Common use of CLAUSES INCORPORATED BY REFERENCE (FEB 1998 Clause in Contracts

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an Internet “search engine” (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 STOP-WORK ORDER AUG 1989 52.242-17 GOVERNMENT DELAY OF WORK APR 1984

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates one or more the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. Department of State Acquisition Website website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an Internet “search engine” (e.g.for example, Google, Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 STOP-WORK ORDER (AUG 1989 52.242-17 GOVERNMENT DELAY OF WORK APR 19841989)

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates one or more clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. of State Acquisition Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an Internet “search engine” ―search engine‖ (e.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 STOP-WORK ORDER AUG 1989 52.242-17 GOVERNMENT DELAY OF WORK APR 1984

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates one or more the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically atat this address: xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Dept. Department of State Acquisition Website website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an Internet internet “search engine” (e.g.for example Google, Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 STOP-WORK ORDER AUG 1989 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 52.242-14 SUSPENSION OF WORK APR 1984