum or other similar floor covering, an interlining of builder’s deadening felt shall be first affixed to the payment floor, by a paste or other material, soluble in water; the use of cement or other similar adhesive materials, which are not water soluble, are expressly prohibited. 8. No bicycles, vehicles, or animals of any rental amounts. Subtenant kind shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons be brought into or property, to the extent same arises from any act or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while kept in or about the BuildingPremises. No cooking shall be done or permitted by Tenant on the Premises except in conformity to law and then only in the utility kitchen, arising if any, as set forth in Tenant’s layout, which is to be primarily used by Tenant’s employees for heating beverages and light snacks. Tenant shall not cause or permit any unusual or objectionable odors to be produced upon or permeate from any liens or claims the Premises. 9. No space in the Building shall be used for services rendered or labor or materials furnished in manufacturing, distribution, or for the performance storage of Subtenant's Work merchandise or arising from any accident for the sale of merchandise, goods, or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance property of any work therein, Subtenant shall furnish Sublandlord, kind at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Work, nor its move-in process to the Demised Premisesauction.

Early Access. Subtenant shall have After Landlord determines that the right Landlord’s First Floor Expansion Premises TI Work has sufficiently progressed to the point where permitting Tenant to enter the Demised ------------ First Floor Expansion Premises will not adversely affect the timely completion of the remaining elements of Landlord’s First Floor Expansion Premises TI Work, then prior to the First Floor Expansion Premises Commencement Date following full execution of this Sublease, Landlord shall permit Tenant to enter the First Floor Expansion Premises for the purpose of (i) testing preparing the equipment in the Building; (ii) commencing Subtenant's Work in the Demised First Floor Expansion Premises for occupancy by Tenant. Any such early entry shall be at Tenant’s sole risk and in other areas of the Building and (iii) to test Subtenant's equipment and systems installed in the Building and the Demised Premises. Notwithstanding the foregoingexpense, Subtenant shall not commence any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entryand, other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damage, including damage to person, persons or property, excepting only to the extent same arises from any act caused by the gross negligence or negligence willful misconduct of Subtenant's employees, contractor Landlord or any of its subcontractorsLandlord’s agents, employees or contractors, Landlord shall have no liabilities or obligations to Tenant in connection therewith, including any liability for damage or injury to persons or property in connection therewith. Upon such entry, Tenant shall be bound by and shall comply with all provisions of this Lease (excepting only the obligations to pay Base Rent, Tenant’s Pro Rata Share of Expenses, Tenant’s Pro Rata Share of Laboratory Expenses, Tenant’s Pro Rata Share of Taxes or the agents or employees Amenity Fee with respect to the First Floor Expansion Premises), including the provisions of any of same while they are engaged in this Lease regarding obtaining and maintaining insurance coverages, and the performance of Alterations in the First Floor Expansion Premises, notwithstanding that the First Floor Expansion Premises Commencement Date may not yet have occurred. Without limitation, all of such work performed by Tenant in the First Floor Expansion Premises shall be coordinated with any work within the Demised Premises, or while being performed by Landlord and in or about the Building, arising from such manner as to maintain harmonious labor relations. In no event shall any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into such work by Tenant damage the Building or the Demised First Floor Expansion Premises by Subtenant and or interfere with the timely performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none of the above-described work or early entry shall interfere with or delay in any manner any work to be performed by Sublandlord under this Sublease. Further, Subtenant shall not be charged by Sublandlord for the use of any freight elevators, access to the Building's loading docks, utility usage or the use of any other Building facilities or services during the initial planning and subsequent construction of Subtenant's Landlord’s First Floor Expansion Premises TI Work, nor its move-in process to the Demised Premises.

Early Access. Subtenant Tenant shall be allowed early access prior to the Commencement Date for the sole purpose of installation of telecommunication equipment and furniture provided that (i) any delay in Substantial Completion arising from such early occupancy by Tenant, its, employees, contractors, invitees, or agents shall constitute a Tenant Delay, (ii) satisfactory evidence of insurance as required by Article 11 of this Lease shall first have been provided to Landlord and (iii) there shall be harmonious union labor relations between the contractors, subcontractors, suppliers and vendors on site and no disruption of the Work arising from Tenant’s early occupancy hereunder shall be permitted. 1. No sign, placard, picture, advertisement, name or notice shall be installed or displayed on any part of the outside or inside of the Building without the prior written consent of the Landlord. Landlord shall have the right to enter remove, at Tenant’s expense and without notice, any sip installed or displayed in violation of this rule. All approved signs or lettering on doors and walls shall be printed, painted, affixed or inscribed at Tenant’s expense by a vendor designated or approved by Landlord. In addition, Landlord reserves the Demised ------------ right to change from time to time the format or the signs or lettering and to require previously approved signs or lettering to be appropriately altered. 2. If Landlord objects in writing to any curtains, blinds, shades or screens attached to or hung in or used in connection with any window or door of the Premises, Tenant shall immediately discontinue such use. No awning shall be permitted on any part of the Premises. Tenant shall not place anything or allow anything to be placed against or near any glass partitions or doors or windows which may appear unsightly, .in the opinion of Landlord, from outside the Premises. 3. Tenant shall not obstruct any sidewalks, halls, passages, exits, entrances, elevators, or stairways of the Building. No tenant and no employee or invitee of any tenant shall go upon the roof of the Building. 4. Any directory of the Building, if provided, will be exclusively for the display of the name and location of tenants only and Landlord reserves the right to exclude any other names. Landlord reserves the right to charge for tenant’s directory listing. 5. All cleaning and janitorial services for the l3ttilding and the Premises prior shall be provided exclusively through Landlord. Tenant shall not cause any unnecessary labor by carelessness or indifference to the Commencement Date following full execution good order and cleanliness of the Premises. Landlord shall not in any way be responsible to any tenant for any loss or property on the Premises, however occurring, or for any damage to any tenant’s property by the janitor or any other employee or any other person. 6. The toilet rooms, toilets, urinals, wash bowls and other apparatus shall not be used for any purpose other than that for which they were constructed. No foreign substance of any kind whatsoever shall be thrown into any of them and the expense of any breakage, stoppage or damage resulting from the violation of this Subleaserule shall be borne by the tenant who, for the purpose or whose employees or invitees, shall have caused it. 7. Tenant shall store all its trash and garbage within its Premises. Tenant shall not place in any trash box or receptacle any material which cannot be disposed of (i) testing the equipment in the Building; ordinary and customary manner of trash and garbage disposal. All garbage and refuse disposal shall be made in accordance with directions issued from time to time by Landlord. Tenant will comply with any and all recycling procedures designated by Landlord, 8. Landlord will furnish Tenant two (ii2) commencing Subtenant's Work keys free of charge to each door in the Demised Premises premises that has a passage way lock. Landlord may charge Tenant a reasonable amount for any additional keys, and Tenant shall not make or have made additional keys on its own. Tenant shall not alter any lock or install a new or additional lock or bolt on any door of its Premises. Tenant, upon the termination of its tenancy, shall deliver to Landlord the keys of all doors which have been furnished to Tenant, and in the event or loss of any keys so furnished, shall pay Landlord therefor. 9. If Tenant requires telephone, data, burglar alarm or similar service, the cost of purchasing, installing and maintaining such service shall be borne solely by Tenant. No boring or cutting for wires will be allowed without the prior written consent of Landlord. 10. No equipment, materials, furniture, packages, bulk supplies, merchandise or other areas property will be received in the Building or carried in the elevators except between such hours and in such elevators as may be designated by Landlord. The persons employed to move such equipment or materials in or out of the Building must be acceptable to Landlord. 11. Tenant shall not place a load upon any floor which exceeds the load per square foot which such floor was designed to carry and which is allowed by law. Heavy objects shall stand on such platforms as determined by Landlord to be necessary to properly distribute the weight. Business machines and mechanical equipment belonging to Tenant which cause noise or vibration that may be transmitted to the structure of the Building or to any space in the Building to such a degree as to be objectionable to Landlord or to any tenants shall be placed and maintained by Tenant, at Tenant’s expense, on vibration eliminators or other devices sufficient to eliminate the noise or vibration. Landlord will not be responsible for loss of or damage to any such equipment or other• property from any cause, and all damage done to the Building by maintaining or moving such equipment or other property shall be repaired at the expense of Tenant. 12. Landlord shall in all cases retain the right to control and prevent access to the Building of all persons whose presence in the judgment of Landlord would be prejudicial to the safety, character, reputation or interests of the Building and its tenants, provided that nothing contained in this rule shall be construed to prevent such access to persons with whom any tenant normally deals in the ordinary course of its business, unless such persons are engaged in illegal activities. Landlord reserves the right to exclude from the Building between the hours of 6 p.m. and 7 a.m. the following day, or such other hours as may be established from time to time by 1.andlord, and on Sundays and legal holidays, any person unless that person is known to the person or employee in charge of the Building and has a Pass or is properly identified. Tenant shalt be responsible for all poisons for whom it requests passes and shall be liable to Landlord for all nets of such persons. Landlord shall not be liable for damages for any error with regard to the admission to or exclusion from the Building of any person. 13. Tenant shall not use any method of heating or air conditioning other than that supplied or approved in writing by Landlord. 14. Tenant shall not waste electricity, water or air conditioning. Tenant shall keep corridor doors closed. Tenant shall close and lock the doors of its Premises and entirely shut off all water faucets or other water apparatus and electricity, gas or air outlets before Tenant and its employees leave the Premises. Tenant shall be responsible for any damage or injuries sustained by other tenants or occupants of the Building or by Landlord for noncompliance with this rule. 15. Tenant shall not install any radio or television antenna, satellite dish, loudspeaker or other device on the roof or exterior walls of the Building without landlord’s prior written consent, which consent may be withheld in Landlords sole discretion, and which consent may in any event be conditioned upon Tenant’s execution of Landlord’s standard form of license agreement. Tenant shall be responsible for any interference caused by such installation. 16. Tenant shall not m▇▇▇, drive nails, screw or drill into the partitions, woodwork, plaster, or drywall (iiiexcept for pictures, tack boards and similar office uses) or in any way deface the Premises. Tenant shall not cut or bore holes for wires, Tenant shall not affix any floor covering to the floor of the Premises in any manner except as approved by Landlord. ‘rennin shall repair any damage resulting from noncompliance with this rule. 17. Tenant shall not install, maintain or operate .upon the Premises any vending machine without Landlord’s prior written consent, except that Tenant may install food and drink vending machines solely for the convenience of its employees. 18. No cooking shall be done or permitted by any tenant on the Premises, except that approved microwave ovens or equipment for brewing coffee, tea, hot chocolate and similar beverages shall be permitted provided that such equipment and use is in accordance with all applicable federal, state and city laws, codes, ordinances, rules and regulations. 19. Tenant shall not use in any space or in the public halls of the Building any hand trucks except those equipped with the rubber tires and side guards or such other material-handling equipment as Landlord may approve. Tenant shall not bring any other vehicles of any kind into the Building. 20. Tenant shall not permit any motor vehicles to be washed or mechanical work or maintenance of motor vehicles to be performed in any parking lot. 21. Tenant shall not use the name of the Building or any photograph or likeness of the Building in connection with or in promoting or advertising Tenant’s business. except that Tenant may include the Building name in Tenant’s address. Landlord shall have the right, exercisable without notice and without liability to any tenant. to change the name and address of the Building. 22. Tenant requests for services must be submitted to the Building office by an authorized individual. Employees of Landlord shall not perform any work or do anything outside of their regular duties unless under special instruction from Landlord, and no employee of Landlord will admit any person (Tenant or otherwise) to test Subtenant's equipment and systems installed any office without specific instructions from Landlord. 23. Tenant shall not permit smoking or carrying of lighted cigarettes or cigars other than in areas designated by Landlord as smoking areas. 24. Canvassing, soliciting, distribution of handbills or any other written material in the Building is prohibited and each tenant shall cooperate to prevent the Demised Premisessame, No tenant shall solicit business from other tenants or permit the sale of any good or merchandise in the Building, without the written consent or Landlord. 25. Notwithstanding the foregoing, Subtenant Tenant shall not commence permit any of Subtenant's Work in the Demised Premises until after obtaining the consent of Sublandlord and Prime Landlord of plans and specifications for same. Subtenant shall abide by all terms of this Sublease during its early entry, animals other than those terms relating to the payment of any rental amounts. Subtenant shall indemnify and save Sublandlord harmless from and against all loss and damageservice animals, including damage to person, persons or propertye.g. seeing eye dogs, to the extent same arises from any act be brought or negligence of Subtenant's employees, contractor or any of its subcontractors, or the agents or employees of any of same while they are engaged in the performance of any work within the Demised Premises, or while kept in or about the Building, arising from Premises or any liens or claims for services rendered or labor or materials furnished in or for the performance of Subtenant's Work or arising from any accident or injury. Prior to the initial entry into the Building or the Demised Premises by Subtenant and the performance of any work therein, Subtenant shall furnish Sublandlord, at Subtenant's sole cost, a certificate of insurance from Subtenant and Subtenant's contractors and subcontractors, naming Sublandlord as an additional insured, in the coverage and amounts reasonably required by Sublandlord. Subtenant acknowledges and agrees that none common area of the above-described work or early entry shall interfere with or delay Building. 26. These Rules and Regulations are in any manner any work to be performed by Sublandlord under this Sublease. Furtheraddition to, Subtenant and shall not be charged by Sublandlord construed to in any way modify or amend, in whole or in part, the terms, covenants, agreements and conditions of any lease of any premises in the Building. Landlord may waive any one or more of these Rules and Regulations for the use benefit of any freight elevatorsparticular tenant or tenants, access to the Building's loading docks, utility usage or the use but no such waiver by Landlord shall be construed as a waiver of such Rules and Regulations in favor of any other Building facilities tenant or services during the initial planning and subsequent construction of Subtenant's Worktenants, nor prevent Landlord from thereafter enforcing any such Rules and Regulations against any or all of the tenants of the Building. 27. Landlord reserves the right to make such other and reasonable rules and regulations as in its move-judgment may from time to time be needed for safety and security, for care and cleanliness of the Building, and for the preservation of good order in process and about the Building. Tenant agrees to abide by all such rules and regulations herein stated and any additional rules and regulations which are adopted. Tenant shall be responsible for the Demised Premisesobservance of all of the foregoing rules by Tenant’s employees, agents, clients, customers, invitees and guests. THIS FIRST AMENDMENT TO LEASE (this “Amendment”) is made and entered into as of the 3rd day of February, 2010 (the “Effective Date”), by and between MUSREF 13727 NOEL, L.P., a Washington limited partnership (“Landlord”) and EQUITYMETRIX, LLC, a Texas limited liability company (“Tenant”).