CHANGE TO THE CONTRACT Clause Samples

CHANGE TO THE CONTRACT. 10.1.1 Except as expressly permitted in the Contract, the Contract may be changed only in accordance with clause 10. 1. The Parties shall not be liable to each other for any additional work undertaken or expenditure incurred unless the change has been approved in accordance with clause 10.1. 10.1.2 Either party may propose a change to the Contract. CCPs shall be in the format set out at Attachment G. 10.1.3 If the Defence Project Manager proposes a change to the Contract it shall: a. notify the Contractor and the Contractor shall provide a CCP to the Defence Project Manager within a period of 30 days after receipt of such notice or such other period as agreed; or b. provide a CCP to the Contractor and the Contractor shall notify the Defence Project Manager of any changes it requires to the CCP within 30 days of receipt. 10.1.4 The Commonwealth may at its discretion require the Contractor to provide a not-to-exceed quote for the preparation of a CCP, prior to the Contractor preparing the CCP in accordance with clause 10.
View SourceView Similar (2)
CHANGE TO THE CONTRACT. 3.1. The Parties hereby formally declare that, due to the occurrence of a “Vis Maior” (or “Vis Major”) event within the meaning of Article XX (10) of the Contract causing a significant delay in delivery of material parts of Partial Performances, the delivery periods stipulated in Article VI. as well as in Article XVII. of the Contract for executing and handing over the following parts of Partial Performances as defined in the Contract and specified in the Detailed Itemized Budget are herewith extended in accordance with Article XX. (12) of the Contract accordingly to the duration of the “Vis Maior” consequences, in particular as follows: 1) the delivery period of performance g2 shall end by 15 August 2022, 2) the delivery period of performance h1 shall end by 11 May 2022, 3) the delivery period of performance h2 shall end by 28 February 2022, 4) the delivery period of performance h3 shall end by 18 March 2022, 5) the delivery period of performance i3 shall end by 15 September 2022, 6) the delivery period of performance i4 shall end by 15 August 2022, 7) the delivery period of performance i5 shall end by 15 August 2022, 8) the delivery period of performance k2 shall end by 15 September 2022 and 9) the delivery period of performance k4 shall end by 8 May 2022. 3.2. For avoidance of any doubts, the Parties hereby also confirm their mutual understanding of the above delivery periods extension consequences for the terms of contractual penalties stipulated in Article XVII. of the Contract as follows: The Contractor shall not be deemed in delay with its delivery of the above defined parts of Partial Performances before the expiry of the respective deadlines extended herewith and until then the Contractor shall not be obliged to pay to the Client the respective part of contractual penalty for such a delay.
View Source
CHANGE TO THE CONTRACT. 3.1. Beyond the original scope of Work agreed in Contract, the Contractor hereby undertakes to design, manufacture and deliver the Supporting structure to the Client and to install it at the Place of Delivery in accordance with terms and conditions defined herein, including the below agreed deadline. 3.2. By way of derogation from Article VI of the Contract, the Parties hereby agree that the Supporting structure structural design, manufacturing, delivery and installation shall all be completed and handed over to the Client within 8 weeks of the publication of this amendment in the Register of Contracts. 3.3. In the event that the Contractor fails to design, manufacture, deliver and install the Supporting structure by the deadline specified in paragraph 3.2. of this amendment, the Contractor shall be obliged to pay to the Client a fixed lump sum contractual penalty of CZK 20 000. Payment of this fixed lump sum contractual penalty shall not affect the Client's right to compensation for damages or other claims arising from the Contract. 3.4. The Client undertakes to take over and accept duly and timely delivered and installed Supporting structure by signing of the Supporting structure Acceptance Protocol and to pay the Supporting structure price defined in paragraph 3.5 of this amendment to the Contractor. For the sake of clarity, the Client is hereunder obliged to accept and take over only the efficient Supporting structure that is fully in compliance with all requirements specified in the structural design prepared by the Contractor and previously accepted in written by the Client. 3.5. By way of derogation from Article VIII of the Contract, the Parties hereby agree on the Price increase by the price for the Supporting structure concluded in the amount of CZK 351.071,- excluding VAT (in words: three hundred fifty-one thousand seventy-one Czech korunas excluding VAT, hereinafter the “Supporting structure price”). The Supporting structure price includes all related cost of the Contractor including those for necessary R&D work, design, manufacturing, delivery, installation, alignment and testing of the Supporting structure. 3.6. By way of derogating from Article VIII (5) of the Contract, the Parties hereby agree that the Supporting structure price shall be paid as follows: 100 % of the Supporting structure price shall be paid within 30 days of the day of signing of the Supporting structure Acceptance Protocol. 3.7. The Contractor provides warranty (quality gua...
View Source
CHANGE TO THE CONTRACT. 3.1. The Parties hereby formally declare that, due to the occurrence of a “Vis Major” event within the meaning of Article XX (10) of the Contract over a period of at least twenty-four
View Source

Related to CHANGE TO THE CONTRACT

  • PARTIES TO THE CONTRACT This Contract is solely between the Company and the SBA which administers the FHCF. In no instance shall any insured of the Company or any claimant against an insured of the Company, or any other third party, have any rights under this Contract, except as provided in Article XIV. The SBA will only disburse funds to the Company, except as provided for in Article XIV of this Contract. The Company shall not, without the prior approval of the Office of Insurance Regulation, sell, assign, or transfer to any third party, in return for a fee or other consideration any sums the FHCF pays under this Contract or the right to receive such sums.

  • CHANGES TO THE CONTRACT All contract modifications must be approved by the Dinwiddie County Administrator or his designee. The County will not assume responsibility for the cost of any changes made without proper consent. No fixed-price contract may be increased by more than twenty-five percent (25%) or $50,000, whichever is greater, without advance approval of the Dinwiddie County Board of Supervisors. Changes can be made to the contract in any of the following ways: A. The parties may agree in writing to modify the terms, conditions, or scope of the contract. Any additional goods or services to be provided shall be of a sort that is ancillary to the contract goods or services, or within the same broad product or service categories as were included in the contract award. Any increase or decrease in the price of the contract resulting from such modification shall be agreed to by the parties as a part of their written agreement to modify the scope of the contract. B. The County may order changes within the general scope of the contract at any time by written notice to the Contractor. Changes within the scope of the contract include, but are not limited to, things such as services to be performed, the method of packing or shipment, and the place of delivery or installation. The Contractor shall comply with the notice upon receipt, unless the Contractor intends to claim an adjustment to compensation, schedule, or other contractual impact that would be caused by complying with such notice, in which case the Contractor shall, in writing, promptly notify the County of the adjustment to be sought, and before proceeding to comply with the notice, shall await the County’s written decision affirming, modifying, or revoking the prior written notice. If the County decides to issue a notice that requires an adjustment to compensation, the Contractor shall be compensated for any additional costs incurred as the result of such order and shall give the County a credit for any savings. Said compensation shall be determined by one of the following methods: 1. By mutual agreement between the parties in writing; or 2. By agreeing upon a unit price or using a unit price set forth in the contract, if the work to be done can be expressed in units, and the Contractor accounts for the number of units of work performed, subject to the County’s right to audit the Contractor’s records and/or to determine the correct number of units independently; or 3. By ordering the Contractor to proceed with the work and keep a record of all costs incurred and savings realized. A markup for overhead and profit may be allowed if provided by the contract. The same markup shall be used for determining a decrease in price as the result of savings realized. The Contractor shall present the County with all vouchers and records of expenses incurred and savings realized. The County shall have the right to audit the records of the Contractor as it deems necessary to determine costs or savings. Any claim for an adjustment in price under this provision must be asserted by written notice to the County within thirty (30) days from the date of receipt of the written order from the County. Neither the existence of a claim nor a dispute resolution process, litigation or any other provision of this contract shall excuse the Contractor from promptly complying with the changes ordered by the County or with the performance of the contract generally.

  • Schedules to the Contract Any schedule to this Contract may be amended or additional schedules may be included, as deemed necessary from time to time by agreement between the parties to this Contract. Each schedule and any amendments thereto shall be dated and signed by the parties to this Contract.

  • Termination of the Contract 1. The Contractor may terminate the contract if the Partner has inadequately discharged or failed to discharge any of the contractual obligations, insofar as this is not due to force majeure, after notification of the Partner by registered letter has remained without effect for one month. 2. The Partner shall immediately notify the Contractor, supplying all relevant information, of any event likely to prejudice the performance of this contract.

  • AMENDMENTS TO THE CONTRACT This Contract shall not be altered, amended, or modified by oral representation made before or after the execution of this Contract. All amendments or changes of any kind must be in writing, executed by all Parties.