CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT Clause Samples

CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT. The contractor may suspend work or terminate contract upon ten days written notice to the owner and Engineer, for any of the following reasons: a) If an order of any court, or public authority caused the work to be stopped or suspended for a period of ninety days through no act or fault of the contractor or their employees. b) If the Engineer should fail to act upon any request for payment within thirty days after it is presented in accordance with the general conditions of the contract. c) If the owner should fail to pay the contractor any sum within thirty days after its award by arbitrators.
View SourceView Similar (16)
CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT. 11.1.1 The Contractor may suspend work or terminate the Contract upon fifteen (15) days written notice to the Owner for any of the following reasons: a. If the Owner fails to deliver the Project site to the Contractor within fifteen (15) days from the effectivity of the Contract; b. If the Owner fails to secure the building or construction permit within thirty (30) days from the effectivity of the Contract; c. If an order of any court or other public authority caused the Work to be stopped or suspended for an aggregate period of ninety (90) days or more through no act or fault of the Contractor or its employees; d. If the Owner fails to pay the Request for Payment or any amount due the Contractor within the prescribed period and as herein provided; e. If the Owner suspends the Work without just cause for more than an aggregate period of fifteen (15) days without the Contractor’s consent; f. If the Owner fails to deliver at the construction site the Owner-supplied construction materials and/or equipment for the scope of work along the critical path, beyond fifteen (15) days after the agreed scheduled date of delivery; and g. If the Owner fails to issue its approval of Variation Orders for additional works along the critical path, beyond fifteen (15) days after its submission. 11.1.2 If the suspension is necessary for the proper execution of the Work or by reason of weather or other conditions affecting the safety of the Works and/or the Contractor’s workers, the Contractor may request the Owner to suspend work in accordance with the applicable provisions herein provided. 11.1.3 The Contractor shall be entitled to an equitable adjustment of Completion Time and/or Contract Price for suspension of work due to the above circumstances.
View Source
CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT. If the work should be stopped under an order of any court or other public agency through no act or fault of the Contractor or of anyone employed by them or if the Engineer fails to issue a certificate in accordance with Section 29, in circumstances other than those in which the Engineer is entitled to withhold the certificate under this Contract, or if the Owner should fail to pay to the Contractor within ten (10) days of its maturing and presentation, any sum certified by the Engineer or awarded by arbitrators, then the Contractor may upon five (5) days written notice to the Owner and the Engineer stop work or remedy they may have, and recover from the Owner payment for all work executed and any loss sustained upon the plant or material with reasonable profit and damage.
View Source

Related to CONTRACTOR'S RIGHT TO SUSPEND WORK OR TERMINATE CONTRACT

  • Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.

  • Suspension of Work and Termination 15.01 Owner May Suspend Work A. At any time and without cause, Owner may suspend the Work or any portion thereof for a period of not more than 60 consecutive days by written notice to Contractor and Engineer. Such notice will fix the date on which Work will be resumed. Contractor shall resume the Work on the date so fixed. Contractor shall be entitled to an adjustment in the Contract Price or an extension of the Contract Times, or both, directly attributable to any such suspension.