Date required by. .1.6 Whether it is to be an ongoing or temporary job.
Date required by Sample Clauses
Related to Date required by
Updated Certification of Required Insurances As insurance coverage is traditionally of a term nature, it is the Contractor’s responsibility to maintain not just the appropriate insurance coverages, but also their filed certifications with OGS. The Contractor shall furnish to the State up to date certifications of coverages for all insurance requirements per section 4.16 - Insurance Requirements.
INSURANCE REQUIREMENT REVIEW Grantee agrees to periodic review of insurance requirements by Agency under this Agreement and to provide updated requirements as mutually agreed upon by Grantee and Agency.
Definition of Building Where Lift Required 1.1 A passenger/materials lift shall be provided on a building which shall, when complete, consist of more than six (6) storey levels excluding the roof, parapets and basement levels (if any), but including the ground floor. (Refer to Sub Clause 2.1 herein.)
County Review and Approval of Insurance Requirements The County reserves the right to review and adjust the Required Insurance provisions, conditioned upon County’s determination of changes in risk exposures.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Are There Penalties for Early Distribution from a Xxxx XXX As indicated above, earnings on your contributions, as well as amounts contributed to a Xxxx XXX as a rollover from a Traditional IRA, that are distributed before certain events are subject to various taxes. Please see IRS Publication 590 for further information about Xxxx XXX rules and restrictions.
Required Reports (1) As required in Attachment H, Disadvantaged Business Enterprise or Historically Underutilized Business Program Requirements, the Engineer shall submit Progress Assessment Reports to report actual payments made to Disadvantaged Business Enterprises or Historically Underutilized Businesses. One copy shall be submitted with each billing statement and one copy shall be submitted to the address included in Attachment H, Disadvantaged Business Enterprise or Historically Underutilized Business Program Requirements.
Affirmative Action Compliance The offeror represents that-
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Required Reporting Pursuant to RCW 67.28.1816(2)(c)(i): All recipients must submit a report to the COUNTY by December 15, 2020 describing the actual number of people traveling for business or pleasure on a trip during 2020:
