Costs Resulting from Errors or Omissions Sample Clauses

Costs Resulting from Errors or Omissions. The Municipality shall reimburse the DOT for one hundred percent (100%) of all construction costs and costs of DOT-provided Services, which costs are the result of errors or omissions of the Municipality or its consultant(s), including, but not limited to, errors or omissions with respect to the PS&E, inadequate provision of the Inspection Activities or Design Services During Construction by the Municipality or any of its consultants, or inadequate Administration by the Municipality, as applicable. In order to determine the total cost of DOT-provided Services that were attributable to the errors and omissions of the Municipality (as such are not itemized during the Construction Project), a percentage(s) will be derived from the ratio of the total cost of all DOT-provided Services to the total actual construction cost, as determined by a post-construction audit, and this percentage will be multiplied by the amount attributable to the Municipality’s error or omission, as determined by the DOT, to determine the cost of DOT-provided Services incurred as a result of the errors or omissions which the Municipality must reimburse to the DOT. This provision will survive the expiration of the PAL, the final acceptance of the Construction Project, and the termination of the Master Agreement, or the expiration of the Term.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to Costs Resulting from Errors or Omissions

  • Delays or Omissions No delay or omission to exercise any right, power or remedy accruing to any party under this Agreement, upon any breach or default of any other party under this Agreement, shall impair any such right, power or remedy of such non-breaching or non-defaulting party nor shall it be construed to be a waiver of any such breach or default, or an acquiescence therein, or of or in any similar breach or default thereafter occurring; nor shall any waiver of any single breach or default be deemed a waiver of any other breach or default theretofore or thereafter occurring. Any waiver, permit, consent or approval of any kind or character on the part of any party of any breach or default under this Agreement, or any waiver on the part of any party of any provisions or conditions of this Agreement, must be in writing and shall be effective only to the extent specifically set forth in such writing. All remedies, either under this Agreement or by law or otherwise afforded to any party, shall be cumulative and not alternative.

  • Errors/Omissions The Engineer shall make revisions to the work authorized in this contract which are necessary to correct errors or omissions appearing therein, when required to do so by the State. No additional compensation shall be paid for this work.

  • Professional Liability (Errors & Omissions Insurance with limits of not less than $1,000,000 each occurrence, $2,000,000 aggregate. Such insurance will cover all professional services rendered by or on behalf of PROVIDER and its subcontractors under this Agreement. Renewal policies written on a claims- made basis will maintain the same retroactive date as in effect at the inception of this Agreement. If coverage is written on a claims-made basis, PROVIDER agrees to purchase an Extended Reporting Period Endorsement, effective for two (2) full years after the expiration or cancellation of the policy. No professional liability policy written on an occurrence form will include a sunset or similar clause that limits coverage unless such clause provides coverage for at least three (3) years after the expiration of cancellation of this Agreement.

  • Breach of Contract Claims To the extent that Chapter 2260, Texas Government Code, is applicable to this Agreement and is not preempted by other applicable law, the dispute resolution process provided for in Chapter 2260 and the related rules adopted by the Texas Attorney General pursuant to Chapter 2260, will be used by University and Contractor to attempt to resolve any claim for breach of contract made by Contractor that cannot be resolved in the ordinary course of business. The chief business officer of University will examine Contractor's claim and any counterclaim and negotiate with Contractor in an effort to resolve the claims. The parties specifically agree (i) neither execution of this Agreement by University nor any other conduct, action or inaction of any representative of University relating to this Agreement constitutes or is intended to constitute a waiver of University’s or the state's sovereign immunity to suit; and (ii) University has not waived its right to seek redress in the courts.

  • Exceptions from Liability Without limiting the generality of any other provisions hereof, neither the Custodian nor any Domestic Subcustodian shall be under any duty or obligation to inquire into, nor be liable for:

  • Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11

  • No Special Damages In no event shall either party be liable hereunder (whether in an action in negligence, contract or tort or based on a warranty or otherwise) for any indirect, incidental, special or consequential damages incurred by the other party or any third party, even if the party has been advised of the possibility of such damages.

  • Extent of Liability; Contribution (a) Notwithstanding anything herein to the contrary, each Borrower’s liability under this Section 5.11 shall be limited to the greater of (i) all amounts for which such Borrower is primarily liable, as described below, and (ii) such Borrower’s Allocable Amount.

  • Excluded Action or Omissions To indemnify Indemnitee for acts, omissions or transactions from which Indemnitee may not be relieved of liability under applicable law.

  • Delays or Omissions; Waivers No failure on the part of either Party to exercise any power, right, privilege or remedy under this Agreement, and no delay on the part of either Party in exercising any power, right, privilege or remedy under this Agreement, shall operate as a waiver of such power, right, privilege or remedy; and no single or partial exercise or waiver of any such power, right, privilege or remedy shall preclude any other or further exercise thereof or of any other power, right, privilege or remedy. No Party shall be deemed to have waived any claim arising out of this Agreement, or any power, right, privilege or remedy under this Agreement, unless the waiver of such claim, power, right, privilege or remedy is expressly set forth in a written instrument duly executed and delivered on behalf of such Party; and any such waiver shall not be applicable or have any effect except in the specific instance in which it is given.

Time is Money Join Law Insider Premium to draft better contracts faster.