Common use of CLAUSES INCORPORATED BY REFERENCE (FEB 1998 Clause in Contracts

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm. These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an Internet “search engine” (for example, Google, Yahoo, Excite) to obtain the latest location of the most current FAR. The following FAR clauses are incorporated by reference: CLAUSE TITLE AND DATE 52.242-15 STOP-WORK ORDER (AUG 1989)* *52.242-15 applies to Standard Services in Section B 52.242-15 STOP-WORK ORDER (Alternate I, APR 1984*) *52.242-15, Alternate I (APR 1984), applies to Temporary Additional Services 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxx.xxxxxxxxxxx.xxx/far/ xxxx://xxxxxxxxxxx.xxx/far/index.html or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm. These Please note these addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website xxxxx://xxx.xxxx.xxx/cgi-bin/text- idx?SID=2e978208d0d2aa44fb9502725ecac4e5&mc=true&tpl=/ecfrbrowse/Title4 8/48chapter6.tpl at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see access the links to the FAR. You may also use an Internet “search engine” (for example, Google, Yahoo, Yahoo or Excite) to obtain the latest location of the most current FAR. The following FAR Federal Acquisition Regulation clauses are incorporated by reference: CLAUSE 52.202-1 TITLE AND DATE 52.242DEFINITIONS (NOV 2013) 52.203-15 STOP-WORK ORDER (AUG 1989)* *52.242-15 applies to Standard Services in Section B 52.242-15 STOP-WORK ORDER (Alternate I, APR 1984*) *52.242-15, Alternate I 3 GRATUITIES (APR 1984) 52.203-5 COVENANT AGAINST CONTINGENT FEES (MAY 2014), applies to Temporary Additional Services 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm. These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department of State Acquisition website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ xxxxx://xxx.xxxx.xxx/cgi-bin/text- idx?SID=2e978208d0d2aa44fb9502725ecac4e5&mc=true&tpl=/ecfrbrowse/Title48/48chapt er6.tpl to see the links to the FAR. You may also use an Internet “search engine” (for example, Google, Yahoo, Excite) to obtain the latest location of the most current FAR. The following FAR clauses are incorporated by reference: CLAUSE TITLE AND DATE 52.242-15 STOP-WORK ORDER (AUG 1989)* *52.242-15 applies to Standard Services in Section B 52.242-15 STOP-WORK ORDER (Alternate I, APR 1984*) *52.242-15, Alternate I (APR 1984), applies to Temporary Additional Services 52.242-17 GOVERNMENT DELAY OF WORK (APR 1984)

CLAUSES INCORPORATED BY REFERENCE (FEB 1998. This contract incorporates the following clauses by reference, with the same force and effect as if they were given in full text. Upon request, the Contracting Officer will make their full text available. Also, the full text of a clause may be accessed electronically at: xxxx://xxx.xxxxxxxxxxx.xxx/far/ or xxxx://xxxxxxx.xxxx.xx.xxx/vffara.htm. xxxx://xxxxxxxxxxx.xxx/far/index.html or, xxxx://xxxxxxx.xxxx.xx.xxx/search.htm These addresses are subject to change. If the Federal Acquisition Regulation (FAR) is not available at the locations indicated above, use the Department Dept. of State Acquisition website Website at xxxx://xxx.xxxxxxxx.xxxxx.xxx/ to see the links to the FAR. You may also use an Internet “search engine” ―search engine‖ (for example, Googlee.g., Yahoo, Excite, Alta Vista, etc.) to obtain the latest location of the most current FAR. The following FAR clauses are incorporated by reference: CLAUSE TITLE AND DATE FEDERAL ACQUISITION REGULATION (48 CFR CH. 1) 52.242-15 STOP-WORK ORDER AUG 1989 52.242-15 STOP-WORK ORDER (AUG 1989)* *52.242-15 applies to Standard Services in Section B 52.242-15 STOP-WORK ORDER (Alternate ALT I, ) APR 1984*) *52.242-15, Alternate I (APR 1984), applies to Temporary Additional Services * 52.242-17 GOVERNMENT DELAY OF WORK APR 1984 *APPLICABILITY OF STOP-WORK ORDER CLAUSES FAR clause 52.242-15, Stop-Work Order, applies to Standard Services in Section B. FAR clause 52.242-15, Stop-Work Order (APR 1984Alternate I), applies to Temporary Additional Services.