Common use of Construction; Substantial Completion Clause in Contracts

Construction; Substantial Completion. Landlord shall cause a contractor selected by Landlord ("Landlord's Contractor") to construct the Tenant Improvements as shown on the Plans in compliance with this Paragraph 4. With regard to telephones and computer systems, Landlord shall provide and cause to be installed only those wall terminal boxes and/or floor monuments required for Tenant's telephone or computer systems as are shown on the Plans. Landlord will provide ordinary power wiring to locations shown on the Plans and shall provide and cause to be installed conduits as required for Tenant's telephone and computer systems as shown on the Plans, but shall in no event install, pull or hook up such wires, supply jacks or plugs or provide wiring necessary for special conditioned power to the Premises."Substantial Completion" of the Tenant Improvements for the Initial Premises or Added Premises, as the case may be, shall be deemed to have occurred when the Tenant Improvements for such portion of the Premises have, in Landlord's reasonable judgment, been completed in accordance with the Plans, subject only to correction or completion of "Punch List" items, which items shall be limited to minor items of incomplete or defective work or materials or mechanical maladjustments that are of such a nature that they do not materially interfere with or impair Tenant's use of such portion of the Premises for Tenant's business. The definition of "Substantially Completed" shall also apply to the terms "Substantial Completion" and "Substantially Complete."

Construction; Substantial Completion. Landlord shall cause a contractor selected by Landlord ("Landlord's Contractor") Contractor to construct the Tenant Improvements as shown on the Plans in compliance with this Paragraph 4. With regard to telephones and computer systems, Landlord shall provide and cause to be installed only those wall terminal boxes and/or floor monuments required for Tenant's telephone or computer systems as are shown on the Plans. Landlord will provide ordinary power wiring to locations shown on the Plans and shall provide and cause to be installed conduits as required for Tenant's telephone and computer systems as shown on the Plans, but shall in no event install, pull or hook up such wires, supply jacks or plugs or provide wiring necessary for special conditioned power to the Premises."Substantial . "Substantial Completion" of the Tenant Improvements for each Increment of the Initial Premises or Added Premises, as the case may be, shall be deemed to have occurred when (a) the Tenant Improvements for such portion of the Premises Increment have, in Landlord's reasonable judgment, been completed in accordance with the Plans, subject only to correction or completion of "Punch List" items, which items shall be limited to minor items of incomplete or defective work or materials or mechanical maladjustments that are of such a nature that they do not materially interfere with or impair Tenant▇▇▇▇▇▇'s use of such portion of the Premises for Tenant's business, and (b) any governmental approvals (which may be oral approvals by inspectors or other officials, and may be temporary or conditional in accordance with local practice) required for the initial occupancy of the Premises by Tenant have been obtained, subject to final inspection and "sign off" as to isolated or incidental items of construction (provided that if the failure to obtain such approval results from construction of Tenant Improvements in accordance with Plans which do not comply with building codes or other Legal Requirements, then this item (b) shall not be a condition to the occurrence of Substantial Completion). The definition of "Substantially Completed" shall also apply to the terms "Substantial Completion" and "Substantially Complete."

Construction; Substantial Completion. Landlord shall cause a contractor selected by Landlord ("Landlord's Contractor") Contractor to construct commence the construction of the Tenant Improvements as shown on soon as is reasonably possible after approval of the Plans in compliance with this Paragraph 4Final Plans. With regard to telephones and computer systems, Landlord shall provide and cause to be installed only those wall terminal boxes and/or floor monuments required for Tenant's telephone or computer systems as are shown on the Final Plans. Landlord will provide ordinary power wiring to locations shown on the Final Plans and shall provide and cause to be installed conduits as required for Tenant's telephone and computer systems as shown on the Final Plans, but shall in no event install, pull or hook up such wires. Further, supply jacks or plugs or provide wiring necessary for special conditioned power notwithstanding anything to the Premises."Substantial Completion" of the contrary herein, Landlord and Tenant shall cooperate with each other to resolve any space plan issues raised by applicable local building codes. The Tenant Improvements for the Initial Premises or Added Premises, as the case may be, shall be deemed to have occurred be "Substantially Completed" when the Tenant Improvements for such portion of the Premises they have, in Landlord's and Tenant's reasonable judgment, been completed in accordance with the Final Plans, subject only to correction or completion of "Punch List" items, which items shall be limited to minor items of incomplete or defective work or materials or mechanical maladjustments that are of such a nature that they do not materially interfere with or impair Tenant's use of such portion of the Premises for Tenant's business. The definition of "Substantially Completed" shall also apply to the terms "Substantial Completion" and "Substantially Complete"."

Construction; Substantial Completion. Landlord shall cause a contractor selected by Landlord ("Landlord's Contractor") Contractor to construct commence the construction of the Tenant Improvements as shown on soon as is reasonably possible after the approval by Landlord and Tenant of the Final Plans in compliance with this Paragraph 4and the Final Budget. With regard to telephones and computer systems, Landlord shall provide and cause to be installed only those wall terminal boxes and/or floor monuments required for Tenant's ’s telephone or computer systems as are shown on the Final Plans. Landlord will provide ordinary power wiring to locations shown on the Plans and shall provide and cause to be installed conduits as required for Tenant's ’s telephone and computer systems as shown on the Final Plans, but shall in no event install, pull or hook up such wires. Further, supply jacks or plugs or provide wiring necessary for special conditioned power notwithstanding anything to the Premises."Substantial Completion" of the contrary herein, Landlord and Tenant shall cooperate with each other to resolve any space plan issues raised by applicable local building codes. The Tenant Improvements for the Initial Premises or Added Premises, as the case may be, shall be deemed to have occurred be “Substantially Completed” when the Tenant Improvements for such portion of the Premises (i) they have, in Landlord's ’s reasonable judgment, been completed in accordance with the Final Plans, subject only to correction or completion of "“Punch List" ” items, which items shall be limited to minor items of incomplete or defective work or materials or mechanical maladjustments that are of such a nature that they do not materially interfere with or impair Tenant's ’s use of such portion of the Premises for Tenant's business’s business and (ii) any governmental approvals (which may be oral approvals by inspectors or other officials, and may be temporary or conditional in accordance with local practice) and permits required for the legal occupancy of the Premises have been issued. The definition of "“Substantially Completed" ” shall also apply to the terms "“Substantial Completion" ” and "“Substantially Complete."”